Loading...
17A-156 (2) Options Summary Sample Insurance Certificate Catalog Cuts and Product Literature Plans and Sketches Accepted: Do not sign this agreement if there are blank spaces in this contract form. i s 00 /s�6 v Owner Date Owner D to to, this Agreement or the breach thereo:P, except for claims which have been waived by the making or acceptance of final payment shall be decided by arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association then obtaining unless the parties mutually agree otherwise in writing. This Agreement to arbitrate shall be specifically enforceable under the prevailing arbitration law. Notice of the demand for arbitration shall be filed in writing with the other parry to this Agreement and with the American Arbitration Association. The demand for arbitration shall be made within a reasonable time after the claim, dispute_.or other matter in question has arisen, and in no event shall it be made after the date when institution of legal or equitable proceedings based on such claims, dispute or other matter in question would be barred by the applicable statute of limitations. The award rendered by the arbitrators shall be final and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. Unless otherwise agreed in writing, Contractor shall at his option be entitled to continue the Work and Owner shall continue to make payments in accordance with this Agreement. Warranty: Wright Builders provides a:Limited Warranty against defects in materials and workmanship for a period of one year from date of certificate of occupancy, or owner's beneficial use, whichever comes first. It is, of course, the owner's responsibility to undertake proper maintenance, and to promptly advise the Builder of any items requiring attention. We thank you very much for this opportunity and look forward to serving you. in y Wright r si AW Home Improvement Contractor Registration number: 101536 Federal Tax I.D. number: 04-2541115 Mass. Employer Identification number: 09-57200-0 Enclosures: 1 Proposal Package Proposal Letter with Terms Signature Copy Estimate Summary These same statutes also require the following notification: It is Wright Builders' obligation to obtain the building permit as your agent. In the event that we do not obtain these permits, and you obtain them, or if Wright Builders is not registered with the Board of Building Regulations, you will not be entitled to obtain any benefits from the guarantee fund established under Massachusetts General Laws Chapter 142A. Cancellation: If you have previously provided a deposit for the work, cancellation will result in billing and collection of all costs and reimbursement for professional time expended. If you have not made a prior commitment via a deposit, you may under the laws of the Commonwealth, cancel this agreement after signing for a period of three days without further obligation, according to the provision of the Notice of Cancellation attached. Enclosures: The accompanying materials, enumerated below under "enclosures", are part of this proposal and also contain information that Wright Builders is obliged to provide. Ordering the work. Please call me with your questions, changes, and further instructions; at the appropriate time, you may indicate your acceptance by signing, dating and returning a copy of these documents to us. At this time please select any items from the list of options so that we may incorporate these into the job documents for streamlined .communication to suppliers, contractors, and our own staff. Deposit Required. Please provide us with the balance of a $1500.00 deposit, which will be credited against the first month's billing. Start of Work. At this time, construction can begin spring 2000. Schedule: We will provide you with additional schedule information at the start of the job. Completion: The project will take approximately two weeks to reach