Loading...
38D-044 (4) BP-2023-1506 28 HARLOW AVE COMMONWEALTH OF MASSACHUSETTS Map:Block:Lot: 38D-044-001 CITY OF NORTHAMPTON Permit: Exterior Res PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL c.142A) BUILDING PERMIT Permit# BP-2023-1506 PERMISSION IS HEREBY GRANTED TO: Project# ROOF 2023 Contractor: License: NEXTGEN CONSTRUCTION Est. Cost: 18453 SERVICES INC 098654 Const.Class: Exp.Date: 08/19/2025 Use Group: Owner: ROBERT LOCK Lot Size (sq.ft.) Zoning: URB Applicant: NEXTGEN CONSTRUCTION SERVICES INC Applicant Address Phone: Insurance: 1 ARCH RD (413)579-5798 WC-9098917 WESTFIELD, MA 01085 ISSUED ON: 10/25/2023 TO PERFORM THE FOLLOWING WORK: STRIP AND REROOF POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector Underground: Service: Meter: Footings: Rough: Rough: House # Foundation: Final: Final: Final: Rough Frame: Gas: Fire Department Driveway Final: Fireplace/Chimney: Rough: Oil: Insulation: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF ANY OF ITS RULES AND REGULATIONS. Signature: •, t(44A„,._, ."2 cs, • Fees Paid: $40.00 212 Main Street,Phone(413)587-1240,Fax: (413)587-1272 Office of the Building Commissioner The Commonwealth of Massac sett: I Board of Building Regulations and tan rdsOCT 2 4 2023 OR Massachusetts State Building Code, 780 MR I IPALITY _ SE Building Permit Application To Construct,Repair Retiiiwate)Qri g ,, • evis Mar 2011 One-or Two-FamilyDwell: r"'?- AS1'T ON.1." E oc o 1A 0780 This Section For Official Use Only t Buildingermit Number: 174-2:-/.�'0� Date Applied: ��/Y�,s /7 l4-Zy-Zo23 Building Official(Print Name) ignature Date SECTION 1:SITE INFORMATION 1.1 Property Address: 1.2 Assessors Map& Parcel Numbers 28 Harlow Ave Li a Is this an accepted street?yes no Map Number Parcel Number 1.3 Zoning Information: 1.4 Property Dimensions: Zoning District Proposed Use Lot Area(sq ft) Frontage(ft) 1.5 Building Setbacks(ft) Front Yard Side Yards Rear Yard Required Provided Required Provided Required Provided 1.6 Water Supply:(M.G.L c.40,§54) 1.7 Flood Zone Information: 1.8 Sewage Disposal System: Public 0 Private CI Municipal_ Outside Flood Zone? Municipal❑ On site disposal system 0 Check if yes❑ SECTION 2: PROPERTY OWNERSHIP' 2.1 Owner'of Record: Robert Lock Northampton,MA.oiobo Name(Print) - City,State,ZIP 28 Harlow Ave 617-571-8204 lock.robert@gmail.com No.and Street Telephone Email Address SECTION 3:DESCRIPTION OF PROPOSED WORK2(check all that apply) New Construction 0 Existing Building❑ Owner-Occupied 0 Repairs(s) 0 Alteration(s) 0 Addition 0 Demolition 0 Accessory Bldg.❑ Number of Units Other 0 Specify: Brief Description of Proposed Work': Remove and replace Roof to code and manufacturers specifications. Please see estimate for details. SECTION 4: ESTIMATED CONSTRUCTION COSTS Item Estimated Costs: Official Use Only (Labor and Materials) 1.Building $ 18453.75 1. Building Permit Fee:$ Indicate how fee is determined: 2.Electrical $ ❑Standard City/Town Application Fee ❑Total Project Cost (Item 6)x multiplier x 3.Plumbing $ 2. Other Fees: $ 4.Mechanical (HVAC) $ List: 5. Mechanical (Fire $ Total All Fee Suppression) A Q Check No. heck Amount: Cash Amount: 6.Total Project Cost: $ 18453.75 ❑Paid in Full 0 Outstanding Balance Due: SECTION 5: CONSTRUCTION SERVICES 5.1 Construction Supervisor License(CSL) CS-o98654 08/19/2025 Rene Gauthier License Number Expiration Date Name of CSL Holder List CSL Type(see below) U 1 Arch Road Suite it No.and Street Type Description Westfield,MA 01o85 U Unrestricted(Buildings up to 35,000 cu.ft.) R Restricted 1&2 Family Dwelling City/Town,State,ZIP M Masonry RC Roofing Covering WS Window and Siding SF Solid Fuel Burning Appliances 413-579-5798 info@nextgen4i3.net I Insulation Telephone Email address D Demolition 5.2 Registered Home Improvement Contractor(HIC) 196063 06/27/2025 NextGen Construction Service Inc. HIC Registration Number Expiration Date HIC Company Name or HIC Registrant Name 1 Arch Road Suite it info@nextgen413.net No.and Street Email address Westfield,MA oto85 413-579-5798 City/Town,State,ZIP Telephone SECTION 6:WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c. 152.§ 25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the Issuance of the building permit. Signed Affidavit Attached? Yes ® No 0 SECTION 7a:OWNER AUTHORIZATION TO BE COMPLETED WHEN OWNER'S AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT I,as Owner of the subject property,hereby authorize Rene Gauthier to act on my behalf,in all matters relative to work authorized by this building permit application. Rene Gauthier `� 10/19/23 Print Owner's Name(Electronic Signature) Date SECTION 7b:OWNER'OR AUTHORIZED AGENT DECLARATION By entering my name below,I hereby attest under the pains and penalties of perjury that all of the information contained in this application is true and accurate to the best of my knowledge and understanding. Rene Gauthier ,ti�� � 10/19/23 Print Owner's or Authorized (Elee+C onic Name Agent'sSignature)Si