Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
31C-081-014
BP-2022-1189 117OL` NDER COMMONWEALTH OF MASSACHUSETTS Map:Block:Lot: 31C-081-014 CITY OF NORTHAMPTON Permit: Solar Build PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL c.142A) BUILDING PERMIT Permit# BP-2022-1189 PERMISSION'S HEREBY GRANTD TO: Project# 2022 SOLAR UNIT 12 Contractor: License: Est. Cost: 38014 SUNBUG SOLAR LLC CSL057898 Const.Class: Exp.Date:08/15/2023 Use Group: Owner: G.C.DYER HOLMES,JOSEPH M. &ELIZABETH Lot Size (sq.ft.) G.C.DYER HOLMES,JOSEPH M.& Zoning: Applicant: ELIZABETHROBERT ACEVEDO Applicant Address Phone: Insurance: 117 OLANDER # 12 NORTHAMPTON, MA 01060 64 MAPLE ST 617-500-3938 FRANKLIN, MA 02038 ISSUED ON:09/23/2022 TO PERFORM THE FOLLOWING WORK: INSTALL 20 PANEL 7.3 KW ROOF MOUNTED SOLAR SYSTEM WITH 16.0 KW BATTERY POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector Underground: Service: Meter: Footings: Rough: Rough: House # Foundation: Final: Final: Final: Rough Frame: Gas: Fire Department Driveway Final: Fireplace/Chimney: Rough: Oil: Insulation: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOIATION OF ANY OF ITS RULES AND REGULATIONS. Signature: i I .>2• If '1 • Fees Paid: $75.00 212 Main Street, Phone(413)587-1240,Fax:.(413)587-1272 Office of the Building Commissioner JOL.UJIL9II CI IVOIUIJO ILJ. IDOI DJUC- GJ/-4MCo-yl,O/-I..L UOCOUCYUUC Ct /I/The Commonwealth of Massac usett• Sep - R Board of Building Regulations a 4 St.� 4.rds 0 I ALITY Massachusetts State Building Co 8(�o;fie �0�42 SE Building Permit Application To Construct,Repair, Reno 9T-. ` I.�c-.polish a Revi edMar 2011 One-or Two-Family Dwelling TON MspF This Section For Official Use Only A���o�ONS Building Permit Numbers P )-.11 'r 67 Date Applied: g e,I, &:)•> /11Z q.Zz-zozZ Building Official(Print Name) Signature Date SECTION 1: SITE INFORMATION 1.1 Property Address: 1.2 Assessors Map&Parcel Numbers 117 Olander Dr. Unit 12, Northampton, MA 01060 1.1 a Is this an accepted street?yes_ no Map Number Parcel Number 1.3 Zoning Information: 1.4 Property Dimensions: Zoning District Proposed Use Lot Area(sq ft) Frontage(ft) 1.5 Building Setbacks(ft) Front Yard Side Yards Rear Yard Required Provided Required Provided Required Provided 1.6 Water Supply: (M.G.L c.40,§54) 1.7 Flood Zone Information: 1.8 Sewage Disposal System: Public 0 Private 0 Zone: _ Outside Flood Zone? Municipal 0 On site disposal system 0 Check if yes❑ SECTION 2: PROPERTY OWNERSHIP' 2.1 Owner'of Record: Joseph Holmes Northampton, MA 01060 Name(Print) City,State,ZIP 117 Olander Dr.Unit 12 978-844-1182 joseph.holmes@alum.mit.edu No.and Street Telephone Email Address SECTION 3:DESCRIPTION OF PROPOSED WORK2(check all that apply) 1 New Construction 0 Existing Building 0 Owner-Occupied 0 Repairs(s) 0 Alteration(s) 0 Addition 0 Demolition 0 Accessory Bldg. ❑ Number of Units Other ■ Specify: Solar and ESS Install Brief Description of Proposed Work2: Installation of 20 roof mounted solar modules and an ESS comprising of one DC-coupled LG RESU16H Prime. SECTION 4: ESTIMATED CONSTRUCTION COSTS Item Estimated Costs: Official Use Only (Labor and Materials) 1.Building $ 38014.55 1. Building Permit Fee: $ Indicate how fee is determined: ❑Standard City/Town Application Fee 2.Electrical $ ❑Total Project Cost'(Item 6)x multiplier x 3.Plumbing $ 2. Other Fees: $ 4.Mechanical (HVAC) $ List: 5.Mechanical (Fire $ Suppression) Total All Feetel Check No. Check Amount: �� Cash Amount: 6.Total Project Cost: $ 38014.55 0 Paid in Full 0 Outstanding Balance Due: UU(.UOIyII CIIVCIUF/C IU. !DO!D.)lJ ULa!WMCO-yli0!-I,LUOCOUC4UUC SECTION 5: CONSTRUCTION SERVICES 5.1 Construction Supervisor License(CSL) CS-057898 08/15/2023 Robert Acevedo License Number Expiration Date Name of CSL Holder List CSL Type(see below) U 64 Maple Street No.and Street Type Description U Unrestricted(Buildings up to 35,000 cu.ft.) Franklin, MA 02038 - R Restricted 1&2 Family Dwelling City/Town,State,ZIP M Masonry r°"""ekrf d RC Roofing Covering ` WS Window and Siding • SF Solid Fuel Burning Appliances 617-500-3938 permits@sunbugsolar.com I Insulation Telephone Email address D Demolition 5.2 Registered Home Improvement Contractor(HIC) 163091 05/10/2023 SunBug Solar / Cheney Brand [ gru,d, HIC Registration Number Expiration Date HIC Company Name or HIC Registrant Name "` 2a Draper Street No.and Street permits@sunbugsolar.com Email address Woburn, MA 01801 617-500-3938 City/Town,State,ZIP Telephone SECTION 6: WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c. 152.§ 25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the Issuance of the building permit. Signed Affidavit Attached? Yes ■ No...........❑ SECTION 7a: OWNER AUTHORIZATION TO BE COMPLETED WHEN OWNER'S AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT I,as Owner of the subject property,hereby authorize SunBug Solar to act on my behalf,in all matters relative to work authorized by this building permit application. 9/14/2022 Print Owner's Name(Electronic Signature) Date SECTION 7b:OWNER'OR AUTHORIZED AGENT DECLARATION By entering my name below,I hereby attest under the pains and penalties of perjury that all of the information contained in this application is true and accurate to the best of my knowledge and understanding. ( °'""""' 9/14/2022 E Printwner's or Authorized Agent's Name(Electronic Signature) Date NOTES: 1. An Owner who obtains a building permit to do his/her own work,or an owner who hires an unregistered contractor (not registered in the Home Improvement Contractor(HIC)Program),will not have access to the arbitration program or guaranty fund under M.G.L.c. 142A. Other important information on the HIC Program can be found at www.mass.gov/oca Information on the Construction Supervisor License can be found at www.mass.gov/dps 2. When substantial work is planned,provide the information below: Total floor area(sq.ft.) (including garage,finished basement/attics,decks or porch) Gross living area(sq. ft.) Habitable room count Number of fireplaces Number of bedrooms Number of bathrooms Number of half/baths Type of heating system Number of decks/porches Type of cooling system Enclosed Open 3. "Total Project Square Footage"may be substituted for"Total Project Cost" a • � JuuuatyiI CI IVCIU�a IU. /DO/DJUC-ULO/-4MCO-UVO/-I,LUOCOUC4UUC City of Northampton ca -. , S`S ...sirs Massachusetts � '<<, DEPARTMENT OF BUILDING INSPECTIONS II c. e v �� aw, 212 Main Street • Municipal Building ' Northampton, MA 01060 'rst-h, 3,.,‘''N CONSTRUCTION DEBRIS AFFIDAVIT (FOR ALL DEMOLITION AND RENOVATION PROJECTS) In accordance of the provisions of MGL c 40, S54, a condition of Building Permit Number is that all debris resulting from this work shall be disposed of in a properly licensed waste disposal facility, as defined by MGL c 111, S 150A. The debris will be disposed of in: Trash Bins Location of Facility: 68 Hopkinton Rd, Westborough, MA 01581 The debris will be transported by: Name of Hauler: El Harvey and Sons ° 9/14/2022 Signature of Applicant: (k Date: ; Commonwealth of Massachusetts Division of Professional Licensure Board of Building Regulations and Standards Constru Ion O rvisor � CS -057898 Expires : 08/ 15/2023 ROBERT W ACEVEDO 64 MAPLE ST FRANKLIN MA 02038 4 I/SS ' I yIL III Commissioner ,jai `sue f. ZiC419cit ac, Office of Consumer Affairs and Business Regulation 1000 Washington Street - Suite 710 Boston, Massachusetts 02118 Home Improvement Contractor Registration Type: LLC SUNBUG SOLAR LLC Registration 163091: 05/10/2023 411A HIGHLAND AVENUE Expiration: SUITE 312 SOMERVILLE, MA 02144 Update Address and Return Card. Office of Consumer Affairs & Business Regulation HOME IMPROVEMENT CONTRACTOR Registration valid for individual use only TYPE: LLC before the expiration date. If found return to: Registration Expiration Office of Consumer Affairs and Business Regulation 163091 05/10/2023 1000 Washington Street - Suite 710 SUNBUG SOLAR LLC Boston, MA 02118 / CHENEY BRAND 1165 MASSACHUSETTS AVENUE f %//6".° c ARLINGTON, MA 02476 Undersecretary at vall ithout signature The Commonwealth of Massachusetts Department of Industrial Accidents Office of Investigations e Lafayette City Center . — _;t,i 2 Avenue de Lafayette, Boston, MA 02111-1750 www.mass.gov/dia o11ers' Compensation Insurance Affidavit: Builders/Contractors/Electricians/Plumbers Applicant Information Please Print Legibly Name (Business/Organization/Individual):SunBug Solar Address:411 A Highland Ave. Suite 312 City/State/Zip:Somerville, MA 02144 Phone#:413-884-1000 Are you an employer?Check the appropriate box: Type of project(required): 1.2 I am a employer with 70 employees(full and/or part-time).* 7. ❑New construction 2.0 I am a sole proprietor or partnership and have no employees working for me in 8. ❑Remodeling any capacity.[No workers'comp.insurance required.] 3.0 I am a homeowner doingall work myself. 9. Demolition❑ y [No workers'comp.insurance required.]t 4.0 I am a homeowner and will be hiring contractors to conduct all work on my property. I will 10❑Building addition ensure that all contractors either have workers'compensation insurance or are sole 11.0 Electrical repairs or additions proprietors with no employees. ! 12.