The URL can be used to link to this page

43-138 SOLAR BP-2023-0058 56 LONGFELLOW DR COMMONWEALTH OF MASSACHUSETTS Map:Block:Lot: 43-138-001 CITY OF NORTHAMPTON Permit: Solar Build PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL c.142A) BUILDING PERMIT Permit# BP-2023-0058 PERMISSION IS HEREBY GRANTED TO: Project# 2023 SOLAR Contractor: License: Est. Cost: 42795 SUNBUG SOLAR LLC 099037 Const.Class: Exp.Date: 02/12/2024 Use Group: Owner: DERR VINCENT LINDA & THOMAS S Lot Size (sq.ft.) Zoning: WSP Applicant: SUNBUG SOLAR LLC Applicant Address Phone: Insurance: 2A DRAPER ST 617-500-3938 WC333749A WOBURN, MA 01801 ISSUED ON: 01/19/2023 TO PERFORM THE FOLLOWING WORK: INSTALL 11 PANEL 16 KW ROOF MOUNT SOLAR SYSTEM WITH 16 KW BATTERY POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector Underground: Service: Meter: Footings: Rough: Rough: House # Foundation: Final: Final: Final: Rough Frame: Gas: Fire Department Driveway Final: Fireplace/Chimney: Rough: Oil: Insulation: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF ANY OF ITS RULES AND REGULATIONS. Signature: !MAL, )9 . T-3„,„ Fees Paid: $75.00 212 Main Street,Phone(413)587-1240,Fax: (413)587-1272 Office of the Building Commissioner Uucu. IyII CI IVCIupe IL).DDUCrQ,C-ozor-4C1,10-PI1J I D-I L9 I yomro It, - r The Commonwealth of Massachusetts j —= Board of Building Regulations and Standards FOR Massachusetts State Building Code, 780 CM1t"N 1 8 p rUNICALITJ .�a3 ;USE Building Permit Application To Construct,Repair, Renovate Or Demolish a ! evised Mar 2011 One-or Two-Family Dwelling This Section For Official Use Only Building P it Number: 6P- ••q 3- ym�' Date Applied: ,,__,..,_, a,, 1// /- /q-ZOZ3 Building Official(Print Name) Signature Date SECTION 1:SITE INFORMATION 1.1 Property Address: 1.2 Assessors Map& Parcel Numbers 56 Longfellow Drive,Northampton,MA 01062 1.1 a Is this an accepted street?yes x no Map Number Parcel Number 1.3 Zoning Information: 1.4 Property Dimensions: Zoning District Proposed Use Lot Area(sq ft) Frontage(ft) 1.5 Building Setbacks(ft) Front Yard Side Yards Rear Yard Required Provided Required Provided Required Provided 1.6 Water Supply: (M.G.L c.40,§54) 1.7 Flood Zone Information: 1.8 Sewage Disposal System: Public 0 Private 0 Zone: _ Outside Flood Zone? Municipal 0 On site disposal system 0 Check if yes❑ SECTION 2: PROPERTY OWNERSHIP' 2.1 Owner'of Record: Thomas Derr Northampton, MA 01062 Name(Print) City,State,ZIP 56 Longfellow Drive (413) 584-9468 tderr@smith.edu No.and Street Telephone Email Address SECTION 3:DESCRIPTION OF PROPOSED WORK2(check all that apply) New Construction 0 Existing Building 0 Owner-Occupied 0 Repairs(s) 0 Alteration(s) 0 Addition 0 Demolition 0 Accessory Bldg. 0 Number of Units Other ■ Specify: Solar and ESS Install Brief Description of Proposed Work2: Installation of 11 roof mounted solar modules and an ESS comprising of one LG RESU16H Prime battery for a total of 16kWh. SECTION 4:ESTIMATED CONSTRUCTION COSTS Item Estimated Costs: Official Use Only (Labor and Materials) 1.Building $ 36,376.00 1. Building Permit Fee: $ Indicate how fee is determined: 2.Electrical $ 6,419.00 ❑ Standard City/Town Application Fee ❑Total Project Cost'(Item 6)x multiplier x 3.Plumbing $ 2. Other Fees: $ 4. Mechanical (HVAC) $ List: 5. Mechanical (Fire $ Suppression) Total All Fees: �^ Check No. Check Amount: `�" I� Cash Amount: 6.Total Project Cost: $ 42,795.00 0 Paid in Full 0 Outstanding Balance Due: L,uu:u01y1I CI IVtliupe IU.DDUCro,C-JLJr-MCVO-mu I D-I LY 191/0Mr Ili SECTION 5: CONSTRUCTION SERVICES 5.1 Construction Supervisor License(CSL) CS-099037 02/12/2024 Cheney Brand License Number Expiration Date Name of CSL Holder List CSL Type(see below) U 11 Morrison Place, unit 2 No.and Street Type Description Somerville MA, 02144 U Unrestricted(Buildings up to 35,000 Cu.ft.) R Restricted 1&2 Family Dwelling City/Town,State,ZIP M Masonry Ow.*" 12/30/2022 RC Roofing Covering WS Window and Siding SF Solid Fuel Burning Appliances 617-500-3938 permits@sunbugsolar.com I Insulation Telephone Email address D Demolition 5.2 Registered Home Improvement Contractor(HIC) 163091 05/10/2023 SunBug Solar Cheney Brand HIC Registration Number Expiration Date HIC Company Name or HIC Registrant Name 2a Draper Street permits@sunbugsolar.com No.and Street Email address Woburn, MA 01801 617-500-3938 City/Town,State,ZIP Telephone SECTION 6:WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c. 152. § 25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the Issuance of the building permit. Signed Affidavit Attached? Yes ■ No...........❑ SECTION 7a: OWNER AUTHORIZATION TO BE COMPLETED WHEN OWNER'S AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT I,as Owner of the subject property,hereby authorize Cheney Brand to act on my behalf,in all matters relative to work authorized by this building permit application. Print Owner's Name(Electronic Signature) Date SECTION 7b:OWNER'OR AUTHORIZED AGENT DECLARATION By entering my name below, I hereby attest under the pains and penalties of perjury that all of the information contained in this application is true and accurate to the best of my knowledge and understanding. 12/30/2022 Print Owner's or Authorized Agent's Name(Electronic Signature) Date NOTES: 1. An Owner who obtains a building permit to do his/her own work,or an owner who hires an unregistered contractor (not registered in the Home Improvement Contractor(HIC)Program),will not have access to the arbitration program or guaranty fund under M.G.L.c. 142A. Other important information on the HIC Program can be found at www.mass.gov/oca Information on the Construction Supervisor License can be found at www.mass.gov/dps 2. When substantial work is planned,provide the information below: Total floor area(sq. ft.) (including garage,finished basement/attics,decks or porch) Gross living area(sq. ft.) Habitable room count Number of fireplaces Number of bedrooms Number of bathrooms Number of half/baths Type of heating system Number of decks/porches Type of cooling system Enclosed Open 3. "Total Project Square Footage"may be substituted for"Total Project Cost" UVVUJKyII CIIVCIUpC IL.DDUCroi C-acar'WCUO-NV ID-IL9141JOMr0 IV City of Northampton �,> ; , Massachusetts �� ''c�, t, w .,_ DEPARTMENT OF BUILDING INSPECTIONS 212 Main Street • Municipal Building yeti PD 4;;;;) Northampton, MA 01060 �sl1h, seD\A' CONSTRUCTION DEBRIS AFFIDAVIT (FOR ALL DEMOLITION AND RENOVATION PROJECTS) In accordance of the provisions of MGL c 40, S54, a condition of Building Permit Number is that all debris resulting from this work shall be disposed of in a properly licensed waste disposal facility, as defined by MGL c 111, S 150A. The debris will be disposed of in: Location of Facility: 68 Hopkinton Road,Westborough, MA 01581 The debris will be transported by: Name of Hauler: El Harvey&Sons 12/30/2022 Signature of Applicant: rr ,6.4 Date: ;._ Commonwealth of Massachusetts Division of Occupational Licensure IP Board of Building Re ulations and Standards if , Cons is S V1$ " CS-099037 cpsres : 02/ 1212024 CHENEY C BAND 11 MORRISON PL NO. 2 SOMERVILLE IA 02144 .