ature) Date NOTES: 1. An Owner who obtains a building permit to do his/her own work,or an owner who hires an unregistered contractor (not registered in the Home Improvement Contractor(HIC)Program),will not have access to the arbitration program or guaranty fund under M.G.L.c. 142A.Other important information on the HIC Program can be found at www.mass.gov/oca Information on the Construction Supervisor License can be found at www.mass.gov/dps 2. When substantial work is planned,provide the information below: Total floor area(sq.ft.) (including garage,finished basement/attics,decks or porch) Gross living area(sq.ft.) Habitable room count Number of fireplaces Number of bedrooms Number of bathrooms Number of half/baths Type of heating system Number of decks/porches Type of cooling system Enclosed Open 3. "Total Project Square Footage"may be substituted for"Total Project Cost" _ City of Northampton �oaY, ', ,,,,.""".SI C C' `; Massachusetts �,,' C. `ie C. I $ 1.t4 ! DEPARTMENT OF BUILDING INSPECTIONS y:, +� �. 212 Main Street • Municipal Building Y>�` Northampton, MA 01060 s kii'i5 o CONSTRUCTION DEBRIS AFFIDAVIT (FOR ALL DEMOLITION AND RENOVATION PROJECTS) In accordance of the provisions of MGL c 40, S54, a condition of Building Permit Number is that all debris resulting from this work shall be disposed of in a properly licensed waste disposal facility, as defined by MGL c 111, S 150A. The debris will be disposed of in: Location of Facility: Casella Waste 686 Main Street Holyoke,MAoto40 The debris will be transported by: Name of Hauler: NextGen Construction Service Inc. Signature of Applicant: g,,c / Date: 10/19/23 The Commonwealth of Massachusetts h!—±--:4,_!r Department of Industrial Accidents IIn'- ; 1 Congress Street.Suite 100 =i = Boston,MA 02114-2017 �:;,_� ��,, wwwmass.gov/dia Workers'Compensation Insurance Affidavit:Builders!ContractorstEIectriciansiPlumberr. TO BE FILED WITH THE PERMUTING AUTHORITI_ lttltlicant Information Please Print Ixeibh Name It3u.lnt,organi dimf ndividuaIENextGen Construction Service Inc. Address: r Arch Road Suite ii City/State/Zip: Westfield,MA 01085 Phone#: 413-579-5798 Arc i nu an employee Cheek dha aortae hos: Type of project(required): 1.0 I art a employee'with ..__ 12 a ►yee%thin and'u part-trend.• 7. 0 New construction 20 I am a mole propsietie orparinet.hep and hat,no cmpl yce%wirknntc fit nee in B.u%ut n Remodeling, am capacity.1\o widcrame 'cram monied..! y 9. ❑Demolition .#.Q 1 am a honttrwrrct Jinni;all wit&eny..lf. M'sinkrn...comp.insurance lemur cd.l' 4.01 am a trtntarvinr.i and will be hit*atom maim.to conduct all wok on my property. I will 10 Q Building addition ensure that all conua.ton titter hail'wrwkers"cin►rpennsanioa ierYranrx a•err mile I I.rj Electrical repairs or additions proprietor.with no cIiv..s. 12.0 Plumbing,repairs or additions 30 l am a pineal contractor and I hate hued the mb"contza s's%listed tar the attached sheet 13.1 Roof repairs These mb-contracksn hate employee%and lime stake&comp.nsuraocc_: 14.J Other 6.Q Ws:arc aertspnratio n anal eta officer%hat a esvrrxd then right of exemption per Mtil_c_ -- ________ 1$2,I I(4),sod we ha%c no.inphtyce%_l Ni worker"comp.inwrance required" °Any applicant that cheek%his a I mud also(Il out tlr•section twliw%horsing theft w or kers"con►perwatatn policy idasurninn. '4'i knows um.r%who%Junk this affidavit inificatios they arc doing all soli and then hue,art-otk.rmrruetura ma aaltatit a anew'at1►da%it indicating such. t r.ntractors that check this.hot ram ran and a.addauntal,beet%how rnr the name of the mil,ceammearraand gift trkelk!ar sot tame names have enrplO_vee, if the satx ei itmetrxs have employees.dory must mos Me Men sinker."coup.policy number. I am an employer that is providing workers'compensation insurance for my employes. Below Is the policy and job site information_ Insurancet'otnpan) Name: Alera group Inc Polley#t or Self-ins.Lie.437366658"f or Expiration Date:o7/14/2024 Job Site Address 28 Harlow Ave City,.Statr'Zip:Northampton,MA.oio6o Attach a copy of the workers'compensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under MGL c. 152,§25A is a criminal violation punishable by a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of a STOP WORK ORDER and a fine of up to$250.00 a day against the violator.A copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certi fc under the pains and penalties of perjury that the information provider/above is true and correct Silmnitur: ,c-,fie.)�/ Date: 10/19/23 Phone#: 413-579-5798 r Official use only. Do not write in this area,to be completed hi city or town official r ' ('its or Town: Permit/license Issuing Authority (circle one): I.Board of Health 2.Building Department 3.('ityllosn Clerk 4. Electrical Inspector 5. Plumbing Inspector ' 6.Other 4 (Contact Person: Phone#: I ---- ._�......_..._,..a ACo CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) (`.