❑Plumbing repairs or additions 5.0 I am a general contractor and I have hired the sub-contractors listed on the attached sheet. 13.❑Roof repairs These sub-contractors have employees and have workers'comp.insurance. 6.❑We area corporation and its officers have exercised their right of exemption per MGL c. 14.®Other 5G(`.V awl 152,§1(4),and we have no employees.[No workers'comp.insurance required.] *Any applicant that checks box#1 must also fill out the section below showing their workers'compensation policy information. t Homeowners who submit this affidavit indicating they are doing all work and then hire outside contractors must submit a new affidavit indicating such. :Contractors that check this box must attached an additional sheet showing the name of the sub-contractors and state whether or not those entities have employees. If the sub-contractors have employees,they must provide their workers'comp.policy number. I am an employer that is providing workers'compensation insurance for my employees. Below is the policy and job site information. Insurance Company Name:New York Marine and General Insurance Policy#or Self-ins.Lic.#:WC333749A Expiration Date:4/30/2023 Job Site Address:117 Olander Dr. Unit 12 City/State/Zip: Northampton, MA 01060 Attach a copy of the workers'compensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under MGL c. 152,§25A is a criminal violation punishable by a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of a STOP WORK ORDER and.a fine of up to$250.00 a day against the violator.A copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certify under the pains and penalties of perjury that the information provided above is true and correct. Signature: Date: Phone#: Official use only. Do not write in this area,to be completed by city or town official City or Town: _Permit/License# Issuing Authority(circle one): I. Board of Health 2.Building Department 3.City/Town Clerk 4. Electrical Inspector 5. Plumbing Inspector 6.Other_ Contact Person: Phone#: AC CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDD/YYYY) `/ 5/6/2022 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER INpower Global Insurance Services, LLC CONTACT NAME: Nicole Doverspike 999 Corporate Drive, Suite 100 AX (A//CC.No.Ext). (949)339-2799 (FAlCC,No) (949)600-7998 Ladera Ranch, CA 92694 E-MAIL ADDRESS: NDoverspike@INpowerGlobal.com INSURER(S)AFFORDING COVERAGE NAIC# www.INpowerGlobal.com CA DOI License No.6003712 INSURER A: Gotham Insurance Company 25569 _ INSURED INSURER B: New York Marine and General Insurance Co 16608 SunBug Solar, LLC, SunBug WM, LLC, SunBug, LLC 411 A Highland Ave#312 INSURERC: National Casualty Company 11991 Somerville MA 02144 INSURERD: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 68126113 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD MD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) i COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $1,000,000 DAMAGE TO CLAIMS-MADE / OCCUR PREMISES uES(Ea occr rrrrence) $100,000 MED EXP(Any one person) $5,000 A PK202200025565 4/30/2022 4/30/2023 PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE _ $2,000,000 POLICY ✓ JET LOC PRODUCTS-COMP/OP AGG $2,000,000 OTHER: $ AUTOMOBILE LIABILITY COMBINED O eBBIINEDtSINGLE LIMIT) $1,000,000 ✓ ANY AUTO BODILY INJURY(Per person) $ B OWNED ^ SCHEDULED AU202200016856 (MA) 4/30/2022 4/30/2023 AUTOS ONLY _ AUTOS BODILY INJURY(Per accident) $ HIRED NON-OWNED AU202200018380 (CT) PROPERTY DAMAGE $ ✓ AUTOS ONLY _ AUTOS ONLY (Per accident) $ UMBRELLA LIAR ✓ OCCUR EACH OCCURRENCE $5,000,000 A ✓ EXCESSLIAB CLAIMS-MADE EX202200002326 4/30/2022 4/30/2023 AGGREGATE $5,000,000 DED ✓ RETENTION$10,000 $ WORKERS COMPENSATION ✓ STATUTE ERH AND EMPLOYERS'LIABILITY Y I N C OF ICER/MEMBEREXCLU EXCLUDED?ECUTIVE N N/A WC333749A 4/30/2022 4/30/2023 E.L.EACH ACCIDENT $1,000,000 (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $1.000.000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 A Professional Liability-Claims Made PK202200025565 4/30/2022 4/30/2023 Each Wrongful Act: $1,000,000 Retroactive Date 01/01/2009 Aggregate Limit: $1,000,000 A Installation Floater PK202200025565 4/30/2022 4/30/2023 Any One Installation Project: $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Evidence of Coverage CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Evidence of Coverage THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE /j M"t--/ (-- 1 -1-b4/4----- Bart J.Le Fevre/KSK ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 68126113 1 22-23 GL AL XS WC PL IF 1 Nicole Doverepike 1 5/6/2022 8,41,51 AM (PDT) I Page 1 of 1 This certificate cancels and supersedes ALL previously issued certificates. Wwim WESTSHORE jmi DESIGN ENGINEERS. P.C. - 100 GREAT OAKS BLVD. 'SUITE 115 ALBANY I NEW YORK I 12203 To: SunBug Solar 66 Westfield Industrial Park Rd. Westfield,MA 01085 Date: June 17,2022 Ref.: 22060246 Subject: Joseph Holmes 117 Olander Dr. Unit 12 Northampton,MA To Whom it May Concern, The following references the Joseph Holmes residence in Northampton, MA: I. Existing roof framing: Pre-fabricated/engineered wood truss is 2x4 at 24"o.c.This existing structure is capable to support all the loads that are indicated below for this photovoltaic project. 2. Roof Loading: - 4psf dead load(modules plus mounting hardware) - 40psf ground snow load - 5.7psf roof materials(1.7psf 2x6, 1.5psf sheathing,2.5psf asphalt shingles) - Exposure Category B, 135mph wind gust(3 sec.) This installation design will be in general conformance to the manufacturer's specifications,and complies with all applicable laws, codes, and ordinances, specifically the International Building Code/IBC 2018 and International Residential Code/IRC 2018 including all MA regulations and amendments.Snap N Rack attachments at 48"o.c.staggered,with 5/16"lag and a 2.5"embed minimum for shingle roof. S-5! Clamps or equal attachments for metal roof. Unirac Flashloc RM installed per manufacturers recommendations and specifications installed on dormer roof. Thank you. Westshore Design Engineers �����SNOFNAssgcd �O ar.a.eo-a * OJF1' NICOLAS A. a, NITTI �/ CIVIL NO. 50222 ,o REGISTERED �Q It 94`esSIONAI ERs��� 6/17/2022 John Eibert Nicolas Nitti, PE Project Coordinator President WestShore Design Engineers 1100 Great Oaks Blvd.I Suite 115 I Albany,NY 12203 1518.313.7153 DocuSign Envelope ID:CEC0BF60-8405-4C37-8C6A-70CCCC567503 SunBug Solar TURNKEY INSTALLATION AGREEMENT THIS AGRp,EMEN'1', daces¢/2 7/2022 and SunBug Solar,LLC ' (the" for the instapatio ( ')whose "D is entered into be een: Joseph Holmes n�d/01 physical address is 2A Draper Street,Woburn, Ownr'� 1, �1fIP�t��illl gS more s prOV �t of.a sour system at the Owner's premises located at. 117 Oland anDr.Untt f License nnnrot 16360 the p specifically described below(the"Proiect'� A. nIF.JEQRK. Installer has previousl submitt By way of summary only,Installer's Scope of Work consistsand f the fr has ollowing elementroved the s as indi at d roject(the")'n Pusa Materials Procurement mitting Completion of Incentive Paperwork Per Turnkey Installation Electrical Interconnection Support Owner Operation Training Customer it responsible for providing Internet connection for online monitoring services. B. CONTRACT DOCUMENTS. This Turnkey Installation Agreement together with the Terms&Conditions set forth below (the"Terms and Conditions"),any change orders executed by the parties("Change Orders") and the Proposal(each of which are incorporated herein by reference and may be referred to as the "Contract Documents") comprise the entire agreement of the parties and may be referred to as"this Agreement" C. CONTRACT SUM,PAYMENTS.REBATES. C 1. The cost of the Project,including all materials,labor and Installer's fees(described as the gross price in the Proposal) is $27,283.00 dollars("Guaranteed Maximum Price"). The Guaranteed Maximum Price is a fixed price,not an estimate, and can only be changed by the parties executing and delivering a Change Order(see Section 10 of the Terms&Conditions for more information on Change Orders). However,the cost of the Project may be affected by unanticipated'regulatory requirements(e t?.,such as wetlands studies),unforeseen site conditions discovered after Installer's engineering analysis (e.g., structural rein orcement or roof repair),expenses related to utility interconnection approval(e.g.,transformer upgrade), or additional unforeseen expenses required by the local municipality to obtain required permit approvals. If this is the case, a Change Order reflecting a new Guaranteed Maximum Price will be required in order for the Project to continue. C 2. Owner will make payments to Installer in accordance with the following schedule: Payment Terms Amounts Down payment 1,000.00 50%due on Order of Materials 12,954.00 40%due on Commencement of Construction 10,363.00 SunBug Enhanced Warranty 900.00 SolarEdge Warranty 474.36 Balance due on Utility Interconnection 1,591.64 Total $27,283.00 C 3. Installer is ordering materials on behalf of Customer and will warehouse materials until time of installation. C 4. Installer may bill Owner partial progress payments for construction work(gg.,when some work is scheduled to be done before or after our primary construction