% ILI % I , „ 03 vCrrrrrrr.4.2rvrwr f ^ l/.. v 11. Construction Stipervw r llnres*rfctrtl • Bud of any use group Which co i1 In less than 34,000 cubs: feel (9111 cubic meters) of enclosed %p w e. Faillure to possess a current edition ot the Massachus+ ti s State Building Ccxk ih cause Nw revocation of this license. For Kt1r,rmation about this license Call I,€171 727 32G0 twr vlstt www,ina+cs.gcw dpl Office of Consumer Affairs and Business Regulation 1000 Washington Street - Suite 710 Boston, Massachusetts 02118 Home Improvement Contractor Registration Type: LLC SUNBUG SOLAR LLC Registration: 163091 411A HIGHLAND AVENUE Expiration: 05/10/2023 SUITE 312 SOMERVILLE, MA 02144 Update Address and Return Card. Office of Consumer Affairs& Business Regulation HOME IMPROVEMENT CONTRACTOR Registration valid for individual use only TYPE: LLC before the expiration date. If found return to: Registration Expiration Office of Consumer Affairs and Business Regulation 163091 05/10/2023 1000 Washington Street -Suite 710 SUNBUG SOLAR LLC Boston, MA 02118 CHENEY BRAND 1165 MASSACHUSETTS AVENUE , 'a ARLINGTON. MA 02476 Undersecretary Ot Va�i ithout signature The Commonwealth of Massachusetts Department of Industrial Accidents Office of Investigations k hf/ _•�I_ Lafayette City Center , �F- 2 Avenue de Lafayette, Boston, MA 02111-1750 www.mass.gov/dia ` otters' Compensation Insurance Affidavit: Builders/Contractors/Electricians/Plumbers Applicant Information Please Print Legibly Name (Business/Organization/Individual):SunBug Solar Address:411 A Highland Ave.Suite 312 City/State/Zip:Somerville, MA 02144 Phone#:413-884-1000 Are you an employer?Check the appropriate box: Type of project(required): 1.2 I am a employer with 70 employees(full and/or part-time).* 7. New construction 2.0 I am a sole proprietor or partnership and have no employees working for me in 8. p Remodeling any capacity.[No workers'comp.insurance required.] 3.01 am a homeowner doing all work myself.[No workers'comp.insurance required.]t 9. ❑Demolition 100 Building addition 4.01 am a homeowner and will be hiring contractors to conduct all work on my property. I will ensure that all contractors either have workers'compensation insurance or are sole 11.0 Electrical repairs or additions proprietors with no employees. 12.0 Plumbing repairs or additions 5.0 I am a general contractor and I have hired the sub-contractors listed on the attached sheet. These sub-contractors have employees and have workers'comp.insurance.: 13.QRoof repairs 14.1Other Solar and ESS Install 6.❑We are a corporation and its officers have exercised their right of exemption per MGL c. 152,§1(4),and we have no employees.[No workers'comp.insurance required.] *Any applicant that checks box#1 must also fill out the section below showing their workers'compensation policy information. t Homeowners who submit this affidavit indicating they are doing all work and then hire outside contractors must submit a new affidavit indicating such. :Contractors that check this box must attached an additional sheet showing the name of the sub-contractors and state whether or not those entities have employees. If the sub-contractors have employees,they must provide their workers'comp.policy number. I am an employer that is providing workers'compensation insurance for my employees. Below is the policy and job site information. Insurance Company Name:New York Marine and General Insurance Policy#or Self-ins.Lic.#:WC333749A Expiration Date:4/30/2023 Job Site Address:56 Longfellow Dr. City/State/Zip:Northampton, MA 01062 Attach a copy of the workers'compensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under MGL c. 152,§25A is a criminal violation punishable by a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of a STOP WORK ORDER and a fine of up to$250.00 a day against the violator.A copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certify under the pains and penalties of perjury that the information provided above is true and correct Signature: Date: 12/30/2022 Phone#: Official use only. Do not write in this area,to be completed by city or town official • City or Town: Permit/License# Issuing Authority(circle one): 1.Board of Health 2.Building Department 3.City/Town Clerk 4.Electrical Inspector 5.Plumbing Inspector 6.Other Contact Person: Phone#: DATE(MM/DD/YYYY) A`E L1 CERTIFICATE OF LIABILITY INSURANCE 5(MMJD22 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER IN power CONTACT ower Global Insurance Services, LLC NAME: Nicole Doverspike 999 Corporate Drive, Suite 100 PHONE FAX Extl: (949)339-2799 (a/c,No): (949)600-7998 Ladera Ranch, CA 92694 E-MAIL ADDRESS: NDoverspike@INpowerGlobal.com INSURER(S)AFFORDING COVERAGE NAIC N www.INpowerGlobal.com CA DOI License No.6003712 INSURERA: Gotham Insurance Company 25569 INSURED INSURER B: New York Marine and General Insurance Co 16608 SunBug Solar, LLC, SunBug WM, LLC, SunBug, LLC 411 A Highland Ave#312 INSURER C: National Casualty Company 11991 Somerville MA 02144 ,INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 68126113 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUER POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER IMM/DD/YYYYI (MM/DD/YYYY) i COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $1,000,000 CLAIMS-MADE /I OCCUR I PR TOc ED PREMISES lEaa occurrence)currnence) $100,000 A PK202200025565 4/30/2022 4/30/2023 MED EXP(Any one person) $5,000 PERSONAL 8,ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY ✓ PEQ LOC PRODUCTS-COMP/OP AGG $2,000,000 OTHER: $ AUTOMOBILE LIABILITY (Ee BINEDISINGLE LIMIT $1,moD,00D ANY AUTO BODILY INJURY(Per person) $ B ✓ OWNED SCHEDULED ! AU202200016856 (MA) 4/30/2022 4/30/2023 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS ' AU202200018380 (CT) PROPERTY ✓ AUTOS ONLY AUTOS ONEYY (Per accidenDAMAGE $ UMBRELLA LIAR ,/ OCCUR EACH OCCURRENCE $5,000,000 A i EXCESS LIAB CLAIMS-MADE EX202200002326 4/30/2022 4/30/2023 AGGREGATE �i$5,000,000 DED / RETENTION$10,000 '$ WORKERS COMPENSATION PER AND EMPLOYERS'LIABILITY ✓ STATUTE EERH C OFF CEWMEMBEREXCLUDEDXANYRROPRIETORMARTNER/EXECUTIVE YNN N I A WC333749A 4/30/2022 4/30/2023 E.L.EACH ACCIDENT $1,000,000 (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1.000.000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 A Professional Liability-Claims Made PK202200025565 4/30/2022 4/30/2023 Each Wrongful Act: $1,000,000 Retroactive Date 01/01/2009 Aggregate Limit: $1,000,000 A Installation Floater PK202200025565 4/30/2022 4/30/2023 Any One Installation Project: $1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Evidence of Coverage CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Evidence of Coverage THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE 3 .e". ( -w — I Bart J.Le Fevre/KSK ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 68126113 1 22-23 GL AL XS WC PL IF 1 Nicole Doverepike 1 5/6/2022 8:61:51 AM (PDT) 1 Page I of 1 This certificate cancels and supersedes ALL previously issued certificates. WESTSHORE W No DESIGN ENGINEERS, P.C. - 100 GREAT OAKS BLVD. I SUITE 115 ALBANY I NEW YORK I 12203 To: SunBug Solar 66 Westfield Industrial Park Rd. Westfield, MA 01085 Date: November 22, 2022 Ref.: 22110256 Subject: Thomas Derr 56 Longfellow Dr. Northampton, MA To Whom it May Concern, The following references the Thomas Derr residence in Northampton, MA: 1. Existing roof framing: Conventional framing is 2x10 at 16"o.c.with a 15' span(horizontal rafter projection).This existing structure is capable to support all the loads that are indicated below for this photovoltaic project. 