substantial completion, all subject to prior commitments at time of order. This work is undertaken without penalty for failure to complete on the designated schedule. Job Site Identification: In order to facilitate deliveries, and because we are proud of our work, we will place a modest directional identification sign near the road access to this project. Insurance: It is the owner's responsibility to insure the property and all materials or items delivered to the site, and to reimburse any deductible in the case of loss. Any products furnished to the site belong to the owner of the site, effective at the time of delivery, and should be insured accordingly by the owner. Wright Builders provides Liability, Workers Compensation, and Completed Operations insurance. Arbitration: All claims, disputes and other matters in question arising out of, or relating Site conditions: All costs presented for site work items are estimates assuming conditions are as they appear on documents provided and ascertained during site inspection. Any site conditions that occur that require alteration of site plans, site engineering, septic engineering, cope of construction work or related work will result in cost changes to the owner. Site Services: Temporary power usage and all electricity used on site, temporary heat fuel, fuel for heating system once installed, water and sewer consumption charges, and snow removal are the owner's responsibilities; the costs for these items will be paid directly by the owner or added to the contract through change order. Waste Disposal: Waste disposal costs and methods are in the process of changing. We have assumed, for our pricing purposes, that mixed waste can be disposed of in containers or by our truck in local facilities at a cost, unsorted, of not to exceed $70.00 per ton. Costs in excess of this amount per ton, or procedures that require additional labor or services; will be added to the cost of the project. Changes to the Work. The scope of the work can be altered on request through a change order, which is typically priced and approved prior to the execution of the work. If job conditions should necessitate additional work authorized by you, such as concealed water or insect damage, on a "T&M" (time and material) basis, these items will be handled at cost plus 15% plus a project management charge. Further, allowances are generally line items in the Estimate Summary and include a mark-up for overhead. Actual costs, plus 15% and a project management charge will be used to adjust allowance as work is completed. Billin . All bills are typically prepared monthly, although we reserve the right to bill twice monthly, for all work completed, stored, in process, and deposits required, net five days, no retainage. Billings are estimated as of approximately the 25`h of the month, projecting to the end of the month. Late Payment: Balances over 30 days, 1-1/2% interest per month. Expiration of Proposal: Because of volatile materials costs, quotations are firm for only 10 days. It may well be that prices are secure beyond that period, but it is best to check with us. Please review all documents carefully and advise us of any lack of clarity. Since errors do occasionally occur, we cannot be responsible for clerical oversights. Home Improvement Contractor Regulations. As of July 1, 1992, all residential contractors and subcontractors are required to be registered with the Massachusetts Board of Building Regulations and Standards, unless specifically exempt from registration. Inquiries concerning registration should be directed to Director, Home Improvement Contractor Registration One Ashburton Place Room 1301 Boston.MA 02018 (617/727-85981 4 S WRIGHTJCBUILDERS I N C O R P O R A T E D 48 BATES STREET NORTHAMPTON, MASSACHUSETTS 01060 s�f 2 3 2000 'April6,y2000 Barbara and Peter Rowe 69 Fox Farms Road Florence, Ma. 01062 ' i Modifications