mobilization we may bill a portion of the construction payment for that work; rough-in electrical work,critter guard,etc.) C 5. Installer shall apply,on behalf of Owner,for applicable rebates including any rebates as offered by Owner's utility service.Unless otherwise noted below,any rebates shall be payable directly to Owner subject to utility or other third-party approval.Owner acknowledges that rebates payable to Installer have reduced the contract sum payable to Installer by Owner. ❑Rebates will be paid directly to Installer(Check only if rebates to installer). C 6. If requested by Owner, Installer shall submit a Massachusetts Department of Energy Resources (DOER) and Massachusetts Clean Energy Center(MassCEC)Mass Solar Loan Technical Application.In that case,this Agreement and subsequent work is contingent on Program Loan approval(the"CEC Loan Approvals"). C 7. Installer shall secure all necessary construction related permits, other permits and/or governmental licenses and inspections necessary for the completion of the Project Unless otherwise noted,fees associated with acquiring such permits, licenses and inspections will be borne by Installer. C 8. Installer's obligations are specifically conditioned on the receipt of payment in full of the above amounts at the times specified. Without limiting the foregoing,delayed payments shall accrue interest at the rate of 1.0%per month. D. NOTICE OF RIGHT TO CANCEL. Owner may cancel this Agreement and the transactions contemplated hereby with no liability at any time prior to midnight on the third business day following the Effective Date. Page 1 of 6— SUNBUG SOLAR,LLC©2020 INSTALLATION AGREEMENT DocuSign Envelope ID:CECOBF60-8405-4C37-8C6A-70CCCC567503 E. CONFLICTS. In the event of a conflict between this Turnkey Installation Agreement and any Contract Document or etween the Terms and Conditions and any other Contract Document, this Turnkey Installation Agreement and the T s and Conditions,respectively,shall govern. DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES Entered into as of the Effective Date: OWNER DocuSigned by: SUNBUG SOLAR,LLC NOGr.ra [signature] 9EC313D49A894A4... By, Joseph Holmes By:Ben Mayer,Sales Manager 6/27/2022 Date: Solar Consultant Daniel Britton Page 2 of 6— SUNBUG SOLAR,LLC©2020 INSTALLATION AGREEMENT DocuSign Envelope ID CECOBF60-8405-4C37-8C6A-70CCCC567503 SunBug Solar` TERMS & CONDITIONS These Terms&Conditions are incorporated by reference into that certain Turnkey Installation Agreement between Installer and Owner(together with these Terms&Conditions and the other documents incorporated by reference therein,this"Agreement")and applies to all products and services furnished by Installer thereunder. Capitalized terms used but not otherwise defined in these Terms&Conditions shall have the meanings assigned to them in the documents comprising this Agreement. 1. TIME OF COMMENCEMENT&SUBSTANTIAL COMPLETION. 1.1. Work on the Project(including all labor,materials,equipment and services,whether completed or partially comple d under this Agreement,the"Work")will,unless otherwise scheduled in the Proposal,commence no later than sixty days(60) ollowing the receipt of all applicable approvals including but not limited to the CEC Loan Approvals(the"Start Date"). 1.2. Installer estimates that the Work will be substantially completed within one hundred twenty(120)days following the Date (the"Completion Date"). Substantially complete shall be defined as the date the Owners receive a utility interconn ction,or similar such certification from the applicable authority. 1.3. If the Work is delayed at any time by causes beyond Installer's reasonable control,which causes may include,but not lie limited to, weather, acts of war or terrorism, material shortages, delays in the delivery of materials, Change Orders, inspection/permitting delays, labor disputes, design changes, hazardous site conditions, design flaws or impairments, subcontractor disputes,or Owner's use or directives,then the Completion Date will be extended for such equal number of days as occasioned the delay. In addition,the Completion Date may be extended for such reasonable time as O rter and Installer may determine in writing pursuant to a Change Order. 1.4. Installer shall have all materials required to commence the Work at the Premises no later than the Start Date. 1.5. Installer shall supervise and direct the Work in accordance with industry and regulatory standards, and it shall solely responsible for all construction means,methods,techniques,sequences and procedures and for coordinating all p rtions of the Work hereunder. 2. WARRANTIES OF INSTALLER 2.1. Installer warrants to Owner that all materials,equipment,and accessories incorporated into the Work by Installer will be new unless otherwise agreed in the Proposal Except for the warranty specified in this Section 2.1,Installer disclaims any and all warranties with respect to any materials,equipment,or accessories incorporated into the Work,it being the understanding of Owner that such warranties,if any,shall be provided by the manufacturer thereof. 2.2. Installer warrants to Owner that all labor and services provided by Installer and induded in the Work shall be of goad quality, free from material defects,and in material conformance with the Contract Documents. 2.3. Upon written notice from Owner delivered to Installer no later than the toyer anniversary date of the Comple on Date, Installer shall promptly correct any labor and services in breach of Section 2.2 above.Installer's obligation to promp y correct any labor and services in breach of Section 2.2 shall be Owner's sole and exclusive remedy for Installer's breach of .2 above. The provisions of this Artide apply to Work performed by third parties engaged by Installer as well as to work don by direct employees of Installer. 2.4. To the extent assignable,Installer shall pass through to Owner all original manufacturers'warranties and shall provi a Owner with its reasonable assistance in connection with any warranty claim against a manufacturer for defective materials, uipment, or accessories incorporated into the Work by Installer.Installer makes no representation or warranty regarding the aranties of manufacturers whose materials, equipment, or accessories are incorporated into the Work. Owner acknowl s that manufacturers'warranties may provide coverage to Owner for replacement of defective materials,equipment,or a essories, but that an individual manufacturer's warranty may not cover 100%of the costs and expenses borne by Installer to tro bleshoot and/or replace defective materials,equipment,or accessories.Payment to Installer for such uncovered corrective maintenance costs and expenses shall be Owner's responsibility. 2.5. Enhanced Product Warranty. In instances where Installer is required to troubleshoot and/or replace defective materials, equipment,or accessories incorporated into the Work by Installer prior to the first anniversary date of the Completion Date, Installer shall waive all of its direct labor costs associated therewith in excess of the amount covered by the manufacturer's warranty,and Owner shall not be required to pay Installer such excess amount.Within the first year following the Completion Date,Owner may optionally select to purchase an extension to Installer's Enhanced Product Warranty through the tenth anniversary date of the Completion Date. Battery storage equipment, electric vehicle charger equipment, and/or tracker equipment (single-or dual-axis) incorporated into the Work by Installer are not eligible for Enhanced Product Warranty coverage.With the exception of Installer's direct labor costs,other direct and indirect expenses(including equipment rentals) incurred by Installer in conjunction with the troubleshooting and/or replacement of defective materials, equipment, or accessories incorporated into the Work by Installer are also not eligible for Enhanced Product Warranty coverage. Page 3 of 6— SUNBUG SOLAR,LLC©2020 INSTALLATION AGREEMENT DocuSign Envelope ID:CECOBF60-8405-4C37-8C6A-70CCCC567503 2.6. Notwithstanding anything contained herein to the contrary,Installer's warranties and obligations under this Artide do not extend to(I)any materials,equipment,or accessories not selected by Installer or its agents,or to work performed by third parties not engaged by Installer, (ii) any damage to the Work due to weather,animal infestation,or other extern factors unrelated to Installer's installation workmanship, or (ii) the effectiveness of any accessories incorporated into tl�e Work induding,by way of example,pest abatement barriers(so-called critter guards)and snow abatement systems(so-cal,ed snow guards).Damage or defect caused by abuse,modifications not executed by Installer,improper or insufficient tenance, improper operation,or normal wear and tear shall void Installer's warranties and obligations hereunder. 2.7. Installer disclaims any and all warranties or guarantees with respect to the level of electrical production of the Project. Information with respect to electrical production of the Project is based on manufacturer's estimates of installed materials,and of peak sun hours,sun direction,and other factors.Factors such as dust,shading,snow,ice,weather,and other na viral and man-made elements,including usage,may adversely affect electrical production. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND IN LIEU OF ALL OTHER WARRANTIES OF Q ALITY AND PERFORMANCE, WHETHER WRITTEN, ORAL OR IMPLIED, AND ALL OTHER WA NTIES INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PAR CULAR PURPOSE, NONINFRINGEMENT OR USAGE OF TRADE ARE HEREBY DISCLAIMED. THE RE EDIES STATED HEREIN CONSTITUTE OWNER'S EXCLUSIVE REMEDIES AND INSTALLER'S ENTIRE BILITY FOR ANY BREACH OF WARRANTY. 3. COMPLIANCE WITH LAWS. 3.1. Unless otherwise specified in this Agreement,Installer shall secure all necessary permits,any applicable rebate applications, other governmental licenses and inspections necessary for the completion of the Project Unless otherwise specified in this Agreement,fees associated with acquiring such permits,licenses and inspections will be borne by Installer. I 3.2. Owner shall furnish at Owner's expense,all of the following as deemed necessary by the Installer 3.2.1. Legal descriptions (including legal limitations such as easements, rights of way, codes, covenants, conditions,restrictions,design guidelines),surveys and utility locations for the Premises;and 3.2.2. Any required engineering plans,drawings,calculations,or specifications(the"i, ") (i)in order to obtain any required non-ministerial permits or inspections,or(ii)in order to adequately s-cure the Premises and provide reasonable safety precautions.Owner acknowledges that some municipalitie.,utilities or other necessary permitting parties may require specific engineering studies or inspections in addition to those customary required or already obtained by Owner 3.3. Installer shall give all notices and comply with all laws,ordinances,rules,regulations,and lawful orders of any public authority . applicable to the performance of the Work,and shall promptly notify Owner if it has a reasonable basis to conclude that the designs,plans or Additional Plans are at variance therewith. 3.4. Installer shall be responsible for all safety precautions in connection with the Work. Installer shall take all legally required and commercially reasonable safety precautions at the Premises. 3.5. Installer and all subcontractors shall be registered as home improvement contractors and any inquiries relating to a registration should be directed to:Office of Consumer Affairs and Business Regulation Ten Park Plaza,Suite 5170 Boston,WA 02116 Phone:(617)973-8700 4. INSURANCE. Installer's liability insurance shall be purchased and maintained by the Installer to cover claims under workers' compensation acts and other employee benefit acts,daims for damage because of bodily injury,induding death,and from claims for property damage to the Premises which may arise out of or result from Installers operations under this Agreement,whether such operations be by itself or by any subcontractor or anyone directly or indirectly employed by any of them.This insurance shall be written for not less than the minimums required by the state where the Project is located under applicable law and state rebate programs.Certificates of such insurance shall be filed with Owner prior to the commencement of the Work at Owner(s)'request. Owner shall maintain liability insurance(either as separate policy or included in a homeowners or excess liability policy)sufficient to meet the Owner indemnity obligations under Section 8 below. 5. SUBCONTRACTORS,. Owner acknowledges that portions of the Work may be allocated to Subcontractors. Installer shall not employ any subcontractor to whom the Owner may have a reasonable objection. Installer shall not be required to con Tact with anyone to whom it has a reasonable objection.The Guaranteed Maximum Price includes the cost of a qualified electrician for electrical interconnection to the utility. Unless specifically noted in the Proposal, additional costs for any required electrical upgrades or improvements to the site's electrical service and components shall be the responsibility of Owner and are not included in the Guaranteed Maximum Price. 6. SITE CONDITIONS. Owner has no knowledge of any pre-existing toxic materials, hazardous substances, or detective or dangerous conditions,structural or otherwise which may pose a health or injury risk to Installer or Installer's employees or agents. Page 4 of 6— SUNBUG SOLAR,LLC©2020 INSTALLATION AGREEMENT DocuSign Envelope ID:CECOBF60-8405-4C37-8C6A-70CCCC567503 In the event that Installer observes hazardous site conditions,Installer will notify Owner promptly and Owner and Installer will,if feasible,execute a Change Order for the remediation of such conditions.Such hazardous conditions will postpone the Completion Date by the amount of days required to complete remediation. The Guaranteed Maximum Price includes the cost of basic site preparation,but does not indude the cost of any remedial site preparation as contemplated in this Section.The cost of such remedial site preparation shall be the responsibility of Owner. 7. INCENTIVE APPLICATIONS. Unless otherwise set forth in this Agreement,Installer shall apply for available incentives on behalf of Owner.Owner will assist Installer in such application process and warrants that all Owner information provided therein (including financial information,home value information and other personal information)shall be true,correct and complete as of the date of the application.Owner agrees that Installer will be listed as the primary installer/contractor on any application and be credited as the installer of record on all public documents and correspondence concerning the Project. Owner hereby acknowledges that Installer makes no warranty or guarantee of the availability of all,or any part of,any federal,state,local or utility incentives,tax credits or deductions.Owner is encouraged to consult with a tax advisor as to the availlabiliiy of tax credits with respect to the Pr ject. 8. INDEMNITY. 8.1. To the fullest extent permitted by law,Owner shall indempify,hold harmless and reimburse Installer,its agents and employees from and against all claims,damages,losses and expenses(including,but not limited to reasonable attorney's fees)wising out of or resulting from any death,bodily injury or illness or destruction to property,including any resulting loss of use thereof(i) due to a breach of Owner's warranty contained in the first sentence of Section 6 above or(A)to the extent resulting from the negligence or misconduct of Owner or its invitees or agents (other than Installer and its subcontractors). Owner's indemnification obligations herein are conditioned upon the following(a)it is promptly notified in writing;provided,that the indemnified party's failure to promptly notify shall not relieve the indemnifying party of its obligations hereunder to the extent the indemnifying party is not actually prejudiced,(b)Owner is allowed to exercise sole control over the defense of any claim and all related settlement negotiations(with counsel reasonably acceptable to the indemnified party);and(c)the indemnified party provides Owner,at Owner's expense,all reasonably necessary assistance,information,and authority to perform the above. The indemnified party shall have the right to participate in its defense with counsel of its own choosing at the indemnified party's sole cost and expense. 8.2. The foregoing notwithstanding,Owner will not make any offers of settlement nor enter into any settlement agreements without the written consent of the indemnified party,which consent will not be unreasonably withheld or delayed. 9. LIMITATIONS ON DAMAGES AND LIABILITY. Except in connection with Owner's obligations under Sectioili 8,each party's liability to the other party for any loss,cost,claim injury,liability,or expense,including reasonable attomey's fees,relating to or arising from any act or omission in its performance of this Agreement,shall be limited to the amount of direct damage actually incurred. Except in connection with Owner's obligations under Section 8,in no event shall either party be liable to the other party for any indirect, incidental, special, consequential, or punitive damages of any kind whatsoever. This waiver shall survive any termination of this Agreement. 10. CHANGE IN THE WORK. Owner,without invalidating this Agreement,may seek changes in the Project consisting of dditions, deletions,or modifications.In addition,changes in the Project maybe necessitated by permitting or regulatory requirements All such changes in the Project shall be authorized by a written Change Order signed by Owner and Installer. Installer will advise er of the cost of a proposed Change Order,and,if executed,the Guaranteed Maximum Price or price per watt will be adjusted ac ordingly. All Change Orders will include revision of the Completion Date. 11. TERMINATION. 11.1. If a Change Order is necessary to complete the work,either party has the option to terminate the agreement. 