2. Roof Loading: - 4psf dead load (modules plus mounting hardware) - 40psf ground snow load - 6.9psf roof materials(2.9psf 2x10, 1.5psf sheathing, 2.5psf asphalt shingles) - Exposure Category B, 135mph wind gust(3 sec.) This installation design will be in general conformance to the manufacturer's specifications,and complies with all applicable laws, codes, and ordinances, specifically the International Building Code/IBC 2018 and International Residential Code/IRC 2018 including all MA regulations and amendments.Snap N Rack attachments at 48"o.c. maximum, staggered, with 5/16" lag and a 2.5" embed minimum for shingle roof. S-5! Clamps or equal attachments for metal roof. Thank you. HOFMASS Westshore Design Engineers yo�0. 4cyos NICOLAS A. N ITTI CIVIL ' NO. 50222 REGISTE0 FFSSIONA1.Et0�� 11/22/2022 John Eibert Nicolas Nitti, PE Project Coordinator President WestShore Design Engineers 1100 Great Oaks Blvd.I Suite 115 I Albany,NY 12203 1518.313.7153 4 SunBug Solar TURNKEY INSTALLATION AGREEMENT i i 11S AGREEMENT,dated U I I` Z 2-"(the"Effective Date")is entered int4,between: Thomas Derr ("Owner") and Sun Bug Solar,IJ.0("Inetalle ')whose physical address is 2A Draper Street,Woburn,MA 01801 and I IIC license number is 163091, for the installation and/or improvement of a solar system at the()wner's premises located at:56 Longfellow Dr., Northampton,MA 01062 (the "Premises"),all as more specifically described below(the"Project"). A. TI-IE WORK installer has previously submitted,and Owner has approved the Proposal for the Project(the"Proposal"). By way of summary only,Installer's Scope of Work consists of the following elements as indicated: Materials Procurement Permitting (:ompletion of Incentive Paperwork "Turnkey Installation I lectrical interconnection Support Owner Operation Training Customer is ncpos able for pronitling Intent ronnection for online monitoring,retinas. B. CONTRACT DOCUMENTS. This Turnkey Installation Agreement together with the Terms&Conditions set forth'below (the"Terms and Conditions""),any change orders executed by the parties ("Change Orders}")and the Proposal(�ach of which are incorporated herein by reference and may be referred to as the "Contract Document$") comprise the entire agreement of the parties and may be referred to as"this Agreement." C. CONTRACT SUM.PAYMENTS,REBATES. C 1. "lhc cost of the Project,including all materials,labor and Installer's fees(described as the gross price in the Proposal) is $26,111.00 dollars("Guaranteed Maximum Price"). "The Guaranteed Maximum Price is a fixed price,not an estimate, and can only be changed by the parties executing and delivering a Change Order(see Section 10 of the Terms&Conditions for more information on Change Orders). However,the cost of the Project may be affected by unanticipated regulatory requirements(eg.,such as wetlands studies),unforeseen site conditions discovered after Installer's engineering analysis (e.g., structural reinforcement or roof repair),expenses related to utility interconnection approval(e.g.,transformer upgrade), or additional unforeseen expenses required by the local municipality to obtain required permit approvals. if this is the case,a Change Order reflecting a new Guaranteed Maximum Price will be required in order for the Project to continue. (:2. Owner will make payments to Installer in accordance with the following schedule: Payment Terms Amounts Down payment 1,000.00 60%due on Order of Materials 15,666.00 35%due on Commencement of Construction 9.138.00 Due on submission of Utility Certificate of Completion 307.00 Total $26,111.00 C 3. Installer is ordering materials on behalf of Customer and will warehouse materials until time of installation. C 4. Installer may bill Owner partial progress payments for construction work(e.g.,when some work is scheduled to be done before or after our primary construction mobilization we may bill a portion of the construction payment for that work; rough-in electrical work,critter guard,etc.) C S. installer shall apply,on behalf of Owner,for applicable rebates including any rebates as offered by Owner's utility service.Unless otherwise noted below,any rebates shall be payable directly to Owner subject to utility or other third-party approval.Owner acknowledges that rebates payable to Installer have reduced the contract sum payable to installer by()i.oner. o Rebates will be paid directly to installer(Cheek only it-rebates to hutman). C 6. If requested by Owner, installer shall submit required preapproval paperwork for the Clean Energy Credit Union or UMassFive MvSolar Loan programs. In that case,this Agreement and subsequent work is contingent on program loan approval(the"Loan Approvals'). C 7. installer shall secure all necessary construction related permits,other permits and/or governmental licenses and inspections necessary for the completion of the Project. Unless otherwise noted,fees associated with acquiring such Permits, licenses and inspections will be borne by Installer. C 8. Installer's obligations are specifically conditioned on the receipt of payment in full of the above amounts at tl a times specified.Without limiting the foregoing,delayed payments shall accrue interest at the rate of 1.0%per month.Owr shall be responsible for reasonable attomey's fees borne by Installer in collecting any past due payments. D. NOTICE OF RIGHT TO CANCEL Owner may cancel this Agreement and the transactions contemplated hereby with no liability at any time prior to midnight on the third business day following the Effective Date. Paste 1 of 6— SUNBUG SOLAR.LLC 0 2022 INSTALLATION AGREEMENT E. CONFLICTS. In the event of a conflict between this Turnkey Installation Agreement and any Contract Document or between the Terms and Conditions and any other Contract Document, this Turnkey Installation Agreement and the Terms and Conditions,respectively,shall govern. DO NOT SIGN THIS CONTRACI'IF THERE ARE ANY BLANK SPACES Entered into as of the Effective Date: OWNEjt/� SUNBUG SOLAR,LLC ''" [signature] By: 62 2J_ / 1--o 2- Z-- By:Ben Mayer,Sales Manager Date: Solar Consultant: Daniel Britton Pam 2 of 6— SUNBUG SOLAR.LLC C 2022 INSTALLATION AGREEMENT 4 SunBug Solar* TERMS & CONDITIONS These Terms&Conditions are incorporated by reference into that certain Turnkey Installation Agreement between Installers and Owner(together with these Terms&Conditions and the other documents incorporated by reference therein,this"Agreement")and applies to all products and services furnished by Installer thereunder. Capitalized terms used but not otherwise defined in these Terms&Conditions shall have the meanings assigned to them in the documents comprising this,\greernent. 