---- 07/14/2023 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Stephanie Herring NAME: Alera Group,Inc. (AI CO,NNo.Est): (413)586-0111 FAX No): (413)586-6481 Webber&Grinnell Division E-MAIL sherring©webberandgrinnell.com ADDRESS: 8 North King Street INSURER(S)AFFORDING COVERAGE NAIC# Northampton MA 01060 INSURER A: State Auto Insurance Companies 14923 INSURED INSURER B: Applied Underwriters NextGen Construction Service,Inc INSURER C: 1 Arch Road INSURER D: Suite 11 INSURER E: Westfield MA 01085 INSURER F: COVERAGES CERTIFICATE NUMBER: Exp 7/2024 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER (MMIDD/YYYY) (MMIDDIYYYY) LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 DAMAGE CLAIMS-MADE XI OCCUR PREMSESO(EaENTED occurrence) $ 500,000 MED EXP(Any one person) $ 15,000 A 10180642CP 07/14/2023 07/14/2024 PERSONAL&ADV INJURY $ 1,000,000 GEN'LAGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 PRO- 2,0 ,0 0000 POLICY JECT LOC PRODUCTS-COMP/OPAGG 8 OTHER: Employee Benefits $ 1,000,000 AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) ANY AUTO BODILY INJURY(Per person) $ A OWNED X SCHEDULED BAP248470200 07/14/2023 07/14/2024 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X HIRED X NON-OWNED PROPERTY DAMAGE $ _ AUTOS ONLY _AUTOS ONLY (Per accident) PIP-Basic $ 8,000 UMBRELLA LIAB 1,000,000 X OCCUR EACH OCCURRENCE $ A EXCESS LIAB CLAIMS-MADE 10180646CU 07/14/2023 07/14/2024 AGGREGATE $ 1,000,000 DED RETENTION$ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER Y/N 1,000,000 B ANY PROPRIETOR/PARTNER/EXECUTIVE [1 N I A 373666580101 07/14/2023 07/14/2024 E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? I I (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under 1000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ , DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space is required) Rene Gauthier is Excluded from Workers'Compensation coverage. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN "`Evidence of Insurance*** ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE 1 I ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 9 i- Commonwealth of Massachusetts Division of Occupational Licensure Board of Building Re ulations and Standards Cons f i�rvisor CS-098654 Ai • 1239ires: 08/19/2025 RENE E GA1 HIER, JR 82 PEQUOT 6D M SOUTHAMPt N MA 01073 ?!. o,- z vlZd,it1`° o o Li,N I 0 O2, M O I Commissioner _(� W�' "'s`�—'- I-CO t° 3.0 I W 0) 0 y q� �� - co cco O, cc i ��fD� N oc n 2S11 3 I � rco .0 , o `g arm ' - to t Q _ N gu, Uk v LL c N N cti co � cc Z Construction Supervisor o u, U o 03 Inrestricted - Buildings of any use group which contain J c, o E m xo 0 ss than 35,000 cubic feet (991 cubic meters) of enclosed aI g'3 E (ryo-m space. E " E. F O � � inn cnorE UIn 9 _ E w G� _ y p U w� ¢ W O S > s) mo = N w ScL U 1- v a C2 z O O Nro `C_.,jv, U '4mUm V D 0 LL: 8 > o � =' wo a:l1,I r m U fn OQ 54 oa� 6 o uilure to possess a current edition of the Massachusetts z° W o€ .P i g ate Building Code is cause for revocation of this license. 0iw� w e- Wog Z , For information about this license Q D zU11 d ° S q Call (617) 727-3200 or visit www.ir�assegov/dpl �0 w u04 i W Wad z zg� iti; GAF N E X 1 G E N ELITE ROOFING "a,. .+. max, ilfew • „L .,. •.. y"$ v~ 1.h •1 ... ., -, . . / Rr - '.... _... 4106. _ - 04_ lam• ♦ ' `I....6 ►� � .. ;; y' -, ,.4$gliollii.. , ' Nil*:..., , ..v...) 1141111, 4e.4.2.1 ro:441°111., i . ' 1,,..N w 1. fwKAAYR.a. _ �_.. 1 • ... • R.. sa x 1.! ii,g *lin__ is— - ' d • •,,... `q:,. w T, ', a 4y. . by '--' J GAF ROOFING PROPOSAL ROBERT LOCK SEP 22,2023 I Project#2631 28 Harlow Ave Northampton,MA We can help you with 01060 Roofing,Siding,Windows,Gutters,& Decks 6175718204 1 Arch Rd Suite 11 Westfield, MA 01085 info@nextgen413.net (413)579-5798 NEXTGEN ROOF + Description Material GAF TIMBERLINE HDZ: The product of millions of dollars in Research&Development.Innovation and expertise from America's Largest shingle manufacturer cannot be ignored.With the new StrikeZone this is now the largest nailing zone in the industry and combined with the layerlock technology you get a Wind Warranty with NO LIMITS. Meaning ANY WIND SPEED,you are covered. GAF WEATHER WATCH ICE&WATER UNDERLAYMENT: A layer of self-sealing protection for vulnerable areas of the roof against wind-driven rain and ice dams. On full roof replacement WEATHERWATCH is installed 6'up from the fascia,in all valleys,and around all roof penetrations. GAF DECK-ARMOR UNDERLAYMENT: Breathable technology helps manage roof system moisture,providing a secondary layer of wind-driven rain protection.The ONLY breathable underlayment on the market TODAY. GAF PRO START SHINGLE STARTER: Starter shingles made with a high-quality,properly positioned adhesive applied at the factory to help prevent shingle blow-off. GAF SEAL-A-RIDGE: Ridge cap offers protection at the highest stress area of your roof(hips and ridges)against leaks and blow-off. DuraGrip Self-Seal adhesive is factory-applied to help seal each piece tightly and reduces the risk of blow-off. Flashings and Fasteners DRIP EDGE: Our Stormguard 8"metal flashing that protects the eaves of your home and prevents rain from going behind the gutters and/or fascia potentially causing damage. ULTRAHOLD RING-SHANK NAILS: We highly recommend using ring shank nails for installing roofing shingles due to their superior holding power,wind resistance,durability,and reduced risk of shingle damage, ultimately improving the roofs longevity and wind damage resistance. T50 STAPLES: Used to secure down the underlayment to the decking prior to installing the roofing system. CHIMNEY FLASHING: Covers the cost of material and labor to install chimney flashing including reglet style counter flashing.