11.2. Either party may terminate this Agreement by a written notice(a"Default Notice")if the other party commits an material breach of this Agreement;provided,that if such breach is capable of cure,such party shall have seven(7)days fo wing its receipt of a Default Notice(the"Cure Period")to cure such breach to the non-breaching party's reasonable satin ction.If such breach is not cured prior to the expiration of the Cure Period,the non-breaching party may terminate this eement immediately by written notice. By way of example only,material breaches include the following. (a)Owner fails make a payment when due(in which event Installer may,in its discretion,also suspend work until payment is made);(b)O er fails to promptly execute a Change Order necessitated by a revision in the Minimum Technical Requirements of a permitting body or regulator,(c)Installer persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; (d) Installer fails to make payment to subcontractors for materials or labor in accordance with the respective agreements between the Installer and subcontractors;and(e) Installer persistently disregards laws,ordinances,or rules,regulations or orders of a public authority having jurisdiction. 11.3. If the CEC Loan Approvals are not obtained,this Agreement shall automatically terminate unless Owner provides Installer with prompt written notice that it wishes to proceed with the Project. 11.4. Either Owner or Installer may terminate this Agreement upon fifteen(15)days prior written notice,if the parties are unable to promptly agree on the terms of a Change Order reasonably necessary for the completion of the Project(,g.,changes due to regulatory requirements or hazardous conditions). Page 5 of 6— SUNBUG SOLAR,LLC©2020 INSTALLATION AGREEMENT DocuSign Envelope ID.CECOBF60-8405-4C37-8C6A-70CCCC567503 11.5. If this Agreement is terminated for any reason,Owner shall pay Installer for all work completed and materials used through the date of termination. 11.6. Notwithstanding anything to the contrary set forth herein,Sections 2,the first sentence of Section 6,8,9,11(d),11($),12,13 and 14 of this Agreement and any remedies for the breach thereof,shall survive the termination of this Agreement under the terms hereof. Termination of this Agreement shall not relieve or release either party from any rights,liabilities or obligations which it or she has accrued prior the effective date of such termination. 12. CHOICE OF LAW. This Agreement shall be governed by the internal laws of the Commonwealth of Massachusetts without regard to principles of conflicts of laws. Disputes arising hereunder shall be adjudicated solely and exclusively in Boston,Massachusetts. 13.13. PROMOTIONAL USE OF PROJECT. Installer may use the description and images of the Project along with any supplied recommendations or testimony of Owner for promotional purposes. (If promotional consent not granted,or if owner requires individual prior written consent,check here:❑) 14. GENERAL PROVISIONS. This Agreement set forth the entire agreement and understanding between Owner and Installer relating to the subject matter hereof and merges all prior discussions between them. If any one or more of the provisions in this Agreement are deemed void by law,then the remaining provisions will continue in full force and effect. No waiver by eit.ier party of any term or condition of this Agreement,whether by conduct or otherwise,in any one or more instance,shall be deemed a continuing waiver of any such term or condition,or a waiver of any other term or condition of this Agreement. Headings set forth in this Agreement are solely for the convenience of the parties and have no legal effect The singular shall include the plural,and the masculine gender shall include the feminine and neuter,and vice versa,unless the context otherwise requires.This Agreement may be executed and delivered either originally or by facsimile transmission,and in one or more counterparts,each of which shall be deemed an original and all of which taken together shall constitute one and the same instrument. This Agreement shall be(I)binding upon,and will inure to the benefit of,the parties and their permitted respective successors and assigns and(ii)constru without presumption of any rule requiring construction to be made against the party causing it to be drafted. Page 6 of 6— SUNBUG SOLAR,LLC©2020 INSTALLATION AGREEMENT 1 BATTERY LOCATION DIAGRAM WALL DETAIL (N.T.S) 2 EXISTING WALL S 3 `W(N)SEBACKUPINTERFACE A (wall mounted on new*wood) N (N)LUMIN SMART PANEL (wall mounted on existing plywood) co Q (E)MAIN SERVICE PANEL 36"WORKING CLEARANCE r o (wall mounted on existing plywood) BASEMENT c7 0 EXISTING EXISTING REQUIRED IN FRONT OF ALL INTERIOR L Q CONCRETE CONDITIONS (E)HVAC EQ IIPMENT mountedoo boalyds) ELECTRICAL EQUIPMENT . WALL (E)DOUBLE LVL CENTER BEA co z (ceiling,outside of fireproofing area) "' — (N)ENERGY HUB INVERTER ? w (wall mounted above battery side clearance) \ p� rD E' (E)FORMER SHELVING AR u. 1 (to be moved by customer prior to install) n (N)LG RESUI6H PRIMES*'-4— C 19.80 It •' LOCATION OF BATTERY (N.T.S) (floor mounted,add fireproofing 24" u on either side and on ceiling above) 3 -- f (E)SHELVING AR • (to remain) L Scale:8"=1'-0" r lI GENERAL NOTES AND DIMENSIONS ° � I A I LIGHTING AND FIRE DETECTION B FIRE PREVENTION C BATTERY SPECIFICATIONS D VEHICLE IMPACT PROTECTION Existing lighting in basement for -Fireproofing:I"Type X Gypsum Board -Battery Type:LG RESU16H PRIME -Bolt down bollard(s)installed to protect ' batteries (floor mount) batteries from vehicle impact / -Existing finished walls require ' -Existing hard-wired smoke detector fireproofing for 24"around battery and -Battery Size:19.8"x42.8"x11.6",352.0 lbs -If multiple bollards are installed,keep in basement for batteries on ceiling above if material is not spacing between 3-5 feet to allow access, IQ naturally fireproof(i.e.concrete) -Minimum Battery Clearances:20"above, without allowing vehicles to pass. E 12"on left and right,36"in front s E DENTI"L JOB REFERENCE: 3686-Wes-W ¢¢Holmes,Joseph SYSTEM SIZE: 7.3 kW DC 7.6 kW AC REVI IONS THE INFORMATION HEREIN CONTAINED SHALL NOT W P DES(%tIPTIOk DATE REA BY: BE USED FSOLAR TR E oc,BENEFIT OF ANYONEBnsa.o =.y SUNBUG OTHERS OUTSIDE NOR SHqurOL asaosED MOUNTING SYSTEM SnapNRack Ultra Rail Racking 117 Olander Dr.Unit 12 STORAGE: (1)LGRESU16H Prime Battery a4eaews sBSaYg a 2 Nye .7fl11 �- TOOTHERS OUTSIDE OF SUJBAS SOLAR LUG, SATHOUT CONSENT ORRN CONNECTIONMiTH AE MODULES: (20)Hanwha O.Peak Duo 365 B08//(20)5440 Northampton,MA 01060 UTILITY: NationalGrid SALE AND USE OF THE RESPECTIVE SLN IUG SOLAR niA H.,hm Ave.SN 312 LLC SYSTEM ^ vie,MA@1M NVERTER SolarEd eEner Hub-SE7600H 978844-1182 TAW)505'�F�°'n"a3az 8 gY SHEET TITLE:ESS OVERVIEW SHEET NUMBER:1 SFEET SIZE:I x1T wym..wmupso..m., a1 f 1. (E) DOUBLE LVL CENTER BEAM (N)8"GYPSUM BOARD (24"around battery and ceiling above) --41------"' 2 i 1 '-8 " i ......_ ..„....„,,,, (E) HVAC EQUIPMENT AND PIPING (N)SE7600H-US ENERGY HUB \ INVERTER \ C. -,j II .: , (E)SHELVING 8 , „. ,......_, _ • TO REMAIN 5y 11 (N)LG RESU16H PRIME (E)SHELVING TO REMAIN I Aso:,.. ....., CONK DENTAL JOB REFERENCE. 3686-Wes-W ., Holmes,Joseph SYSTEM SIZE. 7.3 kW DC 7.6 kW AC REVI IONS THE INFORMATION HEREIN CONTAINED SHALL NOT w P DESCRIPTION. DATE'. REV. BV'. BE USED FOR THE BENEFIT OF ANYONE EXCEPT Ongnul 01162022 1 GA a, suNBucsaARLLC NOR SHALL IT BE DISCLOSED MOUNTING SYSTEM SnapNRack Ultra Rail Racking o 117 Olander Dr.Unit 12 STORAGE: (1)LGRESU16H Prime Battery Mt.Edits Ekancausssa y 962022 2 NB 0.SUn S Ia TO OTHERS OUTSIDE OF SUNBUG.SOLAR LLC, - YATHOUTCsEOF oRMpFo,CONNECTION wTHTL MODULES. (20)Hanwha Q.Peak Duo 365 BoB//(20)5440 Northampton,MA 01060 UTILITY. NationalGrid MIA No.Ae au H1 SALEANDM OF THE REBPECTNE SUNBUG$OUR LLC SYSTEM Sword.NA02141 978-844-1182 T Rn 930.33 emaax F(6Y7)AnaOs INVERTER: SolarEdge Energy Hub-SE7600H SHEET TITLE:ESS PROFILE SHEET NUMBER 2 sHeeTsIZE.>»11r ....,.sunlupsdar.con • f I— : Cp..7 rn LU 00 wLLJ :ZIP . • - . _� ' - :;. O _ ' „ UJ II I--l1—r— LL1 1.w II R, J '•'• •° _1W \ 4° W ~ 1co �__ , 1► Ct 0 D 1 LOCAL UTILITY PROVIDER SHALL BE NOTIFIED PRIOR TO USE AND ACTIVATION OF ANY Ct 1 I SOLAR PHOTOVOLTAIC INSTALLATION w 1 • THIS PROJECT SHALL COMPLY WITH LOCAL ORDINANCES Q I PROPER ACCESS AND WORKING CLEARANCE WILL BE PROVIDED I • ALL ELECTRICAL WORK SHOWN ON THESE PLANS WILL BE COMPLETED BY THE Z1[1-1 UNDERSIGNED 1 • ALL APPUCABLE PV EQUIPMENT LISTED AND COMPLIANT WITH UL2703.UL1741 AND UL1703 1 1 1L:1 Ci) • ALL ROOF PENETRATIONS TO BE SEALED WITH A HIGH PERFORMANCE ROOF SEALANT SUCH J I JI AS Ge0Ce1 2300 CLEAR SEALANT O \ • THE SYSTEM WILL NOT BE INTERCONNECTED UNTIL APPROVAL FROM THE LOCAL JURISDICTION AND THE UTILITY IS OBTAINED \ • THE SOLAR PHOTOVOLTAIC INSTALLATION SHALL NOT OBSTRUCT ANY PLUMBING. 