1. TIME OF COMMENCEMENT&SUBSTANTIAL COMPLETION. 1.1. Work on the Project(including all labor,materials,equipment and services,whether completed or partially completed under this Agreement,the"Worn')will,unless otherwise scheduled in the Proposal,commence no later than sixty days(60)following the receipt of all applicable approvals including but not limited to the CEC Loan Approvals(the"Stan Date"). 1.2. Installer estimates that the Work will be substantially completed within one hundred twenty(120)days following the Stark Date (the"Completion Date"). Substantially complete shall be defined as the date the Owners receive a utility interconnection,or similar such certification from the applicable authority. 1.3. If the Work is delayed at any time by causes beyond Installer's reasonable control,which causes may include,but not be limited to, weather, acts of war or terrorism, material shortages, delays in the delivery of materials, Change Orders, inspection/permitting delays, labor disputes, design changes, hazardous site conditions, design flaws or impai9nents, subcontractor disputes,or Owner's use or directives,then the Completion Date will be extended for such equal number of days as occasioned the delay. In addition,the Completion Date may be extended for such reasonable time as Owner and Installer may determine in writing pursuant to a Change Order. 1.4. Installer shall have all materials required to commence the Work at the Premises no later than the Start Date. 1.5. installer shall supervise and direct the Work in accordance with industry and regulatory standards,and it shall be solely responsible for all construction means,methods,techniques,sequences and procedures and for coordinating all portions of the Work hereunder. 2. WARRANTIES OF INSTALLER. 2.1. Installer warrants to Owner that all materials,equipment,and accessories incorporated into the Work by Installer will be new unless otherwise agreed in the Proposal. Except for the warranty specified in this Section 2.1,Installer disclaims any and all warranties with respect to any materials,equipment,or accessories incorporated into the Work,it being the understanding of Owner that such warranties,if any,shall be provided by the manufacturer thereof. 2.2. installer warrants to Owner that all labor and services provided by Installer and included in the Work shall be of good quality, free from material defects,and in material conformance with the Contract Documents. 2.3. Upon written notice from Owner delivered to Installer no later than the t0 year anniversary date of the Completion Date, installer shall promptly correct any labor and services in breach of Section 2.2 above.Installer's obligation to promptly Correct any labor and services in breach of Section 2.2 shall be Owner's sole and exclusive remedy for Installer's breach of 2.2 above. The provisions of this Article apply to Work performed by third parties engaged by installer as well as to work done by direct employees of Installer. 2.4. To the extent assignable,Installer shall pass through to Owner all original manufacturers'warranties and shall provide f)caner with its reasonable assistance in connection with any warranty claim against a manufacturer for defective materials,equipment, or accessories incorporated into the Work by installer.Installer makes no representation or warranty regarding the warranties of manufacturers whose materials, equipment,or accessories are incorporated into the Work. Owner acknowledges that manufacturers'warranties may provide coverage to Owner for replacement of defective materials,equipment,or accessories, but that an individual manufacturer's warranty may not cover 100%of the costs and expenses borne by installer to troubleshoot and/or replace defective materials,equipment,or accessories.Payment to Installer for such uncovered corrective maintenance costs and expenses shall be Owner's responsibility. 2.5. Enhanced Product Warranty. In instances where Installer is required to troubleshoot and/or replace defective materials, equipment,or accessories incorporated into the Work by installer prior to the first anniversary date of the Completio>}t Date, Installer shall waive all of its direct labor costs associated therewith in excess of the amount covered by the manufacturer's warranty,and Owner shall not be required to pay Installer such excess amount.Within the first year following the Comtpletion Date,Owner may optionally select to purchase an extension to Installer's Enhanced Product Warranty through the. tenth anniversary date of the Completion Date. Battery storage equipment, electric vehicle charger equipment,and/or'tracker equipment(single-or dual-axis) incorporated into the Work by Installer are not eligible for Enhanced Product Warranty coverage.With the exception of Installer's direct labor costs,other direct and indirect expenses(including equipment rentals) incurred by Installer in conjunction with the troubleshooting and/or replacement of defective materials, equipment,or accessories incorporated into the Work by installer are also not eligible for Enhanced Product Warranty coverage. Pace 3 of 6— SUNBUG SOLAR.LLC C 2022 INSTALLATION AGREEMENT 2.6. Notwithstanding anything contained herein to the contrary,Installer's warranties and obligations under this Article 2 do not extend to(i)any materials,equipment,or accessories not selected by Installer or its agents,or to work performed by third parties not engaged by Installer, (ii) any damage to the Work due to weather,animal infestation,or other external factors unrelated to Installer's installation workmanship, or (iii) the effectiveness of any accessories incorporated into the Work including,by way of example,pest abatement barriers(so-called critter guards)and snow abatement systems(so-called snow guards).Damage or defect caused by abuse,modifications not executed by Installer,improper or insufficient maintenance, improper operation,or normal wear and tear shall void Installer's warranties and obligations hereunder. 2.7. Installer disclaims any and all warranties or guarantees with respect to the level of electrical production of the Project. Information with respect to electrical production of the Project is based on manufacturer's estimates of installed materials,and of peak sun hours,sun direction,and other factors. Factors such as dust,shading,snow,ice,weather,and other natural and man-made elements,including usage,may adversely affect electrical production. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND IN LIEU OF ALL OTHER WARRANTIES OF QUALITY AND PERFORMANCE, WI-ILTFIER WRITTEN, ORAL OR IMPLIED, AND ALL OTHER WARRANTIES INCLUDING ANY IMPLIED WARRANTIES OF MERCFIANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, NONINFRINGEMENT OR USAGE OF TRADE ARE HEREBY DISCLAIMED. THE REMEDIES STATED HEREIN CONSTITUTE OWNER'S EXCLUSIVE REMEDIES AND INSTALLER'S ENTIRE LIABILITY FOR ANY BREACH OF WARRANIY. 