(up to a 36"x 24" chimney) Vents GAF COBRA SNOWCOUNTRY ADVANCED: Allows heat and moisture to escape and helps resist snow infiltration in harsh winter weather. LIFETIME PIPE FLASHING 4": Used to seal around plumbing vents that penetrate through the roof decking.These have a flange that is secured to the deck and the roofing material is installed to create a positive lap creating a proper seal. Labor and Disposal SLIPPERY SLOPE INSTALL 8/12-10/12: Covers the cost of labor associated with the 1 layer removal and replacement of the roof on a slippery roof slope. SECOND STORY ACCESS: Covers the cost of labor associated with working on a second story roof. BUILDING PERMIT: Municipal permit for construction activities. DUMP TRAILER: Dump fees for waste disposal. Additional Labor Warranty GAF GOLDEN PLEDGE WARRANTY: Warranty includes a 50-year coverage on manufacturing defects;25-year coverage on workmanship;transferable once within 20 years. Quote subtotal $18,453.75 Total $18,453.75 ally. est. $254.10/mo https://lending.ally.com/qualify/5092/18881 AUTHORIZATION PAGE Nextgen Roof+ $18,453.75 Project: 2631 Name: Robert Lock Address:28 Harlow Ave, Northampton,MA Estimates valid for 30 days from date of estimate Upgrades We Suggest for your " New Roof https://lending.ally.com/qualify/5092 Description Qty Unit price Line total Est. Payment 0 K5 GUTTERS: $21.33 $0.00 $0.00/mo Supply and install k5"white seamless gutters. Final Price $18,453.75 Customer Comments / Notes My Product Selections Shingle/Panel Color Metal Color Vent Color Robert Lock: 7�iLo-ck, Date:10/17/2023 Exclusions: By signing this form I agree to and confirm the following:I certify that I am the registered owner of the above project property,or have the legal permission to authorize the work as stated.I agree to pay the total project price and understand that this work will be completed in accordance with industry best practices. TERMS AND CONDITIONS NEXTGEN CONSTRUCTION SERVICE INC/NEXTGEN ROOFING-CUSTOMER AGREEMENT info©nextgen413.net 1413.579.5798 MA License No.CS-098654 HIC 196063 CT HIC 0663014 1 Arch Rd Suite 11 Westfield,MA 01085 CUSTOMER (also referred to as"YOU"or"CUSTOMER") and NEXTGEN,a fully licensed and insured General Contractor (referred to as"CONTRACTOR","US"or"WE") AGREE AS FOLLOWS: 1.CONTRACTOR SCOPE OF WORK:Please see Estimate for the detailed scope of work 2.CUSTOMER WORK:All work will be performed by Contractor or Contractor's subcontractors.Customer and Contractor agree that Customer must obtain written permission from Contractor prior to performing any work on the Property,Customer agrees to remove any items off walls which may interfere with the Work or be damaged during the course of the Work.Customer acknowledges and agrees that Contractor shall not be liable for any and all damages to such items.Customer acknowledges that during the roofing process some debris may be forced through nail holes or openings in the wood,Contractor is not responsible for clean-up or damages due to this and recommends covering items directly under roofing surface to facilitate easy clean-up. 3.PAYMENT TERMS: Non-Insurance Claim: No Money down at the time this agreement is entered into unless there is special order items needed,and payment of the remainder is due upon successful completion of the work. 4.Insurance Claim:The amount due for the Work shalt be equal to the total insurance claim amount as authorized by your insurance company(the"price").This Agreement does not obligate NextGen in any way to complete the work unless your claim is approved by your insurance company and then accepted by the Contractor. By signing this Agreement,you authorize NextGen to pursue your insured interest for the work at a price agreeable to the insurance company and NextGen with no additional cost to your regards to the work except for the insurance deductible in the FULL amount,which shall be due to NextGen by the customer as a deposit upon execution of this agreement. By signing this agreement,you authorize and agree that NextGen may correspond with your insurance provider regarding the scope of work and shall complete the work upon approval by your insurance company and acceptance by NextGen.Under no circumstance shall this agreement