1 MECHANICAL,OR BUILDING ROOF VENTS A �L • IF THE EXISTING MAIN PANEL DOES NOT HAVE VERIFIABLE GROUNDING ELECTRODE,IT IS NECESSARY TO INSTALL A SUPPLEMENTAL GROUNDING ELECTRODE \ -' A • EACH MODULE WILL BE GROUNDED AS PER UL 2703 OR UL 1703 APPROVED METHOD USING THE SUPPLIED CONNECTION POINTS IDENTIFIED ON THE MODULE AND THE MANUFACTURER'S INSTALLATION INSTRUCTIONS • A LADDER SHALL BE IN PLACE FOR THE INSPECTION IN COMPLIANCE WITH OSHA REGULATIONS • ALL WORK SHALL.COMPLY WITH 2020 NEC,2015 IRC.2015 IBC MUNICIPAL CODE,AND ALL MANUFACTURERS'LISTINGS AND INSTALLATION INSTRUCTIONS. LEGEND • PHOTOVOLTAIC SYSTEM WILL COMPLY WITH 2017 NEC. N • PHOTOVOLTAIC SYSTEM INVERTER IS UNGROUNDED.NO CONDUCTORS ARE SOLIDLY GROUNDED IN THE INVERTER,AND SYSTEM COMPUES WITH 690.35. PROPERTY LINES • MODULES CONFORM TO AND ARE LISTED UNDER UL 1703. Scale:1"=30,-0, 4811 yrINVERTER CONFORMS TO AND IS LISTED UNDER UL 1741. ; • ELECTRICAL EQUIPMENT AND MATERIAL TO BE USTED,LABELED,AND INSTALLED PER THE 0 30' 60' E • NEC.THE INSTALLATION STANDARDS/MANUFACTURER'S RECOMMENDATIONS AND IF SETBACKS REQUIRED A RECOGNIZED ELECTRICAL TESTING LABORATORY. mom •I• • immoslS • CONDUITS EXPOSED TO SUNLIGHT ON ROOF SHALL BE LOCATED NOT LESS THAN 713'ABOVE ROOF SURFACE. CONFIDENTIAL 1I0B REFERENCE: 3686-Wes-W W Holmes,Joseph SYSTEM SIZE: 7.3 kW DC 7.6 kW AC REVI IONS TIE INFORIAATON HERON CONTAINED SHALL NOT T p DESCRIPTION. DATE. REV BY BE USED FOR THE BENEFIT OF ANYONE EXCEPT Ong nal 30 &1B/l0-2 1 GA L+' SJIEUC SOLAR LLC,NOR SHALL ITBEDISCLOSED MOUNTING SYSTEM SnapNRack Ultra Rail Racking 117OlanderDr.Unit12 STORAGE (1)LGRESU16HPrimeBattery Mu Ed. 9.6¢O22 - NB 51111 soar TO OT/ERS OUTSIDE OF SUNBUG SOUR LLC. MT/OUT CONSENT OR INLVHIAEX PATH THE MODULES. (20)Hanwha Q.Peak Duo 365 BoB//(20)5440 Northampton,MA 01060 UTILITY: NationalGrid zAa.Pawe SALE AND USE OF THE RESPECTIVE SUJB.G SOUR - -LLC SYSTEM — 2AOn NA meet TROT 5- 978-844-1182 0U3026 F.(617)412.3062 INVERTER. SolarEdge Energy Hub-SE7600H _ - SHEET TITLE. PROPERTY PLAN SHEET NUMBER 1 SHEET WI11'x1T re6w surtogsoMrcan E) BULKHEAD r ' (on north side of house, basement access) I I O O (N) LG RESU16H PRIME BATTERY (basement, near inverter) ,,--r:rP1 -170°az, 27°tilt (N) INVERTER (20) Hanwha Q.Peak 365 BoB (basement, wall adjacent to MSP) O (20) SE440 ,.-ram — 14 (E) MAIN SERVICE PANEL AG OP'-(N) (basement) O — �(N) SE BACKUP INTERFACE & LUMIN PANEL `+ / (basement, near MSP) S (E) UTILITY SERVICE METER (exterior) N) MA SMART METER LEGEND (N)AC DISCONNECT (at Utility Meter) I0I UTILITY METER&WARNING LABEL Scale:3/16"=1' (at Utility Meter) ri INVERTER&WARNING LABELS 01' 1G 32' �. DC DISCONNECT&WARNING LABELS �- AC DISCONNECT&WARNING LABELS CONFIDENTIAL JOB REFERENCE: 3686-Wes-W w Holmes,Joseph SYSTEM SIZE 7.3 kW DC 7.6 kW AC REVI IONS THE INFORMATION HEREIN CONTAINED SWILL NOT PDESCRIPTIONS. DATE. REV BV: BE USED FOR THE BENEFIT OF ANYONE EXCEPT Onglnal 8I18I2022 1 GA !.Y ["'� SUNBUG SOLAR LLC.NOR SHALL IT BE DISCLOSED MOUNTING SYSTEM. SnapNRack Ultra Rail Racking o 1170Iander Dr.Unit 12 STORAGE: (1)LGRESU16H Prime Battery Mx Edits B EMttnraLESS ON srea0u NB 1 saw. TO OTHERS OUTSICE OF SUN'BUG SOUR LLC, NITHOUT CONSENT OR IN CONnECTOR 44TH TEE MODULES: (20)HanwhaCJ.PeakDuo365808//(20)S440 Northampton,MA01060 UTILITY: NationalGrid ,,,A„y,,„„µ,,�,,,,,, SALE AND USE OF TIE RESPECTIVE SUNBLG SOLAR LLCSYSTEM 978-844-1182 T Sw�.rvib,MA02I14 INVERTER: SolarEdgeHub-SE7600H SHEET TITLE:SITE PLANre+nAxAsunnntO-NMwsdanAI2'°°: g EnergySHEET NUMBER:2 SHEET II'A1r mgaMca ATTACHMENT PLAN N LAYOUT PLAN -MAX.RAIL OVERHANG 16" -MAX.RAIL SPAN 4B' ;i E p -POSITION RAILS 8..7B"/MIN:H25.S(M rl A 4FROM Fr nF annul FCJDLPORL_ - - -STAGGER STANDOFFS,SEE STRUCTURAL REPORT S ROOF FRAMING AND SURFACE DETAILS SURFACE TYPE:ASPHALT SHINGLES(MP1) MP1 RRFTERsa.TRUSS o'oc 170°AZIMUTH 27°TILT 37 MP2 WA N/A N/A MP31 NIA N/A N/A 11-1" 341-10" _ ARRAY POSITION POSITION MP1 ROOF ARRAY AS DIMENSIONED ON ROOF I I I I I I I 1 I I I I I I I I I CII 1 1 I I I 1 I I I I ; ; l -- ( v -e -� -s �- -e a -,-, ADDITIONAL WORK CRITTER GUARDS WA • INVISIBLE END CLAMPS WA SNOW GUARDS WA 1 ('T- SERVICEUPGRADE N/A _- STRUCTURAL NO REINFORCEMENT REQUIRED I 1 I t I REINFORCEMENT — t I i I -3� SPECIAL PERMITTING I I I I T• - - T IY' T T 'T -- 1 ROUGH INSPECTION REQUIRED.EMAIL BUILDING PERMIT APPLICATIONS, I 15 SEE GID FOR DETAILS.IF NEW CONSTRUCTION/SERVICE,EMAIL WORK REQUEST NUMBER TO ELECTRICAL INSPECTOR ONCE RECEIVED FROM UTILITY. i -- -++;- ♦1♦ — EQUIPMENT LOCATION -F- -4-- --T-- " 2- • INVERTER MOUNT INVERTER IN BASEMENT NEAR BATTERY I I 1 1 I •. -i PROD.METER MOUNT MA SMART METER SOCKET OUTSIDE NEAR AC DISCO,LEAVE METER SOCKET EMPTY 1 1 11 AC DISCONNECT INSTALL WITHIN 10 FT OF UTILITY METER, 3-2 MUST BE READILY ACCESSIBLE 1 PROJECT NOTES SNR MID CLAMPS,END CLAMPS,RAIL SPLICES TORQUE TO 10FT-LBS M P 1 Bulkhead act,to basement on north mge Eaboeg combat from a.to basemen.Comes out near inverter Matron SOMrEdge Energy Hub 7600-LGRESU16.lumin panel NO whole Tome backup setup.Fee 2400 breakers In Lunn pane/(SEE SIDI.WEI Router currently on second flop.Customer contemplating mamg 1 to basement fa us A be must haMwre. Mounting Materials Estimate fOam layer over concrete warts.Customer strongly prelers epu,pment s as conso/dated as rasslbB. Actual site conditions may Vary Synth light and wired smoke detector mreaN across from equipment wall SnR Attachments 39 SnR UltraRail(total length) 145 ft Mid Clamps 36 End Clamps 8 CONFIDENTIAL JOB REFERENCE. 3686-Wes-W ee Holmes,Joseph SYSTEM SIZE: 7.3 kW DC 7.6 kW AC REVI IONS THE INFORMATION HEREIN CONTAINED SHALL NOT P DESCRIPTION: DATE'. 1 REV. BY' BE USED FOR THE BENEFIT OF ANYONE EXCEPT GA /el SUNBUG SOUR LLD.NOR SHALL IT BEGSLOSED MOUNTING SYSTEM: SnapNRack Ultra Rail Racking 11170Iander Dr.Unit 12 STORAGE: (1)LGRESU16H Prime Battery A tEab S Etectnu4ESSlog Ss'iewa 2 .S{/11Dug Solar TO OTHERS OUTSIDE OF SUNBUG SOLAR LLC. YNTHart CONSENT OR IN CONNECTION WITH THE MODULES: 20 Hanwha MA 01060 UTIUTY: SALE AND USE OF THE RESPECTIVE SUNN,c SOUR ( ) Q.Peak Duo 365 BoB//(20)S440 Northampton, NationalGrid 111A moans Awl,514.312 LLC SYSTEM S revlk.MA 0I111 978-844-1182 T(617)STO.BASS F SIG)a130C1INVERTER: SolarEd eEnerBY Hub-SE7600H SHEET TITLE:CONSTRUCTION PLAN SHEET NUMBER:3 SHEET SIZE InIT WnwSuntalgSdaf wn MOUNTING PLAN l'.` i � / i �� �,; = i I 4.1,lRo 'n�" ss RAF ?'IOC 4. if."---- 1 N ,it_ 4 s ry. it it Ii II i I S MOUNTING METHOD 2 S AE1 4* 6" SNAPNRACK SNAPNRACK ® - ULTRA RAIL END CLAMP _ 4 OR UNIVERSAL SNAPNRACK PV MODULE L-FOOT / ',Or .! ULTRA RAIL SNAPNRACK FLASHING 4 MOUNTING 5116"X4"S.S.LAG SCREW HARDWARE MIN 2.5"EMBEDMENT RAIL POSITION PLAN VIE1 1 MOUNTING DETAIL SCALE va••ru' I SCALE 3'•r4' 3 4 '' 7 CONFIDENTIAL JOB REFERENCE: 3686-Wes-W w Holmes,Jose h SYSTEM SIZE: 7.3 kW DC 7.6 kW AC REVI IONS THE INFORMATION HEREIN CONTAINED NOT P DESCRIP110N: pA1E'. REV BY SE USED FOR THE BENEFIT OF ANYONE EXCEPT Opel 1118/2022 T GA del suNeuc SOLAR LLC NOR SHALL IT BE DISCLOSE) MOUNTING SYSTEM: SnapNRack Ultra Rail Racking o 117 Olander Dr.Unit 12 STORAGE: (1)LGRESU16H Prime Battery uw EEY i EYBLn4ESS bog 9412171 2 NB Sun Rug SUdar TO OTHERS OUTSIDE OF SUNBUG SOLAR LLC, WITHOUT CONSENT OR IN CONNECTIONIMTH DE MODULES: (20)Hanwha Q.Peak Duo 365 BoB//12015440 Northampton,MA 01060 UTILITY: NationalGrid a„AH SALE AND USE OF THE RESPECTIVE SUNBLE SOLAR O.Ave.SuR 3,2 LLC SYSTEM Soirervol"MA . 978-844.1182 61n500.3936 F cs,Tc<,axszINVERTER: SolarEdge EnergyHub•SE7600H SHEET TITLE MOUNTING PLAN SHEET NUMBER:4 SHEET SIZE:ntTr .s.„s.N,,,ola,cam INVERTER: SE 7600H-US Energy Hub MAX DC INPUT POWER: 15200W - - DC INPUTS: 1-2 PV STRINGS, 1 COMBINED BATT. INPUT OPTIMIZER: S440 MAX POWER PER STRING: 5700W MIN STRING LENGTH:8 STRING 1 - 10 MODULES STRING 2 - 10 MODULES CONFIDENTIAL JOB REFERENCE 3686-Wes-W Holmes,Joseph SYSTEM SIZE: 7.3 kW DC 7.6 kW AC REVI IONS THE INFORMATION HEREIN CONTAINED SHALL NOT PDESCRIPTION. DATE'. REV BY: REUSED 9FOR THE ERLBENOR HF ANYONE IXCEPi Or &1N2p0 I GA TOOTH SOLAR NFSUNB uiSLARLLCDISCLOSED MOUNTING SYSTEM. SnapNRack Ultra Rail Racking 117()lender Dr.Unit 12 STORAGE: (1)LGRESU16H Prime Battery Mnccaw EENEYXA ESSEeg 4'64V:2 a Na War TO OTHERS OUTSIDE OF SLRSLG SOLAR LLC, SATHOUTLSEOFT OR IN CONNECTIDNBTH ME MODULES (20)Hanwha Q.Peak Duo 365 BoB /20 5440 Northampton,MA 01060 UTILITY: NationalGrid a3AI06M Aa.9N3R SALE AND..SE OF-HERESPECTIVE SUM3UG SOLAR / ( 1 978-844-1182 6Ie17)502.44x'F(81041 3082 INVERTER: SolarEdge Energy Hub-SE7600H SHEET TITLE STRING DIAGRAM SHEET NUMBER.5 SHEET SIZE:1111T vmw.wHx6mMtcam Utility Info Existing Electrical Specs(E) lie in Description Inverter Specs Module Specs General Notes NabonalGnd Eaton Tie-In:Back-Feed Breaker Inv I SolarEdge SE7600H-US Energy Hub 20 Hanwha QPEAK DUO BLK-G10+365 200A MSP with no main Meter Number: ' 05706443 Panel Info 200A/2P Main Breaker 7600 W,240V,99%,AFC! 365 W 343.59 W PTC breaker. Meter/main outside. Service Entrance Underground 200A Rated Main Panel Inv 1:DC Ungrounded VOC:41.21 Vpmax: 34.58 SE whole home backup with 240V 10 Inc And Imp Are Shown in the DC string labels Lumm panel on 5 large toads. A 1 I Soladeck 1 (N)SOLAREDGE BACKUP INTERFACE I Uunction Box PHOTO VOLTAIC SYSTEM EQUIPPED WITH RAPID SHUTDOWN BI-NUSGN-01 1 Inverter 1 MA SMART © 1x10 365W PANELS 0 AUTO TRANSFER RELAY 5 O BOA Non-Fused T SOLAREDGE With iX10 540 Meter AC Disconnect SE76WH Energy Hub ` a. rrh o _, .1Q� AT u . r_( _; • • OPTIMIZERI,' , U I i 11 r • AUTO- --.,. N .. a N •• \\ TRANSFORMER I _ ■ ■ - I .