3. COMPLIANCE WITH LAWS. 3.1. Unless otherwise specified in this Agreement,Installer shall secure all necessary permits,any applicable rebate applications, other governmental licenses and inspections necessary for the completion of the Project. Unless otherwise specified in this Agreement,fees associated with acquiring such permits,licenses and inspections will be borne by Installer. 3.2. Owner shall furnish at Owner's expense,all of the following as deemed necessary by the Installer: 3.2.1. Legal descriptions (including legal limitations such as easements, rights of way, codes, covenants, conditions,restrictions,design guidelines),surveys and utility locations for the Premises;and 3.2.2. Any required engineering plans,drawings,calculations,or specifications(the"Additional Plans")(i) in order to obtain any required non-ministerial permits or inspections,or(il)in order to adequately secure the Premises and provide reasonable safety precautions.Owner acknowledges that some municipalities,utilities or other necessary permitting parties may require specific engineering studies or inspections in addition to those customary required or already obtained by Owner 3.3. Installer shall give all notices and comply with all laws,ordinances,rules,regulations,and lawful orders of any public authority applicable to the performance of the Work,and shall promptly notify Owner if it has a reasonable basis to conclude that the designs,plans or Additional Plans are at variance therewith. 3.4. Installer shall be responsible for all safety precautions in connection with the Work. Installer shall take all legally required and commercially reasonable safety precautions at the Premises. 3.5. Installer and all subcontractors shall be registered as home improvement contractors and any inquiries relating to a registration should be directed to:Office of Consumer Affairs and Business Regulation Ten Park Plaza,Suite 5170 Boston,MA 02116 Phone:(617)973-8700 4. INSURANCE. Installer's liability insurance shall be purchased and maintained by the Installer to cover claims under workers' compensation acts and other employee benefit acts,claims for damage because of bodily injury,including death,and from claims for property damage to the Premises which may arise out of or result from Installer's operations under this Agreement,whether such operations be by itself or by any subcontractor or anyone directly or indirectly employed by any of them.This insurance shall be written for not less than the minimums required by the state where the Project is located under applicable law and state rebate programs.Certificates of such insurance shall be filed with Owner prior to the commencement of the Work at Owner(s)'request. Owner shall maintain liability insurance(either as separate policy or included in a homeowners or excess liability policy)sufficient to meet the Owner indemnity obligations under Section 8 below. 5. SUBCONTRACTORS, Owner acknowledges that portions of the Work may be allocated to Subcontractors. Installer shall not employ any subcontractor to whom the Owner may have a reasonable objection. Installer shall not be required to contract with anyone to whom it has a reasonable objection.The Guaranteed Maximum Price includes the cost of a qualified electrician for electrical interconnection to the utility. Unless specifically noted in the Proposal, additional costs for any required electrical upgrades or improvements to the site's electrical service and components shall be the responsibility of Owner and arc not included in the Guaranteed Maximum Price. 6. SITE CONDITIONS. Owner has no knowledge of any pre-existing toxic materials, hazardous substances, or defective or dangerous conditions,structural or otherwise which may pose a health or injury risk to Installer or Installer's employees or agents. Pane 4 of 6— SUNBUG SOLAR LLC©2022 INSTALLATION AGREEMENT In the event that Installer observes hazardous site conditions,Installer will notify Owner promptly and Owner and Installer will,if feasible,execute a Change Order for the remediation of such conditions.Such hazardous conditions will postpone the Completion Date by the amount of days required to complete remediation.The Guaranteed Maximum Price includes the cost of basic site preparation,but does not include the cost of any remedial site preparation as contemplated in this Section.The cost of such remedial site preparation shall be the responsibility of Owner. 7. INCENTIVE APPLICATIONS. Unless otherwise set forth in this Agreement,Installer shall apply for available incentives on behalf of Owner.Owner will assist installer in such application process and warrants that all Owner information provided therein (including financial information,home value information and other personal information)shall be true,correct and complete as of the date of the application.Owner agrees that installer will be listed as the primary installer/contractor on any application and be credited as the installer of record on all public documents and correspondence concerning the Project. Owner hereby acknowledges that Installer makes no warranty or guarantee of the availability of all,or any part of,any federal,state,local or utility incentives,tax credits or deductions.Owner is encouraged to roeualt with a lax advisor as to the availability of tax needs with trilled to the Project. 8. INDEMNITY. 8.1. To the fullest extent permitted by law,Owner shall indemnify,hold harmless and reimburse Installer,its agents and employees from and against all claims,damages,losses and expenses(including,but not limited to reasonable attomey's fees)arising out of or resulting from any death,bodily injury or illness or destruction to property,including any resulting loss of use thereof(i) due to a breach of Owner's warranty contained in the first sentence of Section 6 above or(ii)to the extent resulting from the negligence or misconduct of Owner or its invitees or agents (other than Installer and its subcontractors). Owner's indemnification obligations herein are conditioned upon the following:(a)it is promptly notified in writing;provided,that the indemnified party's failure to promptly notify shall not relieve the indemnifying party of its obligations hereunder to the extent the indemnifying party is not actually prejudiced,(b)Owner is allowed to exercise sole control over the defense of any claim and all related settlement negotiations(with counsel reasonably acceptable to the indemnified party);and(c)the indemnified party provides Owner,at Owner's expense,all reasonably necessary assistance,information,and authority to perform the above. 'Ilse indemnified party shall have the right to participate in its defense with counsel of its own choosing at the indemnified party's sole cost and expense. 