to Kitchen Dear Peter and Barbara: ` Thank you for your confidence in Wright Builders and for the opportunity to be of assistance. Our quote is based on the scope of work outlined below. The Scope of the Project: Install and connect new one piece range, slide in, at existing range top location, modifying base cabinet, remaking drawers, and wrapping paining grade 5" base. Attach to existing ductwork. Modify existing oven base to receive new drawer and opening for microwave. Owner to purchase appliances subject to review and approval. Allowance for electrical work including new micro circuit and new range circuit. Costs: Costs for the project are as shown below. 1200 Non-Materials 202 2010 Demolition& General Labor 297 6002 Carpentry Labor Allowance 1716 6004 Carpentry Material Package 262 6400 Custom Millwork Allowance—drawers and doors 1048 8700 Finish Hardware 158 15500 Heating and Duct Allowance 378 16100 Electrical Allowance 1134 Total of Estimated Budget 5195 Optional Work: Options for material or costs savings, if applicable, are included in a separate options summary page. They may be selected at time of original contract, and will then be incorporated as a Change Order. TELEPHONE 413-586-8287 FAX 413-537-9276 ELECTRONIC MAIL: wrightbldleaol.com Mar 06 00 09: 48a P. 5 SECTION 8 • CONSTRUCTION SERVICES $,_1 Licensed Construction Supervisor: Not App'.:cable ❑ Name of License Holder ( License Number _�(� �_ 3 -�� A 6-21 AA,MN, Mrs GIB �D I W�� Address (I-, - Expira`..cn Cate -�N I �_AN �13 g2g Signature Telephone _: Not Applicable ❑ Company Name Regis:rat,c-i Number t}$ �'- Address Expira`ion Date _ �1f VV�'11 Telephcneb" SECTION 10-WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c. 152,§;25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the issuance of the building permit. Signed Affidavit Attached Yes....... No,..... ❑ �AN *r The current exemption for"homeowners"was extended to include Owner-occupied Dwellings of one(1) or two(2)families and to allow such homeowner to engage an individual for hire who does not possess a license, provided that the owner acts as supervisor.CMR 780, Sixth Edition Section 108.3.5.1. Definition of Homeowner:Person(s)who own a parcel of land on which he/she resides or intends to reside,on which there is,or is intended to be,a one or two family dwelling,attached or detached structures accessory to such use and/or farm structures. A person who constructs more than one home in a two-year period shall not be considered a homeowner. Such"homeowner"shall submit to the Building Official,on a form acceptable to the Building Official,that he/she shall be responsible for all such work performed under the building permit. As acting Construction Supervisor your presence on the job site will be required from time to time,during and upon completion of the work for which this permit is issued. Also be advised that with reference to Chapter 152(Workers' Compensation) and Chapter 153 (Liability of Employers to Employees for injuries not resulting in Death)of the Massachusetts General Laws Annotated,you may liable for person(s) you hire to perform work for you under this permit. The undersigned"homeowner" certifies and assumes responsibility for compliance with the State Building Code,City of Northampton Ordinances,State and Local Zoning;Laws and State of Massachusetts General Laws Annotated. Homeowner Signature Mar 06 00 09: 48a p. 4 SECTION 5.DESCRIPTION OF PROPOSED WO c ck a4l.aopl cabal New Mouse ❑ Addition ❑ Replacement Windows Alteration(s)� TRoofing ❑ Or Doors ❑ Accessory Bldg. ❑ Demolition❑ New Signs [ j Decks [ ] Siding[ } Other[ ] Brief Description of Proposed Work: � �� S 71--WAC41/v)-EP-r aA Alteration cf existing bedroom Yes No Adding new bedroom Yes �K No Attached Narrative'./ Renovating unfinished basement Yes __>!