� . I 2 1x10 365W PANELS i g 11 , G� -- -- a---12----11, �. t 0 . . °a �4�r�+ WN1,X,08440 ,— a WI 9 I 7 u �, r=- Q- �-- �- I �_�_ • • _ / OPTIMIZERS I iii f r I Exterior utility-owned - Exteror AC asronrx:d 1� ,, production meter ---s`=n'd i ROOFTOP mA � .. n EXTERIOR AT UTILITY METER Storage Charging Capability:Generation Only V�N��«��������M�����N���J (El 2'CONDUIT FROM i Storage Discharging Capability Restricted Electric Grid or Onsite Load EGa ATTIC TO BASEMENT i (E) fgEC GEC i r ,I o (E)200A MAIN PANEL (2)AWG#6.THWN-2 I- N Lz Li GEO,i T (1)AWG#10 EGC Gnd TO120/210V ILx..- ,,._ -I (I' I( ICTR + SINGLE PHASE LG RESUISH PRIME BATTERY SPECS UTILITY SERVICE I ! USEABLE ENERGY:16kWh I )�LOADa VOLTAGE:350-450V (N)LUMIN - MAX POWER(CONT.lBsII: I. . SMART PANEL MAX PCMER(PEAKI10s0:11.Odcw SMART LOAD LG RESUI61; MANAGEMENT PRIME BATTERY EXTERIOR (pro lzdreDRs) __ BASEMENT OF HOME _ g DC Disconnect Label J —Jr I S440 STRING REQUIREMENTS I AC Disconnect Label MINIMUM LENGTH: A - BASEMENT OF HOME MAXIMUM POWER. 5700 W - 6 (3)AWG 2/0,THWN-2,SER V=240V Imax= 200 A 5 (3)AWG#8,THWN-2 Vmp=240V Imp= 32 A 3 (2)AWG*10,THWN-2 Voc=480 Inc=15 1 (2)AWG*10,PV Wire Voc=480 Inc=1S (1)AWG*6,THWN-2,EGC/GEC Gnd (1)AWG*10,THWN-2,EGC/GEC Gnd 40 ft(I)AWG*10,THWN-2,Gnd Vmp=480 Imp=7.51 40 ft(1)AWG*6,Bare Cu EGC Vmp=480 Imp=7.51 :'.r, 2"CONDUIT o I'CONDUIT 4 (2)AWG#10,THWN-2 Voc=480 Inc=15 2 (2)AWG#10,PV Wire Voc=480 Isc=15 X' 40 a(1)AWG#10,THWN-2,Gnd Vmp=480 Imp=7.51 40 ft(1)AWG#6,Cu EGC Vmp=480 Imp=7.51 (E)2'conduit from attic to basement r CONFIDENTIAL JOB REFERENCE: 3686-Wes-W w Holmes,Joseph SYSTEM SIZE 7.3 kW DC 7.6 kW ACREVISIONS THE INFORMATION HEREIN CONTAINED SHELL NOT p DESCRIPTION GATE. REV'. BY SENSED SORMEeENOR S OF HALL aBE EXCEPT 3Ou ExI B�,Brig21 I OA �Wg S3{ol SUNKJG FSONALATOLARLLC DISCLOSED MOUNTING SYSTEM SnapNRack Ultra Rail Racking o 11701anderDr.UnR12 STORAGE: (l)LGRESU16H Prime Battery MecEabaEWfiaYEnSag wsrzon a Na lei TO TIetUT CONSENT GE OF SUN&1G SOLAR L LC. —- - YMTHOUrcoNSENTORIN CONNECTION OATH TOE MODULES: (20) Northampton,MA 01060 UTILITY: NationalGrid SALE AND USE OF THE RESPECTIVE SINBUG SOLAR Hanwha Q.Peak Duo 365 Bob//(20 5440 FHA HOW Awn in ILC SYSTEM �n•nIA MAW M INVERTER: SolarEdge EnergyHub-SE7600H 978-844-1182 r�ro+ .w.sne Fllutern n gSHEET TITLE:ELECTRICAL DIAGRAM SHEET NUMBER:1 SNEETSItE:1171r nr.w o„r powered by Q.ANTUM f ouol© 1 \ \ \ \ \ \ \ \ , Quality Q.PEAK DUO BLK-G10+ Controlled PV TUVRhelnland 350 370 , CERTIFIED i w 111123 61 ENDURING HIGH lit 25YR r PERFORMANCE �O EUPD RESEARCH ' TOP BRAND PV ' MODULES EUROPE A 2021 USA Warranty CI CELLS P, y ry,b,„.0. Yield Security �Jf�In BREAKING THE 21%EFFICIENCY BARRIER nl ll ll l Q.ANTUM DUO Z Technology with zero gap cell layout boosts module efficiency up to 20.9%. THE MOST THOROUGH TESTING PROGRAMME IN THE INDUSTRY Q CELLS is the first solar module manufacturer to pass the most compre- -g hensive quality programme in the industry:The new"Quality Controlled -04 PV"of the independent certification institute TUV Rheinland. i INNOVATIVE ALL-WEATHER TECHNOLOGY ��; Optimal yields,whatever the weather with excellent low light and temperature behaviour. ENDURING HIGH PERFORMANCE � Long-term yield security with Anti LID Technology,Anti PID l V 1 Technology',Hot-Spot Protect and Traceable Quality Tra.QTm. EXTREME WEATHER RATING High-tech aluminium alloy frame,certified for high snow(8100 Pa)and wind loads(4000 Pa). A RELIABLE INVESTMENT vlinear Inclusive 25-year product warranty and 25-year performance warranty2. CELL TECHNOLOGY APT test conditions according to IEC/TS 62804-1:2015,method A(-1500 V,96h) 2 See date sheet on rear for further information. THE IDEAL SOLUTION FOR: 6,_?1 Rooftop arrays on residential buildings Engineered in Germany Q CELLS r MECHANICAL SPECIFICATIONS Format 67.6 in x 41.1in x 1.26 in(including frame) 87.8•(1717 mm) (1717mm x 1045mm x 32mm) 35s•(9eomm) insnmm.5mm) Weight 43.8lbs(19.9 kg) 1 I, i t , IFront Cover 0.13in(3.2mm)thermally pre-stressed glass with anti-reflection technology 4,,Grounding WIm4.0.18•(4.5 mm) 3.misoFran*- Back Cover Composite film 39.5'(1002.5mm) Frame Black anodized aluminum 41.1.(1045 mm) Cell 6 x 20 monocrystalline Q.ANTUM solar half cells Junction Box 2.09-3.98 a 1.26-2.36 x 0 59 0.71in(53-101 x 32-60 x 15-18mm), Label--0 .4u3•(v50mm) Protection class IP67,with bypass diodes ... 4.rw°mm9.wts Cable 4 mm2 Solar cable,(+)>45.3 in(1150 mm),(+)>-45.31n(1150mm) , (DETAIL A) 8.Dmm49•nob4 Connector Staubli MC4;IP68 I ` ! ... --1 -32a•(32mm) DETAIL 0.63'(1amm) 0.837.(21.25 mm)I-C=I0.3T(9.5 mm) 1 ELECTRICAL CHARACTERISTICS POWER CLASS 350 355 360 365 370 MINIMUM PERFORMANCE AT STANDARD TEST CONDITIONS.STC'(POWER T(ll nE a5W/-0 Power at MPP' PMPP [W] 350 355 360 365 370 Short Circuit Current' I5- [A] 10.97 11.00 11.04 11.07 11.10 E -- Open Circuit Voltage' V02 [V] 41.11 41.14 41.18 41.21 41.24 E E Current at MPP I MPP [A] 10.37 10.43 10.49 10.56 10.62 Voltage at MPP VMpp [V] 33.76 34.03 34.31 34.58 34.84 Efficiency' n IN ->19.5 ?_19.8 >_20.1 s20.3 L.20.6 MINIMUM PERFORMANCE AT NORMAL OPERATING CONDITIC ' .NMOT2 Power at MPP Pr,(PP [W] 262.6 266.3 270.1 273.8 277.6 E Short Circuit Current isc [A] 8.84 8.87 8.89 8.92 8.95 E Open •Circuit Voltage Vic [V] 38.77 38.80 38.83 38.86 38.90 F Current at MPP IMpp [A] 8.14 8.20 8.26 8.31 8.37 Voltage at MPP V [V] 32.24 32.48 32.71 32.94 33.17 'Measurement tolerances P,,,M,±3%,ILA;Voc±5%at STC:1000 W/mz,25±2°C,AM 1.5 according to IEC 60904-3•'800 W/m2,NMOT,spectrum AM 1.5 _._.. _ ... _.. .-- -.. Q CELLS PERFORMANCE WARRANTY PERFORMANCE AT LOW IRRADIANCE u: 0. - cE"s At least 98%of nominal power during Z.u0 T r w°. .. I, I,V$lemero,Mrws,exbt I first year.Thereafter max.0.5% u LL a » degradation per year.At least 93.5% 0 ' I of nominal power up to 10 years.At c No i L least 86%of nominal power up to I a �° 25 > wyears. I- no -r r -r .---- - All data within measurement toleranc- g I i e; es.Full warranties in accordance with rb i I a` the warranty terms of the Q CELLS 200 w 400 o 000 MOO '2 o m sales organisation of your respective IRRADIANCE WWI u 9 e 19 1• m a country. cc'v ' °te m �w a9mwm,m.l0 w ..,°°,P° YEARS Typical module performance under low irradiance conditions in N *me now pa...8-185 0 n 2014(ea4S9144.4,4,20,4, comparison to STC conditions(25°C,1000 W/m2). o TEMPERATURE COEFFICIENTS ,? I en.pelaiweCueis,creniofis, a [%/K] +0.04 Temperature Coefficient of V„ P [%/K] -0.27 8. Temperature Coefficient of Pm, y 1%/K -0.35 Nominal Module Operating Temperature NMOT F 109±5.4 43±3°C 8 0 D PROPERTIES FOR SYSTEM DESIGN a a Maximum System Voltage V3,5 [V] 1000(IEC)/1000(UL) PV module classification Class II p Maximum Series Fuse Rating [A DC] 20 Fire Rating based on ANSI/UL 61730 TYPE 2 W Max.Design Load,Push/Pull' [Ibs/ft2] 113(5400 Pa)/55(2660Pa) Permitted Module Temperature -40°F up to+185°F 0 on Continuous Duty40°C u to+85°C o Max.Test Loa d.Push/Pull' [Ibs/ft2] 169(8100Pa)/84(4000Pa) ( P ) d 'See Installation Manual F, mV S QUALIFICATIONS AND CERTIFICATES 1 Quality Controlled PV-TUV Rheinland; , IEC 61215:2016;IEC 61730:2018. This data sheet complies with DIN EN 50380. IL Ereven.I.I.°e U1.61730 W ID nn7m77 4 Hanwha 0 CELLS America Inc. 400 Spectrum Center Drive,Suite 1400,Irvine,CA 92618,USA I TEL+1 949 748 59 96 I EMAIL inquiry@us.q-cells.com I WEB www.q-cells.us Single Phase Energy Hub Inverter with Prism Technology 0 For North America SE3000H-US/SE3800H-US/SE6000H-US/SE7600H-US/ SE10000H-US / SE11400H-US(1) w 12-25 YEAR WARRANTY • 0 C 0 solar, ' 0 0 0 wi e • Optimized battery storage with HD-Wave technology / Record-breaking 99%weighted efficiency with / Multi-inverter,scalable storage solution 200%DC oversizing / With enhanced battery power up to 10kW / Small,lightweight,and easy to install / Integrated arc fault protection and rapid shutdown for NEC 2014,NEC 2017 and NEC 2020,per article / Modular design,future ready with optional 690.11 and 690.12 upgrades to: / DC-coupled storage for full or partial home backup / Embedded revenue grade production data,ANSI / Built-in consumption monitoring C12.20 Class 0.5 / Direct connection to the SolarEdge smart EV charger solaredge.com solar • I Single Phase Energy Hub Inverter with Prism Technology For North America SE3000H-US/SE3800H-US/SE6000H-US/SE7600H-US/SE10000H-US/ SE11400H-USm SE3000H-US SE3800H-US SE6000H-US SE7600H-US SE10000H-US SE11400H-US UNITS OUTPUT-AC ON GRID Rated AC Power 3000 3800 @ 240V 6000 @ 240V 7600 10000 11400 @ 240V W 3300 @ 208V 5000 @ 208V 10000 @ 208V Maximum AC Power Output 3000 3800 @ 240V 6000 @ 240V 7600 10000 11400 @ 240V W 3300 @ 208V 5000 @ 208V 10000 @ 208V AC Frequency Range(min-nom-max) 59.3-60-60.50 Hz Maximum Continuous Output Current @ 240V 12.5 16 25 32 42 47.5 A Maximum Continuous Output Current @ 208V - 16 24 - - 48.5 A GFDI Threshold 1 A Total Harmonic Distortion(THD) <3 % Power Factor 1,adjustable-0.85 to 0.85 Utility Monitoring,Islanding Protection,Country Configurable Thresholds Yes Charge Battery from AC(if allowed) Yes Typical Nighttime Power Consumption <2.5 W OUTPUT-AC BACKUPt3> 3800 7600 Rated AC Power in Backup Operation, 3000 7600* 6000 10300* 10000 10300 W AC L-L Output Voltage Range in Backup 211-264 Vac AC L-N Output Voltage Range in Backup 105-132 Vac AC Frequency Range in Backup(min-nom-max) 55-60-65 Hz Maximum Continuous Output Current in Backup Operation 12.5 32 25 32 42 43 A GFDI 1 A THD <5 % OUTPUT-SMART EV CHARGER AC l Rated AC Power 9600 W AC Output