be construed to require NextGen to negotiate customer's insurance coverage or otherwise fulfill the duties of a public adjuster.Customer authorizes its insurance company to issue all insurance proceeds checks jointly in the name of Nextgen Construction Service Inc. EXECUTION OF AGREEMENT: (The signatures below acknowledge that the parties have read and agreed to each provision provided) **There are some important things to know about our Terms&Conditions.These conditions are born from suggestions from risk-averse paranoid Legal Departments.We are bound by our core values.Our core values supersede a long jargon-filled block of text as we know any time the terms and conditions are used it is a risk of an unhappy customer and damage to our brand and the loss of future referrals. Feel free to call your sales rep directly for clarification on any of these industry-standard terms and conditions. We have a very logical and reasonable explanation for every line in this agreement and we are happy to share it.** 5.DOWN PAYMENTS/DEPOSITS:Customer understands that any money paid to Contractor as a deposit is to be applied to Contractor's cost to complete the Work("Contractor Deposit").In the event Customer terminates this Agreement pursuant to Notice of Cancellation,such funds shall be returned to Customer pursuant to the Notice of Cancellation. If Contractor has purchased any permits or special order materials for the job there may be a cancelation fee to cover costs. 6.CHANGES TO THE WORK(CHANGE ORDERS):Contractor's obligations under this Agreement cannot be changed[ knowIede that I have read and understand this page.Initials: unless they are changed in writing on a separate Change Order form signed by Customer and Contractor and the insurance company as necessary and applicable ("Change Order"). If there is a discrepancy between documents,the written Change Orders shall take precedence over this Agreement. Payment for the Change Order work is due upon execution of the Change Order.Contractor may,at Contractor's sole discretion, require the customer to provide an additional deposit towards increased costs associated with Change Orders.Customer acknowledges that it shall be personally responsible for any changes which are not included in any applicable insurance settlement.Contractor shall have the right to stop all Work at such time as a change is requested or required until such time as the Change Order is executed by Customer.Contractor has an absolute right to reject any requested Change Order for any reason. **Sometimes additional work may be required due to concealed conditions, If the customer is not available to sign a change order we may proceed with verbal consent from the customer in order to properly protect the property** 7.REMEDIES: In the event of Customer's default of this Agreement,interest will accrue on unpaid amounts at the rate of 1.5%per month,or if lower,the highest amount allowed by law. In the event that Contractor incurs costs or attorney's fees to enforce this Agreement's terms,such amounts will be in addition to any amounts owed by Customer to Contractor. If Contractor does not receive any payments due under this Agreement's terms,Contractor may stop Work without further notice and seek all available remedies.Contractor shall be entitled to all payments due up until the point at which Work is stopped,and for all losses sustained by the Contractor,including but not limited to, materials, machinery,equipment or tools,overhead, lost profits,soft costs,and damages.Contractor will retain title to all machinery and materials if this Agreement is canceled,this includes a situation in which Customer attempts to improperly terminate this Agreement after any insurance proceeds have been determined but construction has not commenced.Contractor is hereby granted a license to enter the Property to remove such items upon termination of this Agreement. If Work has stopped for any reason,including delays by Customer's insurance company,for more than 30 days,Contractor may terminate this Agreement and recover pursuant to this Agreement. If Customer defaults in any manner under this Agreement,Contractor will have the right to (1)terminate this Agreement, (2) retain all deposits, fees,and progress payments Customer has made,and (3)take legal action to recover from Customer payment for all Work completed,and for all losses sustained by Contractor on all materials,machinery,equipment or tools,overhead, soft costs,profit and damages,and (4) place liens upon the Property for payment of any amounts owed,and (5) foreclose any liens placed on the Property if the amounts due including costs and interest are not paid in full. Contractor's exercise of any remedy shall not preclude the exercise of the remedies available to Contractor.The remedies contained in this Agreement may be used concurrently and are in addition to any other remedy which may be available to Contractor at law or equity.This