Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
17A-218 (9)
BP-2023-1447 160 NORTH MAPLE ST COMMONWEALTH OF MASSACHUSETTS Map:Block:Lot: 17A-218-001 CITY OF NORTHAMPTON Permit: Alts Renovations Repair PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL c.142A) BUILDING PERMIT Permit# BP-2023-1447 PERMISSION IS HEREBY GRANTED TO: Project# RAISE ROOF 2023 Contractor: License: MOST BUILDERS AND GENERAL Est. Cost: 53773 CONTRACTING 102746 Const.Class: Exp.Date: 04/02/2025 Use Group: Owner: L GERSTEIN RICHARD Lot Size (sq.ft.) Zoning: URB Applicant: MOST BUILDERS AND GENERAL CONTRACTING Applicant Address Phone: Insurance: PO BOX 187 (413)777-3146 WC2-335-B21Q1H-013 FEEDING HILLS,MA 01030 ISSUED ON: 02/05/2024 TO PERFORM THE FOLLOWING WORK: RAISING THE ROOF TO CREATE LARGER BEDROOM POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector Underground: Service: Meter: Footings: Rough: Rough: House # Foundation: Final: Final: Final: Rough Frame: Gas: Fire Department Driveway Final: Fireplace/Chimney: Rough: Oil: Insulation: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF ANY OF ITS RULES AND REGULATIONS. Signature: if ) ..1 ► ;ra► ; ii. Fees Paid: $349.00 212 Main Street,Phone(413)587-1240,Fax:(413)587-1272 Office of the Building Commissioner File #BP-2023-1447 A HO 1✓6 APPLICANT/CONTACT PERSON:MOST BUILDERS AND GENERAL CONTRACTING PO BOX 187 FEEDING HILLS,MA 01030(413)777-3146 PROPERTY LOCATION 160 NORTH MAPLE ST MAP:LOT 17A-218-001 ZONE THIS SECTION FOR OFFICIAL USE ONLY: PERMIT APPLICATION CHECKLIST ENCLOSED REQUIRED DATE ZONING FORM FILLED OUT Building Permit Filled out Fee Paid $349.00 Type of Construction: RAISING THE ROOF TO CREATE LARGER BEDROOM New Construction Non Structural Renovations Addition to Existing Accessory Structure Building Plans Included: Owner/ Statement or License . 3 sets of Plans/Plot Plan Driveway Grade%9TFOLLOWING ACTION HAS BEEN TAKEN ON THIS APPLICATION BASED ON ORMATIO P NTED: Approved A ditional permits required(see below) PLANNING BOARD PERMIT REQUIRED UNDER:§ Intermediate Project: Site Plan AND/OR Special Permit With Site Plan Major Project: Site Plan AND/OR Special Permit With Site Plan ZONING BOARD PERMIT REQUIRED UNDER: § 3 50 9,JL - Finding Special Permit Variance* X ,kiOT RF„ N I(ZP b -Uwuif Received&Recorded at Registry of Deeds Proof Enclosed Si) JMIITfA 11?DATvit, s trs Other Permits Required: 171-.`A,1 t (a5o-q',3(S) Curb Cut from DPW Water Availability Sewer Availability Septic Approval Board of Health Well Water Potability Board of Health Permit from Conservation Commission Permit from CB Architecture Committee Permit from Elm Street Commission Permit DPW Storm Water Management Demolition Delay 7/72Z M. 1q-20Z3 Signature of Building Official Date Note:Issuance of a Zoning permit does not relieve a applicant's burden to comply with all zoning requirements and obtain all required permits from Board of Health,Conservation Commission,Department of public works and other applicable permit granting authorities. *Variances are granted only to those applicants who meet the strict standards of MGL 40A.Contact Office of Planning&Development for more information. r The Commonwealth of Massachus is OCT 1 6 23 * f, Board of Building Regulations and St dar s 2C �' Massachusetts State Building Code, 70 Cr nr nUrr IN_o Building Permit Application To Construct,Repair,Re r"2N,r� o crtoNs 060 ONE-OR TWO-FAMILY DWELLING /�/J This Section For Official Use Only Building Permit Number: ��of 3 '' /1/ 7 Date Applied: BuildingOfficial(Print Name) ( Signature -- g SECTION 1: SITE INFORMATION 1.1 Property Address: 1.2 Assessors Map&Parcel Numbers 160 NORTH MAPLE., FLORENCE, MA /? o?