8.2. The foregoing notwithstanding,Owner will not make any offers of settlement nor enter into any settlement agreements without the written consent of the indemnified party,which consent will not be unreasonably withheld or delayed. 9. I,IIVIII'ATIONS ON DAMAGES AND LIABILITY. Except in connection with Owner's obligations under Section 8,each party's liability to the other party for any loss,cost,claim,injury,liability,or expense,including reasonable attomey's fees,relating to or arising from any act or omission in its performance of this Agreement,shall be limited to the amount of direct damage actually incurred. Except in connection with Owner's obligations under Section 8,in no event shall either party be liable to the other party for any indirect, incidental, special, consequential, or punitive damages of any kind whatsoever. This waiver shall survive any termination of this Agreement. 10. CHANGE IN THE WORK Owner,without invalidating this Agreement,may seek changes in the Project consisting of additions, deletions,or modifications.In addition,changes in the Project may be necessitated by permitting or regulatory requirements.All such changes in the Project shall be authorized by a written Change Order signed by Owner and Installer. Installer will advise Owner of the cost of a proposed Change Order,and,if executed,the Guaranteed Maximum Price or price per watt will be adjusted accordingly. All Change Orders will include revision of the Completion Date. 11. TERMINATION. 11.1. If a Change Order is necessary to complete the work,either party has the option to terminate the agreement. 11.2. Either party may terminate this Agreement by a written notice(a"Default Notice")if the other party commits any material breach of this Agreement;provided,that if such breach is capable of cure,such party shall have seven(7)days following its receipt of a Default Notice(the"Cure Period")to cure such breach to the non-breaching party's reasonable satisfaction.if such breach is not cured prior to the expiration of the Cure Period,the non-breaching party may terminate this Agreement immediately by written notice. By way of example only,material breaches include the following: (a)Owner fails to make a payment when due(in which event Installer may,in its discretion,also suspend work until payment is made);(b)Owner fails to promptly execute a Change Order necessitated by a revision in the Minimum Technical Requirements of a permitting body or regulator,(c)I nstaller persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; (d) Installer fails to make payment to subcontractors for materials or labor in accordance with the respective agreements between the Installer and subcontractors;and (e) Installer persistently disregards laws,ordinances,or rules,regulations or orders of a public authority having jurisdiction. 11.3. If the CEC Loan Approvals are not obtained,this Agreement shall automatically terminate unless Owner provides Installer with prompt written notice that it wishes to proceed with the Project. 11.4. Either Owner or installer may terminate this Agreement upon fifteen(15)days prior written notice,if the parties are unable to promptly agree on the terms of a Change Order reasonably necessary for the completion of the Project(Lg.,changes due to regulatory requirements or hazardous conditions). Paee 5 of 6— SUNBUG SOLAR.LLC©2022 INSTALLATION AGREEMENT 11.5. If this Agreement is terminated for any reason,Owner shall pay Installer for all work completed and materials used through the date of termination. 11.6. Notwithstanding anything to the contrary set forth herein,Sections 2,the first sentence of Section 6,8,9,11(d),11(e),12,13 and 14 of this Agreement and any remedies for the breach thereof,shall survive the termination of this Agreement under the terms hereof. Termination of this Agreement shall not relieve or release either party from any rights,liabilities or obligations which it or she has accrued prior the effective date of such termination. 12. CHOICE OF T.A.W. 'Ibis Agreement shall be governed by the internal laws of the Commonwealth of Massachusetts without regard to principles of conflicts of laws. Disputes arising hereunder shall be adjudicated solely and exclusively in Boston,Massachusetts. 13. PROMOTIONAL USE OF PROJECT. Installer may use the description and images of the project along with any supplied recommendations or testimony of Owner for promotional purposes. (If promotional consent not,granteeh or if owner requires indinidualprior written consent,cheek here:0) 14. GENERAL PROVISIONS. This Agreement set forth the entire agreement and understanding between Owner and Installer relating to the subject matter hereof,and merges all prior discussions between them. If any one or more of the provisions in this Agreement arc deemed void by law,then the remaining provisions will continue in full force and effect. No waiver by either party of any term or condition of this Agreement,whether by conduct or otherwise,in any one or more instance,shall be deemed a continuing waiver of any such term or condition,or a waiver of any other term or condition of this Agreement. Headings set forth in this Agreement are solely for the convenience of the parties and have no legal effect. The singular shall include the plural,and the masculine gender shall incude the feminine and neuter,and vice versa,unless the context otherwise requires.This Agreement may be executed and delivered either originally or by facsimile transmission,and in one or more counterparts,each of which shall be deemed an original and all of which taken together shall constitute one and the same instrument. Thus Agreement shall be(i)binding upon,and will inure to the benefit of,the parties and their permitted respective successors and assigns and(ii)construed without presumption of any rule requiring construction to be made against the party causing it to be drafted. Pate 6 of 6— SUNBUG SOLAR.LLC©2022 INSTALLATION AGREEMENT . , ..: • .: LGNON®R ... .,.. CD LG435QAC-A6 '''.. *::- .1 435W LG NeON®R is powerful solar module that provides world-class - _ performance.A new cell structure that eliminates electrodes on - the front maximizes the utilization of light and enhances reliability. - r LG NeON®R is a result of LG's efforts to increase customer's - _ - r 41111, values beyond efficiency.LG NeON®R features enhanced durability, /�, . P4*Air performance under real-world conditions,an enhanced warranty and aesthetic design suitable for roofs. _ •• 1114. ••• C (1) US 0 YEAR � 41P41Ir PRODUCT•PERFORMANCE•LABOR Features + Roof Aesthetics ® 25-Year Limited Product Warranty LG NeON®R has been designed with The NeON®R is covered by a 25-year limited aesthetics in mind:the lack of any product warranty.In addition,up to$450 of electrodes on the front creates an labor costs will be covered in the rare case that improved,modern aesthetic. a module needs to be repaired or replaced. • Enhanced Performance Warranty More generation per square meter 2 The LG NeON®R has an enhanced 6 The LG NeON®R has been designed to performance warranty.After 25 years, significantly enhance its output,making LG NeON®R is guaranteed at least it efficient even in limited space. 