one is a Doozy,and we have never had to use it.Typically this is for commercial jobs.When it comes to"Bob and Betty homeowners this is pretty simple.We do the job,be prepared to pay us.If we have to chase you,we charge you to chase you.Simple.We want you happy and don't want you to pay us until you are happy. ARBITRATION OF DISPUTES THIS CONTRACT SHALL BE INTERPRETED UNDER THE LAWS OF THE COMMONWEALTH OF MASSACHUSETTS. IN THE EVENT OF ANY DISPUTE ARISING HEREUNDER AS TO WHETHER CONTRACTOR'S WORK COMPLIES WITH THE PLANS AND SPECIFICATIONS OR WHETHER PAYMENT IS PROPERLY DUE AND THE SAME IS NOT SETTLED WITHIN FOURTEEN DAYS,THEN SAID DISPUTE SHALL BE RESOLVED BY ARBITRATION WITH A PRIVATE ARBITRATION SERVICE THAT HAS BEEN APPROVED BY THE SECRETARY OF THE EXECUTIVE OFFICE OF CONSUMER AFFAIRS AND BUSINESS REGULATIONS AS PROVIDED IN MASSACHUSETTS GENERAL LAWS CHAPTER 142A PRIOR TO EITHER PARTY PROCEEDING TO LEGAL ACTION IN THE COURTS.THE PARTIES SIGN BELOW ACCEPTING SUCH ARBITRATION WITH THE CONSTRUCTION INDUSTRY ARBITRATION RULES OF THE AMERICAN ARBITRATION ASSOCIATION THEN OBTAINING.THERE SHALL BE A SINGLE ARBITRATOR.THE JUDGMENT ON ANY AWARD RENDERED BY THE ARBITRATOR MAY BE ENTERED IN ANY COURT HAVING JURISDICTION.THE PARTIES HEREBY AGREE TO USE REASONABLE EFFORTS TO RESOLVE ANY DISPUTES SO AS TO AVOID THE COST AND DELAY ASSOCIATED WITH THE ARBITRATION. 8.TIME DELAYS:Customer agrees that Contractor is not responsible for delays in completion of the Work due to weather,strikes,war,terrorist attacks,shortage or delay in getting materials,shortage or delay in labor or subcontracting,government regulations,court actions or any other cause beyond Contractor's control. If the cost of materials or labor increases during any such delays,Contractor may require that Customer or Customer's insurance company pay such increased costs or terminate this Agreement after paying Contractor for all work completed to the date of termination and for all materials which cannot be returned.Customer will not be entitled to any remedy for Contractor's failure to start or complete the Work at any particular time.Customer understands that delays caused by Customer,Customer's Lender,or Customer's insurance company may cause additional delays on the part of Contractor due to unavailability of labor or subcontractors. I acknowledge that I have read and understand this page.Initials: 9.CONCEALED CONDITIONS:There are occasionally unseen site conditions,we make every effort to discover this during the estimate.We make a stronger effort here than most, BUT some things just cannot be seen before opening the roof. This Agreement and the price are based solely on the observations of Contractor at the time of entering into this Agreement. If additional concealed conditions are discovered once the Work has commenced,which conditions were not visible at the time of entering into this Agreement,Contractor will identify the unforeseen conditions,and Customer and Contractor will execute a change order for any additional work(which must be approved by the insurance company).Customer agrees that if the insurance company does not agree to pay for unexpected or unanticipated extra costs,then Contractor may terminate this Agreement and Contractor shall be entitled to payment for all Work completed through the date of termination.Customer will be responsible for all additional costs and time for work due to concealed conditions.Such conditions may also extend the time for completion of Contractor's Work under this Agreement. If plywood need to be replace or installed there will be an additional charge of$100 per 4'x8' sheet. 10.CUSTOMER SITE VISITS: Because of hazards that may be on the construction site during construction and the potential to interfere with the Work,Customer is encouraged to enter into the construction area only after first consulting with Contractor. During the time of construction on the Property,conditions will exist that will be hazardous to Customer and Customer's family,friends,and guests.Customer waives all claims against Contractor and agrees to indemnify,defend and hold Contractor harmless for injuries or damages that customer or any member of Customer's family,friends,or guests may suffer while on or around the property during construction. 11.USE OF DUMPSTER:Customer acknowledges and agrees that Contractor may place a dumpster on the Property for collection of construction waste materials (the"Dumpster").Customer agrees that Customer and Customer's family, friends,or guests will not place any materials in the Dumpster whatsoever or otherwise interfere with,enter into,or move the Dumpster.Customer waives all claims against contractor(and agrees to indemnify,defend and hold Contractor harmless)for property damage or injuries or other damages that Customer or any member of the Customer's family,friends,or guests, may suffer as a result of the Dumpster.Should Customer or any member of Customer's family,friends,or guests place any materials in the Dumpster,Customer agrees that it shall be responsible for any increased costs associated with such actions. 