/7 1.1 a Is this an accepted street?yes no Map Number Parcel Number 1.3 Zoning Information: 1.4 Property Dimensions: Zoning District Proposed Use Lot Area(sq ft) Frontage(ft) 1.5 Building Setbacks(ft) Front Yard Side Yards Rear Yard Required Provided Required Provided Required Provided NOT APPLICABLE 1.6 Water Supply: (M.G.L c.40,§54) 1.7 Flood Zone Information: 1.8 Sewage Disposal System: Public II Private 0 Zone: _ Outside Flood Zone? Municipal® On site disposal system 0 Check if yes❑ SECTION 2: PROPERTY OWNERSHIP' 2.1 Owner'of Record: RICHARD GERSTEIN FLORENCE, MA Name(Print) City,State,ZIP 160 N. MAPLE ST. 413-537-7500 drrickg@gmail.com No.and Street Telephone Email Address SECTION 3: DESCRIPTION OF PROPOSED WORK'(check all that apply) New Construction 0 Existing Building❑ Owner-Occupied 0 Repairs(s) 0 Alteration(s) ❑ Addition *3 Demolition 0 Accessory Bldg. 0 Number of Units Other ❑ Specify: Brief Description of Proposed Work2:The contractor will convert the existing 10' x 10'closet into bedroom space, 10'x 20'w/full height ceilings. SECTION 4:ESTIMATED CONSTRUCTION COSTS Item Estimated Costs: Official Use Only (Labor and Materials) 1.Building $ 51,273.00 1. Building Permit Fee: $ Indicate how fee is determined: 0 Standard City/Town Application Fee 2.Electrical $ 2,500.00 ❑Total Project Costa(Item 6)x multiplier x 3.Plumbing $ 0.00 2. Other Fees: $ 4.Mechanical (HVAC) $ 0.00 List: 5. Mechanical (Fire $ Suppression) 0.00 Total All Fees: $ Check No)pf Check Amout4,14 1 Cash Amount: 6.Total Project Cost: $ 53,773.00tS1 Paid in Full ❑ Outstanding Balance Due: SECTION 5: CONSTRUCTION SERVICES 5.1 Construction Supervisor License(CSL) 102746 04/02/2025 JASON T.WOLFE License Number Expiration Date Name of CSL Holder List CSL Type(see below) U PO BOX 187 No.and Street Type Description FEEDING HILLS,MA 01030 U Unrestricted(Buildings up to 35,000 Cu.ft.) R Restricted 18t2 Family Dwelling City/Town,State,ZIP M Masonry RC Roofing Covering WS Window and Siding 413-777-3146 MOSTBUILDERS@GMAIL.COM SF Solid Fuel Burning Appliances I Insulation Telephone Email address _ D Demolition 5.2 Registered Home Improvement Contractor(HIC) 206112 7-31-2024 MOST BUILDERS AND GENERAL CONTRACTING,INC. MC Registration Number Expiration Date HIC Company Name or HIC Registrant Name PO BOX 187 MOSTBUILDERS@GMAIL.COM No.and Street Email address FEEDING HILLS,MA 01030 413-777-3146 City/Town,State,ZIP Telephone SECTION 6:WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c.152.§ 25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the Issuance of the building permit. Signed Affidavit Attached? Yes No ❑ SECTION 7a:OWNER AUTHORIZATION TO BE COMPLETED WHEN OWNER'S AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT I,as Owner of the subject property,hereby authorize Jason T.Wolfe to act on my behalf,in all matters relative to work authorized by this building permit application. RICHARD GERSTEIN 10/16/2023 Print Owner's Name(Electronic Signature) Date SECTION 7b: OWNER'OR AUTHORIZED AGENT DECLARATION By entering my name below,I hereby attest under the pains and penalties of perjury that all of the information contained in this application is true and accurate to the best of my knowledge and understanding. 