(_No Plans Attached Roll Sheet L' tvb �f-►N _ a. Use of building: One Family Two Family. Other b, Number of rooms in each family unit: Number of Bathrooms c. Is there a garage attached? d. Proposed Square footage of new construction— Dimensi e. Number of stories? f. Method of heating? F" aces or Woodstoves Number of each _ g. Energy Conservation Compliance. _Mascheck Energy Compliance form attached? — h. Type of construction i. Is construction within 100 f �, wetlands?.�__Yes _ No. Is construction within 100 yr. floodplain___,.._Yes No j. Depth of basemen cellar ficor below finished grade _ k. Will buddi conform to the Building and Zoning regulations? Yes _No . I. S c Tank City Sewer Private well City water Supply SECTION 7a,OWNER AUTHORIZATION-TO BE COMPLETER WHEN OWNERS AGENT OR CONTRACTOR APPLlkS POR$Ul DING PERMIT I, a A f'B ft-f—A' � 1,,- as Owner of the subject property hereby authorize VU�'j�t�t D��((J�_ te-�i �l`k% _to ac:on my behalf, in all matters relative to work authorized by this building permit application. Signature of Owner Date (/UR/� cf�f� rr ,P�, !N C' as Owner�esto hereby declare that the statements and informa ion on the foregoing application are true and accurate, to knowledge and belief, Signed under the pains and penalties of perjury. =JM&f j VV Prirt Name Signature of Owner/Agent Date Mar' 06 00 09: 47a p. 3 Section 4. ALL INFORMATION MUST BE COMPLETED, or PERMIT CAN BE DENIED DUE TO LACK OF INFORMATION AV- Nov jb ft DW-C &0 '(j 6 6 N6- PD OT/41'M7- b lG Existing Proposed Required by Zoning ,C _.t(Dl 146— rhis column to to filled in by (� Building Depan.-tent Lot Size Frontage. Setbacks Front Side L: R: L: R:_______- Rear Building Height Bldg.Square Footage % Open Space Footage % I (Ut arca minus bldg&paved parking) 9 of Parking Spaces Fill: (volume&Location) A. Has a Special Permit/variance/Finding ever been issued for/on the site? NO DON'T KNOW YES IF YES, date issued: IF YES: Was the permit recorded at the Registry of Deeds? NO — DON'T KNOW YES _ IF YES: enter Book Page and/or Document # B. Does the site contain a brook, body of water or wetlands? NO DON'T KNOW _ YES IF YES, has a permit been or need to be obtained from the Conservation Commission? Needs to be obtained Obtained Date Issued: C. Do any signs exist on the property? YES NQ __, IF YES, describe size, type and Iccation: _ D. Are there any proposed changes to or additions of signs intended for the property?YES_ No IF YES, describe size, type and location: Mar' OG 00 09: 47a p. 2 (' � ty of Northampton . 4" . i �. i ilding Department z ; �212 Main Street ° AUG 2 3 2000 : . � Room 100 flor Hampton, MA 01062 pfrQne 41-3- 87.1240 Fax 413-587-1272 APPLICATION TO CONSTRUCT, ALTER, REPAIR, RENOVATE OR DEMOLISH A ONE OR TWO FAMILY DWELLING SECTION 1- SITE INFORMATION Thi' s�ctr t be zar Pffil�e 1.1 Property Address: Ap 7. N MPro�a 4 EIm�4 DiStClcf�;' n _ �B;Distnet _ - SECTION 2- PROPERTY OWNERSHIP/AUTHORIZED AGENT 2.1 Owner of Recce: jk Name(Print)r / Current Laiiing Address: /-0(L — d—F hI �K Spc �A�' � �,0'/ � Teleahone Q ( / Signature 2.2 Authorized Agent: IN 1-1 (.mob:�!e I N Name(Pint) Current Nailing Address: Signature Telephcne SECTION 3 - ESTIMATED _CGSTS,,—F item Estimated Cost(Dollars)to be Official Use Only completed by permit applicant 1. Building 3f. g3 (a; Building Permit Fee 2. Electrica'. (13(L (b) Estimated Total Cost of ( Construction from 6 3. Plumbing ( Building Permit Fee 4. Mechanical (HVAC) 37 5. Fire Protection 6. Total =(1 + 2+ 3+4+ 5) S •"� Check Number D This Section For Official Use Only Building Permit Number: Date issued: Signature: -- Building Commissioner/Inspector of Buildings Date' File#BP-2001-0208 APPLICANT/CONTACT PERSON Wright Builders ADDRESS/PHONE 48 Bates St (413)586-8287 PROPERTY LOCATION 69 FOX FARMS RD MAP 17A PARCEL 156 ZONE URA THIS SECTION FOR OFFICIAL USE ONLY: PERMIT APPLICATION CHECKLIST ENCLOSED REQUIRED DATE ZONING FORM FILLED OUT Fee Paid Building Permit Filled out _ Fee Paid Typeof