Voltage Range 211-264 Vac On-Grid AC Frequency Range(min-nom-max) 59.3-60-60.5 Hz Maximum Continuous Output Current @240V(grid,PV and battery) 40 Aac INPUT-DC(PV AND BATTERY) Transfurnver-less,Ungrounded Yes Max Input Voltage 480 Vdc Nom DC Input Voltage 380 Vdc Reverse-Polarity Protection Yes Ground-Fault Isolation Detection 600k0 Sensitivity INPUT-DC(PV) Maximum DC Power @ 240V 6000 7600 12000 15200 22000 I 22800 W 15200* 22800* Maximum DC Power @ 208V - 6600 10000 - - 20000 W Maximum Input Currenttsl @ 240V 8.5 10.5 16.5 20 27 31 Adc 20* 31* Maximum Input Current*@ 208V - 9 13.5 - - 27 Adc Max.Input Short Circuit Current 45 I Adc Maximum Inverter Efficiency 99 99.2 % CEC Weighted Effidency 99 99 @ 240V % 98.5 @ 208V 2-pole Disconnection Yes *Supported with PN SExxxxH-USMMxrccx x or SEbaxH-USMNxmocxx (1)These specifications apply to inverters with part numbers SE,000rH-USSMxxxxor or SE,oaxH-USSNxxxxxx and connection unit model number DCD-1PH-US-PxH-F-x (2)For other regional settings please contact SolarEdge support (3)Not designed for standalone applications and requires AC for commissioning.Backup functionality is only supported for 240V grid (4)Rated AC power in Backup Operation are valid for installations with multiple inverters.For a single backup inverter operation,rated AC power in Backup is 90%of the value stated (5)A higher current source may be used;the inverter will limit its input current to the values stated / Single Phase Energy Hub Inverter with Prism Technology For North America SE3000H-US/SE3800H-US/SE6000H-US/SE7600H-US/SE10000H-US/ SE11400H-US(1) SE3000H-US SE3800H-US SE6000H-US SE7600H-US SE10000H-US SE11400H-US UNITS IN•U - , (BA-TERY) Supported Battery Types SolarEdge Energy Bank,LG RESU Primet6l Number of Batteries per Inverter Up to 3 SolarEdge Energy Bank,up to 2 LG RESU Prime Continuous Powerm 6000 7600 10000 W Peak Power(' 6000 7600 10000 W Max Input Current 16 20 26.5 Adc 2-pole Disconnection Yes SMART ENERGY CAPABILITIES Consumption Metering Built-infer Backup&Battery Storage With Backup Interface(purchased separately)for service up to 200A;Up to 3 inverters EV Charging Direct connection to Smart EV charger ADDITIONAL FEATURES Supported Communication Interfaces RS485,Ethernet,CellulartM,Wi-Fi(optional),SolarEdge Energy Net(optional) Revenue Grade Metering,ANSI C12.20 Built-in18J Integrated AC,DC and Communication Connection Unit Yes Inverter Commissioning With the SetApp mobile application using built-in Wi-Fi Access Point for local connection DC Voltage Rapid Shutdown(PV and Battery) Yes,according to NEC 2014,NEC 2017 and NEC 2020 690.12 STANDARD COMPLIANCE Safety UL1741,UL1741 SA,UL1741 PCS,UL16998,UL1998,UL9540,CSA 22.2 Grid Connection Standards IEEE1547,Rule 21,Rule 14H Emissions FCC part 15 class B INSTALLATION SPECIFICATIONS AC Output and EV AC Output Conduit Size/AWG Range 1"maximum/14-4 AWG DC Input(PV and Battery)Conduit Size/AWG Range 1"maximum/14-6 AWG 17.7 x 14.6 x 6.8/ 450x370x174 Dimensions with Connection Unit(H x W x D) 17.7 x 14.6 x 6.8/450 x 370 x 174 17.7 x 14.6 x 6.8/ 17.7 x 14.6 x 6.8/450 370 x 174 in/mm 450 x 370 x 174* 26/11.8 Weight with Connection Unit 26/11.8 30.2/13.7* 30.2/13.7 lb/kg <25 Noise <25 <50* <25 <50 dBA Cooling Natural Convection Operating Temperature Range -40 to+140/-40 to+60m °F/°C Protection Rating NEMA 4 (6)The part numbers SEloosxH-USxMxxxxx only support the SolarEdge Energy Bank.The part numbers SErooeH-USxNxxxxx support both SolarEdge Energy Bank and LG RESU Prime batteries Requires supporting inverter firmware (7)Discharge power is limited up to the inverter rated AC power for on-grid and backup applications (8)For consumption metering current transformers should be ordered separately.SECT-SPL-225A-T-20 or SEACT0750-400NA-20 units per box.Revenue grade metering is only for production metering (9)Information concerning the Data Plan's terms&conditions is available in the following link: https://wv w.solaredge.corn/sites/default/files/se-communication-plan-terms-and-corxiitions-eng.pdf (10)Full power up to at least 50°C/122°F;for power de-rating information refer to:https://ww.solaredge.corrVsitesidefault/files/se-temperature-derating-note-na.pdf ®SolarEdge Technologies,Inc.All rights reserved.SOLAREDGE,the SolarEdge logo,OPTIMIZED BY SOIAREDUE we trademarks or registered trademarks of SolarEdge Technologies,Inc Ro H S All other trademarks mentioned herein are trademarks of their respective owners.Date:06/2021 DS-000031-1.5-NAM.Subject to change without notice. SnapNrack- UR-40 Solar Mounting Solutions UR-60 Ultra Rail 11 The Ultimate Value in Rooftop Solar Industry leading Wire Mounts available for all Management Solutions roof types Single Tool Installation All SnapNrack Module Clamps & Accessories are compatible with both raiil profiles Start Installing Ultra Rail Today RESOURCES snapnrack.com/resources DESIGN snapnrack.com/configurator WHERE TO BUY snapnrack.com/where-to-buy SnapNrack Ultra Rail System A sleek, straightforward rail solution for mounting solar modules on all roof types. Ultra Rail features two rail profiles; UR-40 is a lightweight rail profile that is suitable for most geographic regions and maintains all the great features of SnapNrack rail, while UR-60 is a heavier duty rail profile that provides a larger rail channel and increased span capabilities. Both are compatible with all existing mounts, module clamps, and accessories for ease of install. The Entire System is a Snap to Install • New Ultra Rail Mounts include snap-in brackets Iii?Nsirsersosi, for attaching rail • Compatible with all the SnapNrack Mid Clamps and End Clamps customers love • Universal End Clamps and snap-in End Caps provide a clean look to the array edge Unparalleled Wire Management • Open rail channel provides room for running wires resulting in a long-lasting quality install 1111101, • Industry best wire management offering includes Junction Boxes, Universal Wire Clamps, MLPE Attachment Kits, and Conduit Clamps • System is fully bonded and listed to UL 2703 Standard Heavy Duty UR-60 Rail • UR-60 rail profile provides increased span capabilities for high wind speeds and snow loads • Taller, stronger rail profile includes profile- specific rail splice and end cap • All existing mounts, module clamps, and accessories are retained for the same great • install experience Quality. Innovative . Superior. SnapNrack Solar Mounting Solutions are engineered to optimize material use and labor resources and improve overall installation quality and safety. 877-732-2860 www.snapnrack.com contact:a snapnrack.com c 2019 by SnapNrack Solar Mounting Solutions.All rights reserved DESCRIPTION: DRAWN BY: SNAPNRACK, ULTRA RAIL COMP KIT mwatkins Snup_Xcrack- REVISION: Solar Mounting Solutions PART NUMBER(S): B 585 MARKET STREET,29TH FLOOR•SAN FRANCISCO,CA 94105 USA PHONE(415)580-6900•FAX(415)580�02 SEE BELOW THE INFORMATION IN THIS DRAWING IS ECOMMENT.AND PROPRIETARY.ANY ON REPRODUCTI .DISCLOSURE.CR USE THEREOF THEREEOF ISIS PROHIBITED WITHOUT THE WRITTEN CONSENT CF SUNRUN SOUTH LLCill 1. 4; I/ -.4%.:-.414z,,, Q. 41..., 0 1 O ..„). Q u u 0 u u „.. ,v_....,,, „,..,,_ 0 ,,, ,„,, CP ti 0 0 cik PARTS LIST ITEM QTY PART NUMBER DESCRIPTION 1 1 242-9.2266 SNAPNRACK, UMBRELLA LAG, TYPE 3, 4IN, SS 2 1 242-01219, 242-01220 SNAPNRACK, ULTRA FOOT FOR U FLASHING, SILVER/ BLACK 3 1 232-01375, 232-01376 SNAPNRACK, COMP FLASHING, 9IN X 12IN, SILVER/ BLACK ALUM MATERIALS: 6000 SERIES ALUMINUM, STAINLESS STEEL, RUBBER DESIGN LOAD (LBS): 405 UP, 788 DOWN, 236 SIDE ULTIMATE LOAD (LBS): 2006 UP, 4000 DOWN, 1070 SIDE TORQUE SPECIFICATION: 12 LB-FT CERTIFICATION: UL 2703, FILE E359313; WIND-DRIVEN RAIN TEST FROM UL SUBJECT 2582 WEIGHT (LBS): 0.80 • DESCRIPTION: DRAWN BY: SNAPNRACK, ULTRA RAIL COMP KIT mwatkins SfiQP\--FaCk- REVISION: Solar Mounting Solutions PART NUMBER(S): B 595 MARKET STREET,29TH FLOOR•SIAN FRANCISCO,CA 94105 USA PHONE(415)58043900•FAX(415)58045502 SEE BELOW THE INFORMATION IN THIS DRAWTNO IS NTIAL AND PROPRIETARY.ANY REPRODUCTION,DISCLOSURE,OR USE THEREOF IS PROHIBITED WITHOUT THE WRITTEN CONSENT OF SUNRUN SOUTH LLC. UMBRELLA L FOOT PROPERTIES SKU DESCRIPTION 242-01219 ULTRA RAIL UMBRELLA L FOOT, SILVER �/ 242-01220 ULTRA RAIL UMBRELLA L FOOT, BLACK If 1.37 01.00 N. 4w, ® .38 .30 1 1.00 SLOT o Tit i'� [11150 ® II O 3.25 'or2.78 1.78 -..-1.62 1.80---► H-1 50—H I COMP FLASHING PROPERTIES SKU DESCRIPTION 232-01375 COMP FLASHING, 9" X 12", BLACK ALUM 232-01376 COMP FLASHING, 9" X 12", SILVER ALUM I A r_ - 11 - I , .30 — 01.00 SnapN rack _i__ um Tau-aP Homrnaano zoa D r e 1 - 11.75 _1_ o 4.20 — 105° — wit 56.35 — 3.25 1 8.75 ► .45—P- H— ALL DIMENSIONS IN INCHES 4 SunBug Solar Joseph Holmes 117 Olander Dr. Unit 12, Northampton, MA 01060 Non-Standard Permit Requirements: 0.0 978-844-1182 joseph.holmes@alum.mit.edu Town of Northampton / Florence Puchalski Municipal Building 212 Main St. Northamptor 413-587-1240 Sun Bug Job # 3686-Wes-W Date of Sale 6/8/2022 Project Value $27,283.00 Y � Electrical Work $4,092.45 Construction $23,190.55 Project Size 7.3 kW Building Permit# Electrical Permit# Materials 20 Hanwha Q.Peak Duo 365 BoB 20 SolarEdge Optimizer S440 1 SolarEdge Energy Hub - SE7600H SnapNRack Ultra Rail Racking 4,1