10/16/2023 Print Owner's or Authorized Agent's Name(Electronic Signature) Date NOTES: I. An Owner who obtains a building permit to do his/her own work,or an owner who hires an unregistered contractor (not registered in the Home Improvement Contractor(HIC)Program),will not have access to the arbitration program or guaranty fund under M.G.L.c. 142A.Other important information on the HIC Program can be found at www.mass.gov/oca Information on the Construction Supervisor License can be found at www.mass.gov/dps 2. When substantial work is planned,provide the information below: Total floor area(sq.ft.) (including garage,finished basement/attics,decks or porch) Gross living area(sq.ft.) +200 SOFT Habitable room count Number of fireplaces Number of bedrooms Number of bathrooms Number of half/baths Type of heating system EXISTING Number of decks/porches Type of cooling system EXISTING Enclosed Open 3. "Total Project Square Footage"may be substituted for"Total Project Cost" City of Northampton Massachusetts w÷ • rl DEPARTMENT OF BUILDING INSPECTIONS S w• ; . 212 Main Street • Municipal Building N L N'1 Northampton, MA 01060 SF/y, 1,-)‘� CONSTRUCTION DEBRIS AFFIDAVIT (FOR ALL DEMOLITION AND RENOVATION PROJECTS) In accordance of the provisions of MGL c 40, S54, a condition of Building Permit Number is that all debris resulting from this work shall be disposed of in a properly licensed waste disposal facility, as defined by MGL c 111, S 150A. The debris will be disposed of in: USA HAULING AND RECYCLING Location of Facility: WEST SPRINGFIELD, MA The debris will be transported by: Name of Hauler: USA HAULING AND RECYCLING 10/16/2023 Signature of Applicant: Date: .� The Commonwealth ofMassachusetts r L'-. Department of Industrial Accidents ti ;= s Jap_ 1 Congress Street,Suite 100 1111= Boston,MA 02114-2017 www.mass.gov/dia Workers'Compensation Insurance Affidavit:Builders/Contractors/Electricians/Plumbers. TO BE FILED WITH THE PERMITTING AUTHORITY. Applicant Information Please Print Legibly Name(Business/Organization/Individual): MOST BUILDERS AND GENERAL CONTRACTING, INC. Address: PO BOX 187 City/State/Zip: FEEDING HILLS, MA 01030 Phone#: 413-777-3146 Are you an employer?Check the appropriate box: Type of project(required): 1.®tam a employer with 2 employees(full and/or part•time).* 7. ❑New construction 2.❑I am a sole proprietor or partnership and have no employees working for me in 8. 0 Remodeling any capacity.[No workers'comp.insurance required.] 9. ❑Demolition 3.0[am a homeowner doing all work myself.[No workers'comp.insurance required.]t 10®Building addition CO I am a homeowner and will be hiring contractors to conduct all work on my property. 1 will ensure that all contractors either have workers'compensation insurance or are sole 11.0 Electrical repairs or additions proprietors with no employees. 12.0 Plumbing repairs or additions 5.0 lam a general contractor and I have hired the sub-contractors listed on the attached sheet. 13.0 Roof repairs These sub-contractors have employees and have workers'comp.insurance.] 6.0 We are a corporation and its officers have exercised their right of exemption per MOL c. 14.Q Other 152,§1(4),and we have no employees.[No workers'comp.insurance required.] *Any applicant that checks box#1 must also till out the section below showing their workers'compensation policy information. t Homeowners who submit this affidavit indicating they are doing all work and then hire outside contractors must submit a new affidavit indicating such. !Contractors that check this box must attached an additional sheet showing the name of the sub-contractors and state whether or not those entities have employees. If the sub-contractors have employees,they must provide their workers'comp.policy number. I am an employer that is providing workers'compensation insurance for my employees. Below is the policy and fob site information. Insurance Company Name: LIBERTY MUTUAL INSURANCE Policy#or Self-ins.Lie.