92.5%of initial performance. When you go solar, ask for the brand you can trust: LG Solar About LG a Electronics USA,Inc. �� LG Electronics is a global leader in eelectronicp products in the clean energy markets by offering solar PV panels and energy storage systems The company first embarked on a solar energy source research program in 1985,supported by LG Groups vast experience in the semi-conductor,LCD,chemistry and materials industries.In 2010,LG Solar successfully 110 released its first Mono.series to the market,which is now avglable in 32 countries.The NeON*(previous MonoX•NeON),NeONa2,NeONe2 BiFacial won the"Intersolar Llfe'S Good AWARD'in 2013,2015 and 2016,which demonstrates LG's leadership and innovation in the solar industry. LG NeON®R LG435QAC-A6 General Data Electrical Properties(STC*) Cell Properties(MateriaVType) Monocrystalline/N-type Model LG435QAC-A6 Cell Maker LG -Maximum Power(Pmax) [W] I 4 5 Cell Configuration 66Cells(6x11) MPP Voltage(Vmpp) [V] I 4.1 Module Dimensions(L x W x H) 1,910mm x 1,042mm x 40mm MPP Current(Impp) [A] 1 59 Weight 20.5 kg Open Circuit Voltage(Voc,t 5%) ]V[ 4..0 Glass(Material) Tempered Glass with AR Coating Short Circuit Current(Isc,t 5%) [A] 11[20 Backsheet(Color) White Module Efficiency [%] 21.9 Frame(Material) Anodized Aluminium Power Tolerance [%] I 0-+3 Junction Box(Protection Degree) IP 68 with 3 Bypass Diodes *STC(Standard Test Condition).Irradiance 1000 W/m',Cell temperature 25*C,AM 1.5 - - Measure Tolerance:t 3% Cables(Length) 1,250mm x 2EA Connector(Type/Maker) MC 4/MC Operating Conditions Operating Temperature (C] -40-+85 Certifications and Warrant y Maximum System Voltage [V] 1,000 IEC 61215-1/-1-1/2:2016,IEC 61730-1/2:2016, Maximum Series Fuse Rating (A] 20 0L61730-1:2017,UL61730-2:2017 - -- Certifications ISO 9001,ISO 14001,ISO 50001 Mechanical Test Load"(Front) (Pa/psf] 5,400 OHSAS 18001 Mechanical Test Load"(Rear) [Pu/psf] 4,000 Salt Mist Corrosion Test IEC 61701:2011 Severity6 *The operating ambient temperature of these devices may exceed 40*C at full load for all wire sizes if is determined suitable In the field use application. I Ammonia Corrosion Test IEC 62716:2013 **Based on IEC 61215-2 2016(Test Load-Design Load x Safety Factor(1.5)) Hail Test 25mm(1")diameter at 23m/s(52mph) Module Fire Performance Type 1(UL 61730) Packaging Configuration Fire Rating Class C(UL 790,ULC/ORD C 1703) Number of Modules per Pallet [EA] 25 Solar Module Product Warranty 25 Years Number of Modules per 40'Container [EA] 600 Solar Module Output Warranty Linear Warranty' Number of Modules per 53'Container [EA] 800 *Improved:1•year 98.5%from 2-24th year-0.25%/year down,92.5%at year 25 Packaging Box Dimensions(L x W x H) Porn] 1,960 x 1,20 x 1,221 Packaging Box Dimensions(L x W x H) [in] 77.2 x 44.1 x 48.1 Temperature Characteristics Packaging Box Gross Weight [kg] 49 NMOr ['C] I, 44 t 3 Packaging Box Gross Weight [lb] 1, 10 Pmar (%PC) I -0.29 _.. Voc (96PC) -0.24 isc [WTI 004 Dimensions(mm/inch) *NMOT(Nominal Module Operating Temperature):Irradiance 800 W/m',Ambient temperature 20*C, . W nd speed 1 m/s,Spectrum AM 1.5 1042.0/41.0(Size of Short Side) Electrical Properties(NMOT) - • 175.0/6.9 ' Model LG435QAC•A6 r;1002.0/39A(Mooe bemoan Holesbemoan40.0/157 Maximum Power(Pmax) [W] 330 MPP Voltage(Vmpp) `-[V] 388 R 16-a0x3.0/03x0.1 _ ' _ _. -. ----- aa / ln HolesIM MPP Current(Impp) [A] 8.49 ( (+) 9-e4.3/0.2 Open Circuit Voltage(Voc) [V] 45.8 Giaiii4ig Holes A Short Circuit Current(1st) [A] 9.02 4-85412.0/03z05 Mounting Homes • 1250.0/49.2 I-V Curves a Cable Length g 12.0- & 1000W 110.0 800W 8.0- 9. i 600w I I 54.3 6.0- 400W u 4.0- 200W 2.0 ` " V 0.0 0.0 5.0 10.0 15.0 20.0 25.0 30.0 35.0 40.0 45.0 N, Vottage M ® LG Electronics USA,Inc. Product specifications are subject to change without notice. LG Solar Business Division LG435QAC-A6 pdf Linc Mi Drive 021221 Lincollnshhire,re,IL IL 60069 Life s Good www.lg-solaccom 0 2021 LG Electronics USA,Inc.All rights reserved. SnapNrack' UR-40 Solar Mounting Solutions UR-60 Ultra Rail 11 The Ultimate Value in Rooftop Solar Industry leading Wire Mounts available for all Management Solutions roof types Single Tool Installation All SnapNrack Module Clamps & Accessories are compatible with both raiil profiles Start Installing Ultra Rail Today RESOURCES snapnrack.com/resources DESIGN snapnrack.com/configurator WHERE TO BUY snapnrack.com/where-to-buy SnapNrack Ultra Rail System A sleek, straightforward rail solution for mounting solar modules on all roof types. Ultra Rail features two rail profiles; UR-40 is a lightweight rail profile that is suitable for most geographic regions and maintains all the great features of SnapNrack rail, while UR-60 is a heavier duty rail profile that provides a larger rail channel and increased span capabilities. Both are compatible with all existing mounts, module clamps, and accessories for ease of install. The Entire System is a Snap to Install • New Ultra Rail Mounts include snap-in brackets for attaching rail • Compatible with all the SnapNrack Mid Clamps and End Clamps customers love • Universal End Clamps and snap-in End Caps provide a clean look to the array edge Unparalleled Wire Management • Open rail channel provides room for running wires resulting in a long-lasting quality install 1111101, 11440 • Industry best wire management offering includes Junction Boxes, Universal Wire Clamps, MLPE Attachment Kits, and Conduit Clamps • System is fully bonded and listed to UL 2703 Standard Heavy Duty UR-60 Rail • UR-60 rail profile provides increased span capabilities for high wind speeds and snow ' loads • Taller, stronger rail profile includes profile- specific rail splice and end cap • All existing mounts, module clamps, and accessories are retained for the same great install experience Quality. Innovative . Superior. SnapNrack Solar Mounting Solutions are engineered to optimize material use and labor resources and improve overall installation quality and safety. 877-732-2860 www.snapnrack.com contact a snapnrack.com I DESCRIPTION: DRAWN BY: SNAPNRACK, ULTRA RAIL COMP KIT mwatkins SnapNvack- Solar MountingSolutions REVISION: PART NUMBER(S): B 505 MARKET STREET,28TH FLOOR.SAN FRANCISCO CA 54105 USA PHONE(415)5808800.FAX(415)580-W02 SEE BELOW RR R00000UII INTMSUR ORUlS GThEREOF ISP OOIPROPRIThOU ThE REPRCN%iC110N.NRITTE5 CONSENT SUNRUN ISPITS LUC EO WITNOUT THE NRITTEN CONSENT 65UNRUN 9WTH LLL. O '<l'4') 0 u u u u u 0• T0 aiiii.,:,,,:,:,.,: ,,:7,0<z,,,,,,:. PARTS LIST ITEM QTY PART NUMBER DESCRIPTION 1 1 242-92266 SNAPNRACK, UMBRELLA LAG, TYPE 3, 4IN, SS 2 1 242-01219, 242-01220 SNAPNRACK, ULTRA FOOT FOR U FLASHING, SILVER/ BLACK 3 1 232-01375, 232-01376 SNAPNRACK, COMP FLASHING, 9IN X 12IN, SILVER/ BLACK ALUM MATERIALS: 6000 SERIES ALUMINUM, STAINLESS STEEL, RUBBER DESIGN LOAD (LBS): 405 UP, 788 DOWN, 236 SIDE ULTIMATE LOAD (LBS): 2006 UP, 4000 DOWN, 1070 SIDE TORQUE SPECIFICATION: 12 LB-FT CERTIFICATION: UL 2703, FILE E359313; WIND-DRIVEN RAIN TEST FROM UL SUBJECT 2582 WEIGHT (LBS): 0.80 DESCRIPTION: DRAWN BY: SNAPNRACK, ULTRA RAIL COMP KIT mwatkins Snap_Nrack. REVISION: Solar Mounting Solutions PART NUMBER(S): B 595 MARKET STREET,29TH FLOOR.SAN FRANCISCO,CA 94105 USA PHONE(415)5906900.FAX(415)550.5902 SEEBELOW THE INFORMATION IN THIS DRAWNO IS CONFIDENTIAL AND PROPRIETARY ANY REPROOIKTON,MITTENURE,OR USE THEREOF IS PROHISITEDNITHOVTTNE 055 SNCONSENT OF SUTAIAI SCUM U C UMBRELLA L FOOT PROPERTIES SKU DESCRIPTION 242-01219 ULTRA RAIL UMBRELLA L FOO , SILVER C4.,. 