12.SUBCONTRACTORS:Contractor may use subcontractors and suppliers to complete the Work.Subcontractors will be chosen by the Contractor only.Customer agrees not to hire any of Contractor's subcontractors or suppliers to do any work or supply any materials,except upon written agreement signed by the Contractor.Customer agrees not to interfere with,discuss with,interrupt or provide instruction to any contractor or subcontractor working on the Property. 13.PRE-LIEN NOTICE TO OWNER:GENERAL CONTRACTOR PRE-LIEN NOTICE TO OWNER(A)ANY PERSON OR COMPANY SUPPLYING LABOR OR MATERIALS FOR THIS IMPROVEMENT TO YOUR PROPERTY MAY FILE A LIEN AGAINST YOUR PROPERTY IF THAT PERSON OR COMPANY IS NOT PAID FOR THE CONTRIBUTIONS.(B) UNDER MASSACHUSETTS LAW,YOU HAVE THE RIGHT TO PAY PERSONS WHO SUPPLIED LABOR OR MATERIALS FOR THIS IMPROVEMENT DIRECTLY AND DEDUCT THIS AMOUNT FROM OUR CONTRACT PRICE,OR WITHHOLD THE AMOUNTS DUE THEM FROM US UNTIL 120 DAYS AFTER COMPLETION OF THE IMPROVEMENT UNLESS WE GIVE YOU A LIEN WAIVER SIGNED BY PERSONS WHO SUPPLIED ANY LABOR OR MATERIAL FOR THE IMPROVEMENT AND WHO GAVE YOU TIMELY NOTICE. UNDER CHAPTER 254 OF MASSACHUSETTS GENERAL LAWS,THE CONTRACTOR AND ANY SUBCONTRACTORS THAT THE CONTRACTOR HAS A WRITTEN CONTRACT WITH, MAY OBTAIN A LIEN COMMONLY KNOWN AS A"MECHANICS LIEN"AGAINST THE PROPERTY WHERE THE WORK IS BEING PERFORMED 14.LEGAL NOTICES:Customer acknowledges reviewing the following attached or incorporated legal notices:General Contractor Pre-Lien Notice to Owner, Building Performance Guideline, Urea Formaldehyde Notice,327A Warranty Addendum, Notice of Right of Rescission (if applicable),a Lead Paint Pamphlet and Addendum (if applicable),Water Intrusion and Mold Growth Notice,Authorization to Correspond and the Notice Regarding Cancellation Rights and the Notice of Cancellation which shall be incorporated herein by reference. 15.CUSTOMER'S THREE-DAY RIGHT TO TERMINATE:CUSTOMER IS ADVISED THAT FEDERAL AND STATE LAW ALLOWS CUSTOMER TO TERMINATE THIS AGREEMENT FOR ANY REASON WITHIN THREE (3) DAYS AFTER SIGNING IT. CUSTOMER ACKNOWLEDGES THAT THEY HAVE RECEIVED SUCH NOTICE PURSUANT TO THIS SECTION AND PURSUANT TO THE RIGHT OF RESCISSION ATTACHED HERETO.LIQUIDATED DAMAGES:Customer acknowledges that this agreement constitutes an enforceable contract and that in reliance upon the representations and terms herein, Contractor shall incur substantial time and resources toward the completion of the work authorized herein,which may or may not involve physical work at Customer's property.Customer acknowledges that such expense can not be reasonably ascertained at any specific time,and as such,Customer agrees that if customer terminates this agreement I acknowledge that I have read and understand this page.Initials: prior to Contractor's commencement of any improvement to your property, in addition to any other damages Contractor shall be entitled to,Customer shall pay contractor,as liquidated damages and NOT as a penalty,the sum of $1,500.00 immediately upon demand. 16. DISPUTE RESOLUTION:Except as otherwise provided herein,any claim by Customer or Contractor in any way arising out of this Agreement,any and all other agreements between Customer and Contractor and/or in any way arising out of or relating to the physical condition of the property shall be settled by binding arbitration in Hampden County Massachusetts,under the Construction Industry Rules of the American Arbitration Association.Contractor retains the right to file,perfect and start a lawsuit to Enforce Mechanic's Lien Rights.The parties agree that the court may refer the matter to arbitration,but retain jurisdiction for enforcement of the Mechanic's Lien. 17.PAYMENT UPON COMPLETION AND RETAINAGE RIGHTS:Customer shall pay any outstanding amounts withheld from the Price in accordance with this Contraction notice by the Contractor that the work is complete.Should the Customer believe that the work is not complete,Customer shall communicate and document the belief via text or email within 24 hours of receiving notice from Contractor that the work is complete.Customer shall retain no more than 5%of the Price and must provide Contractor with availability for inspection and walkthrough within three days of Customer's notice of non-completion. 18.PUNCH LIST ITEMS:Contractor shall communicate to customer if work is complete but for certain minor items that Contractor is addressing with due diligence ("punch list items").Contractor shall provide a list and expected completion date for any punch list items if such work shall require more than 7 days to complete. Upon contractor's communication to Customer that work is complete except for identified punch list items,Customer shall pay Contractor all but 5%of the price,the remainder due within 24hrs of notification of completion of punch list items. If customer believes that punch list items are not all completed,such communication must be made to Contractor within 24hrs and the Contractor must be provided access to inspect the claimed non-complete punch list items within 3 days of Customer's notice to Contractor of said belief. 