#: WC2-33S-B2101 H-013 Expiration Date: NOV 2023 Job Site Address: 160 North Maple City/state/ziiEl Oren ce, MA Attach a copy of the workers'compensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under MGL c. 152,§25A is a criminal violation punishable by a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of a STOP WORK ORDER and a fine of up to$250.00 a day against the violator.A copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. _ I do hereby certify under the pains and penalties of perjury that the information provided above is true and correct. Signature: ,e,. _ Date: 10/16/2023 Phone#: 413-777-3146 Official use only. Do not write in this area,to be completed by city or town official. City or Town: Pernitt/License# Issuing Authority(circle one): 1.Board of Health 2.Building Department 3.City/Town Clerk 4.Electrical Inspector 5.Plumbing Inspector 6.Other Contact Person: Phone#: Residential Property Contract This form complies with professional standards currently in effect. ■�:.T MOST BUILDERS AND GENERAL CONTRACTING,INC. DATE OF CONTRACT: CSL 102746 MA/HIC 171929/CT 0639294 PO BOX 187 10/03/2023 MEIN FEEDING HILLS, MA 01030 Phone 413.777.3146 NAME RICHARD GERSTEIN and 1 ) BUYER/ PROJECT ADDRESS 160 N. MAPLE ST., FLORENCE P411.ic�N- 37-7500 OWNER ALTERNATE ADDRESS (NAM) PHONE DESCRIPTION OF THE PROJECT: *MOST Builders and General Contracting will provide all services, materials and labor for the items listed below. The contractor will be required to meet all local and state building codes for the renovations indicated on the supplied drawings dated 09/26/2023:2ND FLR ADDITION. Work provided by the contractor shall include the furnishing of all materials, labor, equipment and supplies and the performance of all operations to provide complete working systems, and construction, in general, to include the following items as indicated: 1. DEMOLITION: The contractor will be responsible for the demolition of all materials that need to be removed for the installation of new work, including siding, roofing, framing, etc. The contractor will be responsible for the removal of all debris. The contractor has included (1) 30 yard dumpster for all debris. 2. FRAMING: The contractor will supply and install the following: -2 x 10 floor joist @ 16" O.C. w/a/T&G subfloor -2 x 6 wall framing© 16" O.C. -2 x 12 rafters @ 16" O.C. w/2 x 6 ceiling joist and 1/2" CDX roof sheathing 3. INSULATION: The contractor will supply and install the following: -R21 batt insulation for exterior walls -R49 ceiling insulation -R3.85 continuous exterior foam w/foil face on exterior 4. WINDOWS AND DOORS: The contractor will supply and install the following: -(4) United Windows,Vinyl new construction double hung units to meet all energy star requirements, exterior trim to match existing, interior to match existing, Location: Bedroom -(1)Velux venting skylight, 21"x 45" —shades not included, Location: Bathroom -No doors required 5. GYP. BOARD: Supply and install'/"drywall, supply and install(3) coats of joint compound, sand and provide uniformly smooth surface. Prime all new drywall. 6. FLOORING: The contractor will supply and install flooring, TBD. The contractor has allotted $7.50 per sqft for 200 sqft of flooring to be selected by the homeowner. 