Construction: KIT HEN RENOVATION _ New Construction Non Structural interior renovations Addition to Existing Accessory Structure Building Plans Included• Owner/Statement or License 015792 3 sets of Plans/Plot Plan THE LLOWING ACTION HAS BEEN TAKEN ON THIS APPLICATION: Approved as presented/based on information presented. Denied as presented: Special Permit and/or Site Plan Required under: § PLANNING BOARD ZONING BOARD Received&Recorded at Registry of Deeds Proof Enclosed Finding Required under: § _w/ZONING BOARD OF APPEALS Received&Recorded at Registry of Deeds Proof Enclosed Variance Required under: § w/ZONING BOARD OF APPEALS Received&Recorded at Registry of Deeds Proof Enclosed Other Permits Required: Curb Cut from DPW Water Availability Sewer Availability Septic Approval Board of Health Well Water Potability Board of Health Permit from Conservation Co n Permit from CB Architecture Committee Signature of Building Official Date Note: Issuance of a Zoning permit does not relieve a applicant's burden to comply with all zoning requirements and obtain all required permits from Board of Health,Conservation Commission,Department of public works and other applicable permit granting authorities. 69 FOX FARMS RD BP-2001-0208 G1S#: COMMONWEALTH OF MASSACHUSETTS MW:Block: 17A- 156 CITY OF NORTHAMPTON Lot:-001 Permit: Building Catep,o!y'Non structural interior renovations BUILDING PERMIT Permit# BP-2001-0208 Project# JS-2001-0336 Est.Cost: $5195.00 Fee:$50.00 PERMISSION IS HEREBY GRANTED TO: Const.Class: Contractor: License: Use Grop Wright Builders 015792 Lot Size(sa.ft.): 19819.80 Owner: ROWE PETER N&BARBARA C Zoning.URA Applicant: Wright Builders AT. 69 FOX FARMS RD Applicant Address: Phone: Insurance: 48 Bates St (413) 586-8287 Workers Compensation NORTHAM PTO NMA01060 ISSUED ON:8128100 0:00:00 TO PERFORM THE FOLLOWING WORK.KITCHEN RENOVATION POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Inspector of Buildings Underground: Service: Meter: Footings: Rough: Rough: House# Foundation: Final: Final: Rough Frame: Gas Fire Department Fireplace/Chimney: Rough: Oil: Insulation: Final: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF ANY OF ITS RULES AND REGULATIONS. Certificate of Occupancy Signature: Fee Type: Receipt No: Date Paid: Check No: Amount: Building 8/28/00 0:00:00 7914 $50.00 212 Main Street,Phone(413)587-1240,Fax: (413)587-1272 Building Commissioner-Anthony Patillo is r i (, s 'k z ___._..--�... _ - ,'-.,".._.,�.:wrv..€::- s^--^--'"•., --•_.,,-_�--�---�-=�.�,,,_,.. 'f auE� a�,tk^vi�e w'�u.�„ a�aav;.,T.'`"�-a.,.. '�.`�'' '_--", ='�.�-� `a:.--__ sr R _ u �e 5i x *G PA Ty"Aviv, WAV igloos NOR e• Wak 69 FOX FARMS RD BP-2001-0208 GIs#: COMMONWEALTH OF MASSACHUSETTS Map:Block: 17A- 156 CITY OF NORTHAMPTON Lot:-001 Permit: Building Cwt gory:NqA structural interior renovations BUILDING PERMIT Permit# BP-2001-0208 a0ject# JS-2001-0336 Est.Cost:$5195.00 Fee: 50.00 PERMISSION IS HEREBY GRANTED TO: Const.Class: Contractor: License: Use Group: Wright Builders 015792 Lot Sim(sq ft.): 19819.80 QLMer: &OWE PETER N&BARBARA C Zoning:URA Agplicant. Wright Builders AT: 6 FQX f~ RC3 A CkantAddress: Phone Insurance: 48 Bates St (413) 586-8287 Workers Compensation NORTHAMPTONMA01060 IS'S'UED ON:8128/()0(:00- TO PERFORM THE.FOLLOWING WORK:KITCHEN RENOVATION POST THIS CARD W IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Inspector of Buildings Underground Service: P4A Meter: j/lf Olt Footings: Rough: Rough: House# Foundation: Final: Final: Rough Frame: Gas Fire Department Fireplace/Chimney: Rough Oil: Insulation: ok Finai: Sm Final: 4/r /©_ THIS PERNIIT MAY BE REVOKED BY THE CITY O RTHAMPTON UPON VIOLATION O ANY OF ITS RULES AND REGULATIONS. Certificate of O e anc si ature: Fee`Type: ReceiAt No Date Paid: Check Nor Amount: Building 8/28/00 0:00:00 7914 $50.00 212 Main Street,Phone(413)587-1240,Fax:(413)587-1272 Building Commissioner-Anthony Patillo