19.MISCELLANEOUS:The invalidity, illegality,or unenforceability of any provision, restriction,condition, reservation,or any other part of this Agreement,in its entirety or as applied to particular circumstances shall not impair or affect in any manner the validity, legality,enforceability or effect of the remainder of this Agreement.This Agreement shall not be assigned by Customer,except with Contractor's prior written consent.This Agreement may be amended only by a written instrument signed by both parties.The captions contained in this Agreement are for convenience only.Any number of counterparts of this Agreement may be executed and each such executed counterpart shall be deemed an original, but all such counterparts together shall constitute one Agreement.The electronic signature of any party to this Agreement shall be sufficient for all purposes.CUSTOMER AGREES THAT THIS AGREEMENT IS SUBJECT TO APPROVAL OF A CORPORATE OFFICER OF CONSTRUCTION COMPANY,AND UPON REVIEW OF THE DETAILS OF TITLE AGREEMENT,INCLUDING THE PRICE, MEASUREMENTS OR ANY OTHER FACTORS,CONSTRUCTION COMPANY MAY DECLINE TO APPROVE THIS AGREEMENT,AND DECLARE THE AGREEMENT NULL AND VOID AT ITS OPTION,AT WHICH TIME ANY DEPOSIT MADE BY CUSTOMER WILL BE PAID IN FULL TO CUSTOMER. 20.Interior prep: During construction,the home will vibrate and even shake at times.We recommend removing any valuable items from the walls or shelves. Nextgen will not be responsible for any broken items.We also recommend moving and protecting items in the attic.It is common for debris to fall through the roof decking and make a mess in the attic.Nextgen is not responsible for cleaning the interior of the home or attic or protecting any of the contents. 21.Skylights:The Company is not responsible for any damages related to leaks from skylights unless the Company completed the skylight replacement as part of the Work.See,skylights are a common issue,and there are 9 ways to install them incorrectly yet can be indistinguishable from the average person's inspection.So if we don't get to replace it we can not guarantee the work we have to do around it as disturbing it could cause problems. It's always best to replace your skylights when replacing your roof. Look at how many improvements and updates your phone has had in 5-years, now think about your 18-year-old skylight. 22.Solar panels: If there are solar panels on the roof,Customer agrees to take all necessary steps to remove, protect, and reinstall the same. Under no circumstances will the Company be responsible for damage to such solar panels during the course of the Work unless the removal of the Panels is provided by NextGen Roofing in this agreement. If you hire someone to remove and replace the panels,then the panels including how and where they are stored are not our responsibility.So make sure they put them somewhere for safekeeping and store them properly to prevent damage. 23.Media:Customer agrees that Contractor has the right to use any reproductions of the Work for publication or distribution,including the publishing or use of photographs or descriptions of the Work,for promotional or advertising I acknowledge that I have read and understand this page.Initials: R4 • uses.You might have found us on Facebook,Instagram,or Youtube,that is because we are proud of the work we do and choose to share it with the world. If you are a billionaire who has hired us to roof your mansion on the beach,we can talk about confidentiality.Otherwise,we might record a video showing us doing awesome work on your roof and share it with the world! 24.Price:Having experienced the COVID-19 Pandemic it seems necessary to mention that our price Guarantee is void barring any drastic swing in prices from our suppliers.This could be caused by any reason out of our control to have been reasonably foreseen.We do not know if America will suffer excessive waves of viral infections,hyperinflation, government shutdowns,or other events that can have a serious impact on pricing volatility.We can cancel the job at any time due to delays,shortages,or volatile pricing.We will refund any money paid prior to starting the job in accordance with our policy above.There are no guarantees in this world.That is one lesson we have learned,and things like Pandemics are tough. I acknowledge that I have read and understand this page.Initials: FINAL AUTHORIZATION SUMMARY Status: Signed Agreement Completed: Tue, 17 Oct 2023 12:37:05 GMT • Document emailed for signature: Thu, 28 Sep 2023 13:50:07 GMT Document e-signed by: Robert Lock (lock.robert@gmail.com) Signature date: Tue, 17 Oct 2023 12:37:05 GMT IP address: 73.68.77.24