7. ELECTRICAL: The contractor will supply and install the following: www.mostbullders.com Page 1 of 5 INTIAL /C� OUTLETS 5 SWITCHES 1 0—Existing to SMOKE DETECTOR remain CEILING FIXTURE(supplied by owner) 2 8. PLUMBING: NA 9. HEATING: The existing mini-split head will be relocated by owner's contractor, NIC. 10. FINISH CARPENTERY: The contractor will be responsible for matching the existing trim on the interior of the bedroom addition. 11. ROOFING:The contractor will supply and install Tamko Heritage architectural shingles. All manufacturer's installation instructions shall be followed for Lifetime warranty. Match existing color. 12. SIDING: The contractor will be required to supply and install all materials to match the existing home. All new siding and trim installed will be factory primes and finished painted after installation to match the existing home. 1. PERMITS/MISC/DRAWINGS: The buyer will allow free access to work areas for workers and vehicles and will allow areas for the storage of materials and debris.Driveways will be kept clear for the movement of vehicles during work hours. MOST Builders will make reasonable efforts to protect driveways,lawns, shrubs,and other vegetation but are not liable for any damages that may occur due to construction and vehicle traffic. MOST Builders also agree to keep the worksite clean and orderly and to remove all debris as needed during the hours of work to maintain work conditions that do not cause health or safety hazards. The contractor will provide all construction drawings and plot plans to the town to obtain a building permit. The contractor will obtain all necessary building permits,all fees are included. MISCELLANEOUS CONDITIONS: The contractor will provide a portable toilet for the duration of the project if the homeowner requests at a rate of$250 per month. All building and electrical permit fees are included. Fire inspection fee is included. ADDITIONAL TERMS: LATE PAYMENTS:Payments not made in a timely fashion shall incur daily interest at the rate of 1 1/2%from the day the payment is due per month. If the buyer fails to pay the builder within seven days of the date the payment is due,through no fault of the builder,the builder may stop work and may keep the job idle until such time as payments that are due to the builder are paid.Tf the builder chooses not to stop work after a payment delay,this is not to be construed as a waiver of his rights to stop work if future payments are delayed.All attorney fees incurred by the builder to collect sums owed by the buyer shall be paid by the buyer,together with interest at the rate of 18%. www.mostbullders.com Page 2 of 5 INTIAL /C� CHANGE ORDERS:The buyer may order changes in the work within the terms of this contract,but only by a prior written order and agreement with the builder that states the changes to the contract,the amount of any additional cost,and the additional number of days to be added to the contract completion date.Any of the buyers may sign the change order and that signature will be binding upon all of the buyers.The buyers hereby agree to make all requests for change orders to the builder,and not to issue instructions to,or otherwise negotiate for additional or changed work specifications with,the builder's employees or subcontractors. INSURANCE AND RISK MANAGEMENT: The builder shall obtain all workers'compensation,commercial general liability insurance and comprehensive liability insurance necessary to protect builder from claims for damages due to bodily injury,including death,and for damages to property that may arise out of and during operations under this contract. ACCESS TO SITE:The buyer shall have access to the property and the right to inspect the work in the presence of the builder.Tf the buyer enters the property during the course of construction without the permission of the builder, he does so at his own risk,and the buyer hereby releases the builder and does hereby hold the builder harmless from any and all claims for injury or damage to his person or property,and to the person or property of any person accompanying the buyer. CONTRACTOR ACCESS TO WORKSITE:The buyer will allow free access to work areas for workers and vehicles and will allow areas for the storage of materials and debris.Driveways will be kept clear for the movement of vehicles during work hours. MOST Builders will make reasonable efforts to protect driveways,lawns,shrubs, and other vegetation but is not liable for any damages that may occur due to construction and vehicle traffic. MOST Builders also agrees to keep the worksite clean and orderly and to remove all debris as needed during the hours of work in order to maintain work conditions that do not cause health or safety hazards. UTILITIES:The buyer shall provide and maintain water and electrical service,connect permanent electrical service,gas service or oil service,whichever is applicable,and tanks and lines to the building constructed under this Agreement after an acceptable cover inspection has been completed,and prior to the installation of any inside wall cover.The buyer maintain,connect sewage disposal and water lines to said building prior to the start of construction,and at all times maintain sewage disposal and water lines during construction as applicable. The buyer shall permit MOST Builders to use,at no cost,any electrical power and water use necessary to carry out and complete the work INSPECTION,ACCEPTANCE,FINAL PAYMENT: At the final inspection,the buyer will give the builder a signed and dated list that identifies any alleged deficiencies in the quality of the work or materials.The builder shall correct any items on the buyer's list that are,in the good faith judgment of the builder,deficient in the quality of the work and/or materials according to the standards of construction in the area in which the house is built.The builder shall correct those defects within a reasonable period of time. After the defects have been corrected according to the standards of construction in the area in which the house is built,the buyer shall sign a certificate of acceptance acknowledging that the defects on the buyer's list have been corrected according to the standards of this contract. www.mostbullders.com Page 3 of 5 //JJ INTIAL /��r The builder shall provide the buyer with an affidavit stating that all materials and services for which a lien could be filed have been paid,or an affidavit identifying what services and materials for which a lien could be filed have not been paid,and swearing that such amounts will be paid from the proceeds of the final payment. Occupancy will be granted to the buyer when the buyer makes a final inspection of the home,signs a certificate of acceptance,and makes the final payment. WARRANTIES:All warranties are limited to the implied warranties of habitability and workmanlike construction and are limited to a period of one year from the date of the issuance of a certificate of occupancy by the local building code enforcement authority.This limited warranty is the only express warranty provided by the builder. OCABR REQUIREMENTS: 1. All home improvement contractors and subcontractors shall be registered and that any inquiries about a contractor or subcontractor relating to a registration should be directed to: Office of Consumer Affairs and Business Regulation Ten Park Plaza,Suite 5170 Boston,MA 02116 Phone:(617)973-8700 2.The contractor's registration number must be on the first page of the contract. 3.Homeowner are entitled to a three-day cancellation rights under MGL c 93 s 48;MGL c 140D s 10 or MGL c 255D s 14 as may be applicable. 4. All warranties on the owner's rights under the provisions of and MGL c. 142A. 5. A lien or security interest may be placed on the residence as a consequence of nonpayment for this contract. DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES. www.mostbullders.com Page 4 of s INTIAL� TIME FOR STARTING AND COMPLETION: The work by the contractor pursuant to this agreement shall be commenced within ten (10)working days from this date 11/06/2023 and shall be substantially completed within Forty-five (45)working days or approximately on (date) 01/16/2023 . This schedule is subject to change due to inclement weather and material acquisition delays. PAYMENT:The Owner agrees to pay the Contractor a total payment of$53,773.00 The payment schedule will be(1)down payment of$ 6,000.00 . The owner agrees to pay the remaining amount to the contractor as work progresses for the invoiced amount based on percentage of work completed. This contract shall become effective on the date it is signed by both parties. We,the undersigned,have read,understood,and agree to each of the provisions of this contract and hereby acknowledge receipt of a copy of this contract. 10/10/2023 RICHARD GERSTEIN,owner D;1TL 10/3/2023 JASON WOLFE,contractor DATE www.mostbullders.com Page 5 of 5 INTIAL 2/5/24, 11:46 AM 160 North Maple Assessor Map copy(1).png 17A-22/-001 17A-104001 0166 W tar 17A-220-001 17A-220-001 S F 0.40$ ITT rn W J a 17A-195401 0-103f. = 173 h— Q.' 0 z 17A-229-001 0.320. 173 17A-2 -001 KIMBALL0.437 STREET }M 17A430-001 0.199 111 17ft 17A-2111-001 0261 1600 Addition 14 ft 17A-166-001 17A-231-001 10ft Otr 0.297 97 17A-217-001 0.333 1S9 W 17A432-001 W 0.323 0S (q 17A-196-001 17A-216-001 W 0219 0.449 iti1 154 d CC 0 17A-197-001 0 209 rip 17A-233-001 0.330 U 17A-215-001 0656 140 POWELL S 17A-234001 r TREE T 0317 17 rpre d Baw 1 AM1� 1/11/2024 11:03:24 AM I .i ! ; ' 4 Scale. 1"=50' aa�>t 160. Scale is approximate The information depicted on this map is for planning purposes only. It is not adequate for legal boundary definition.regulatory interpretation.or parcel-level analyses. https://mail.google.com/mail/u/1/#inbox/FMfcgzGxRdsZXTctKtfPbhGq NCgmdwpr?projector=l&messagePartld=0.1 1/2 General Notes —NEW EXTERIOR WALLS: 2"X 6'STUDS @116'O.C.TO ACCOMODATE NEW WINDOW AND DOOR LAYOUT 7,46'ZIP PLYWOOD SHEATHING W/TAPED JOINTS R19 FIBERGLASS INSULATION W/POLY VAPOR BARRIER 1'RMAX FOAM INSULATION R5 W/TAPED JOINTS EXT.:4'SPRUCE LAP SIDING TO MATCH EXISITNG INT.:4'GYP.BOARD DEMOLISH EXISTING ROOF GABLE SOFFIT 2 X 12 RIDGE BEAM CONTINUOUS RIDGE VENT 2 X 12 RAFTERS C 16'O.C. 19'-10Y' ARCHITECTURAL SHINGLES TO MATCH EXISTING i(y'CDX ROOF SHEATHING / / ARCHITECTURAL SHINGLES TO MATCH EXISTING 1 2 X 4 COLLAR TIES @ 48'O.C. i . EXISTING ROOF LINE BEYOND PROVIDE 2'X 2'ATTIC ACCESS E R60 CELLULOSE INSULATION 2,--- t 1 J Li4C l I J'T04C 1 2 X 8 CEILING JOIST 16'O.C. NEW EXTERIOR WALLS:2'X 6'STUDS C 16'O.C.TO a ACCOMODATE NEW WINDOW AND DOOR LAYOUT i(s'ZIP PLYWOOD SHEATHING W/TAPED JOINTS — R19 FIBERGLASS INSULATION W/POLY VAPOR BARRIER . 1'RMAX FOAM INSULATION RS W/TAPED JOINTS s' BEDROOMEXT.:4'SPRUCE LAP SIDING TO MATCH EXISRNG 0 — + wra H1 X B PRIMED EXT.GRADE TRIM — V.0"11'4J" 1'-0"/1'-0" 1 X 4 PRIMED EXT.GRADE TRIM INT.:1'GYP.BOARD -s: rn Iu-H-ICFI.AIAI�F;rwS�IACONTINUOUS GUTTER AND DOWNSPOUT PANT TO MATCH EXISITING L — — 1 /Nil' I 1 1 1 L--- , ‘ ! 2X 4 NTFRIOR PARTITION CO li"nC o LI }GYP.BOARD uJ FXISTNf,REICIF I INF TO RF fIFUni IU-IFII TRIM TO MATCH EXISTING EXISTIN ' %'OOM a r F ..Arnwoo'rle. L.II 7 Y MI Fl OOR JOIST 0 1fi"Ft f NFU I FXISTINE;Wl4T)C)W .e ttllrvGHUGF- Y'i T&G SUBFLOOR I BATHROOM X PREFINISHED HARDWOOD FLOORING t\ I -'INF 111 ar CEIJAG HE151T HOMEOWNER TO COORDINATE \ REMOVAL AND REINSTALLATION OF EXISTING SOLAR PANEL / W 'w T G OF FFFF"'' I Q' TO REMAIN — \� J— W W U a z � . _ - EXISTING BEDROOM ¢ O -CT R. x U_ w AL 7 11 I I J No. Revision/Issue Date F.*w Aaenis MOST BUILDERS AND GENERAL CONTRACTING ROOF PLAN SECOND FLR. FRAMING AGAWAM,MA NEW SECOND FLR. LAYOUTersED SCALE:1/4" = 1'-0" SCALE: 1/4" = 1'-0" A-1 SCALE: 1/4" = 1'-0" a.i.A No.sad Aer.•• GENERAL NOTES: B i `E D R �MI 1.CONTRACTOR TO VERIFY ALL DIMENSIONS PRIOR TO CONSTRUCTION.DO NOT SCALE THE PRINTS. D D I ITO O I O 1 V WRITTEN DIMENSIONS TO TAKE PRECEDENCE OVER SCALED DIMENSIONS. 2.CONTRACTOR TO PATCH ALL AREAS AROUND DEMOLITION TO MATCH EXISTING.INCLUDES WALLS, FLOORS,CEIUNGS,TRIM,ETC. 3.EXISTING FRAMING,FOUNDATION,AND SOIL BEARING CAPACITY IS UNKNOWN AS Tf IS CONCEALED BY Pm). ineal EXISITNG FINISHES. PRIOR TO BEGINNING ANY WORK,THE CONTRACTOR SHALL VERIFY ALL CONDITIONS AND REPORT ANY DISCREPANCIES TO THE HOMEOWNER BEFORE PROCEEDING WITH WORK ABBREVIATIONS: 1 0/1 6/2023 A2 E.T.R. EXISTING TO REMAIN sew P.T. PRESSURE TREATED C.O. CASED OPENING D.H. DOUBLE HUNG General Notes DEMOLISH EXISTING ROOF FRAMING AND ALL INTERIOR FINISHES _ e,/ HOMEOWNER TO COORDINATE REMOVAL OF EXISTING HEAT PUMP l// VL TO ALLOW FOR SCHEDULED WORK DEMOLISH EXISTING ROOF FRAMING SHORE EXISTING CEILING FRAMING AND PROTECT MUDROOM EXISTING FINISHES AS NEEDED -I" _ = DEMOLISH EXISTING INTERIOR PARTITION _ BATH L I I • _.i.T 1. - CLOSET I I KITCHEN - I E T F I i I 1 ttilI :- ---37 ' r _ . . _ I —13— o 0 EXISTING BEDROOM Ct , BATHROOM DINING ROOM _ BASEMENT -UP.StO (Tp 7 I_ J I �_ _..e_ Z a EXISTING BEDROOM ' S, O LIVING ROOM S, Q ^ , ._, .CTR _ F-+ Z Pe � Q � o ° a 7 �� v w / ". PORCH - I i No. Revision/Issue Date MO S T BUILDERS AND GENERAL CONTRACTING AGAWAM.MA 3� SECOND FLOOR/ DEMOLITION PLAN FIRST FLOOR wxm1777-374ti CD BASEMENT LEVEL w ° °'aers°°mA-1 SCALE:1/4" = 1'-0" CD SCALE: 1/4" = 1'-0" SCALE:1/4" = 1' 0" Project 11....,Memo BEDROOM GENERAL NOTES: 1.CONTRACTOR TO VERIFY ALL DIMENSIONS PRIOR TO CONSTRUCTION.DO NOT SCALE THE PRINTS. LIFE SAFETY DEVICES ADDITION WRITTEN DIMENSIONS TO TAKE PRECEDENCE OVER SCALED DIMENSIONS. 2.CONTRACTOR TO PATCH ALL AREAS AROUND DEMOLITION TO MATCH EXISTING.INCLUDES WALLS. FLOORS,CEILINGS,TRIM,ETC. H 3.EXISTING FRAMING,FOUNDATION,AND SOIL BEARING CAPACITY IS UNKNOWN AS IT IS CONCEALED BY E.T.R INTERCONNECTED HEAT DETECTOR AS INDICATED EXISITNG FINISHES. PRIOR TO BEGINNING ANY WORK,THE CONTRACTOR SHALL VERIFY ALL CONDITIONS 0 """°` Shal AND REPORT ANY DISCREPANCIES TO THE HOMEOWNER BEFORE PROCEEDING WITH WORK E.T.R. INTERCONNECTED SMOKE AND CO DETECTOR AS os. /� w S/CO INDICATED H_I ABBREVIATIONS: O 10/16/2023 E.T.R. EXISTING TO REMAIN Sao P.T. PRESSURE TREATED E.T.R.INTERCONNECTED SMOKE DETECTOR AS C.O. CASED OPENING S D.H. DOUBLE HUNG 0 INDICATED