242-01220 ULTRA RAIL UMBRELLA L FOOT, BLACK 1.3701.00 N. - .38 .30 /y� 1 1.00 A SLOT ® L,lill�llll_ �\1\11 1.50 - O 2.78 ' 13.25 lirr1.78 -.--1.62 IIIIIIIIIIIIIIIIIII 1.80-H H-150H COMP FLASHING PROPERTIES SKU DESCRIPTION 232-01375 COMP FLASHING, 9" X 12", BLACK ALUM 232-01376 COMP FLASHING, 9" X 12", SILVER ALUM - - 6.75 SnapN rack .30 01.00�. _ Tpfo I61P G`�7mWt�Pm�IIa➢�PKi d 1 11.75 _ _ _i__ o e 4.20 105° I= i > C\--- y 0.35 3.25 - 8.75- ► .45 He-- ALL DIMENSIONS IN INCHES Single Phase Energy Hub O Inverter with Prism Technology For North America SE3000H-US/SE3800H-US/SE6000H-US/SE7600H-US/ m SE10000H-US / SE11400H-US(1 12-25 YEAR WARRANTY • C • solar=}' ..HD _ S r • o 0110 • 0 Optimized battery storage with HD-Wave technology / Record-breaking 99%weighted efficiency with / Multi-inverter,scalable storage solution 200%DC oversizing / With enhanced battery power up to 10kW / Small,lightweight,and easy to install / Integrated arc fault protection and rapid shutdown for NEC 2014,NEC 2017 and NEC 2020,per article / Modular design,future ready with optional 690.11 and 690.12 upgrades to: / DC-coupled storage for full or partial home backup / Embedded revenue grade production data,ANSI / Built-in consumption monitoring C12.20 Class 0.5 / Direct connection to the SolarEdge smart EV charger solaredge.com solar • '• W / Single Phase Energy Hub Inverter with Prism Technology For North America SE3000H-US/SE3800H-US/SE6000H-US/SE7600H-US/SE10000H-US/ SE11400H-US(1) SE3000H-US SE3800H US SE6000H-US SE7600H-US SE10000H-US SE11400H-US UNITS OUTPUT-AC ON GRID Rated AC Power 3000 3800 @ 240V 6000 @ 240V 7600 10000 11400 @ 240V W 3300 @ 208V 5000 @ 208V 10000 @ 208V Maximum AC Power Output 3000 3800 @ 240V 6000 @ 240V 11400 @ 240V 7600 10000 W 3300 @ 208V 5000 @ 208V 10000 @ 208V AC Frequency Range(min-nom-max) 59.3-60-60.5,4 Hz Maximum Continuous Output Current @ 240V 12.5 16 25 32 42 47.5 A Maximum Continuous Output Current @ 208V - 16 24 48.5 A GFDI Threshold 1 A Total Harmonic Distortion(THD) <3 % Power Factor 1,adjustable-0.85 to 0.85 Utility Monitoring,Islanding Protection,Country Configurable Thresholds Yes Charge Battery from AC(if allowed) Yes Typical Nighttime Power Consumption <2.5 W OUTPUT-AC BACKUP') Rated AC Power in Backup Operationi°< 3000 38000 6000 7600 10300* 10000 10300 W AC L-L Output Voltage Range in Backup 211-264 Vac AC L-N Output Voltage Range in Backup 105-132 Vac AC Frequency Range in Backup(min-nom-max) 55-60-65 Hz 16 32 Maximum Continuous Output Current in Backup Operation 12.5 32* 25 43* 42 43 A GFDI 1 A THD <5 % OUTPUT-SMART EV CHARGER AC I Rated AC Power 9600 W AC Output Voltage Range 211-264 Vac On-Grid AC Frequency Range(min-nom-max) 59.3-60-60.5 Hz Maximum Continuous Output Current @240V(grid,PV and battery) 40 Aac INPUT-DC(PV AND BATTERY) Transformer-less,Ungrounded Yes Max Input Voltage 480 Vdc Nom DC Input Voltage 380 Vdc Reverse-Polarity Protection Yes Ground-Fault Isolation Detection 600k0 Sensitivity INPUT-DC(PV) J 7600 15200 Maximum DC Power @ 240V 6000 15200* 12000 22800* 22000 22800 W • Maximum DC Power @ 208V - 6600 10000 - - 20000 W 10.5 20 Maximum Input Current(5)@ 240V 8.5 20* 16.5 31* 27 31 Adc Maximum Input Current°l @ 208V - 9 13.5 - , - 27 Adc Max.Input Short Circuit Current 45 1 Adc Maximum Inverter Efficiency 99 99.2 % 99 @ 240V CEC Weighted Efficiency 99 98.5 @ 208V 2-pole Disconnection Yes *Supported with PN SExxxxH-USMMxxxmx or SExxxxH-USMNxxis xx (1)These specifications apply to inverters with part numbers SEiexxcH-USSMmrmx or SExxxxH-USSNxxxxxx and connection unit model number DCD-IPH-US-PxH-F-x (2)For other regional settings please contact SolarEdge support (3)Not designed for standalone applications and requires AC for commissioning.Backup functionality is only supported for 240V grid (4)Rated AC power in Backup Operation are valid for installations with multiple inverters.For a single backup inverter operation,rated AC power in Backup is 90%of the value stated (5)A higher current source may be used;the inverter will limit its input current to the values stated I Single Phase Energy Hub Inverter with Prism Technology For North America SE3000H-US/SE3800H-US/SE6000H-US/SE7600H-US/SE10000H-US/ SE11400H-USm SE3000H-US SE3800H-US SE6000H-US SE7600H-US SE10000H-US SE11400H-US UNITS IN'I - 9 ER ) Supported Battery Types SolarEdge Energy Bank,LG RESU Primed Number of Batteries per Inverter Up to 3 SolarEdge Energy Bank,up to 2 LG RESU Prime Continuous Power(?) 6000 7600 10000 W Peak Power(?) 6000 7600 10000 W MaxlnputCurrent 16 20 26.5 Adc 2-pole Disconnection Yes SMART ENERGY CAPABILITIES Consumption Metering Built-ino) Backup&Battery Storage With Backup Interface(purchased separately)for service up to 200A;Up to 3 inverters EV Charging Direct connection to Smart EV charger ADDITIONAL FEATURES Supported Communication Interfaces RS485,Ethernet,Cellularnl,Wi-Fi(optional),SolarEdge Energy Net(optional) Revenue Grade Metering,ANSI C12.20 Built-inoi Integrated AC,DC and Communication Connection Unit Yes Inverter Commissioning With the SetApp mobile application using built-in Wi-Fi Access Point for local connection DC Voltage Rapid Shutdown(PV and Battery) Yes,according to NEC 2014,NEC 2017 and NEC 2020 690.12 STANDARD COMPLIANCE Safety UL1741,UL1741 SA,UL1741 PCS,UL1699B,UL1998,UL9540,CSA 22.2 Grid Connection Standards IEEE1547,Rule 21,Rule 14H Emissions FCC part 15 class B INSTALLATION SPECIFICATIONS AC Output and EV AC Output Conduit Size/AWG Range 1"maximum/14-4 AWG DC Input(PV and Battery)Conduit Size/AWG Range 1"maximum/14-6 AWG 17.7 x 14.6 x 6.8/ 450 x 370 x 174 n/mm Dimensions with Connection Unit(H x W x D) 17.7 x 14.6 x 6.8/450 x 370 x 174 17.7 x 14.6 x 6.8/ 17.7 x 14.6 x 6.8/450 x 370 x 174 450 x 370 x 174* 26/11.8 302/137' Weight with Connection Unit 26/11.8 30.2/13.3.7* . . lb/kg <25 Noise <25 <50* <25 <50 dBA Cooling Natural Convection Operating Temperature Range -40 to+140/-40 to+6000 'F/ Protection Rating NEMA 4 (6)The part numbers SEwosH-USxMxxxxx only support the SolarEdge Energy Bank.The part numbers SE10oorH-USxM000m support both SolarEdge Energy Bank and LG RESU Prime batteries Requires supporting inverter firmware (7)Discharge power Is limited up to the inverter rated AC power for on-grid and backup applications (8)For consumption metering current transformers should be ordered separately SECT-SPL-225A-T-20 or SEACT0750-400NA-20 units per box.Revenue grade metering is only for production metering (9)Information conceming the Data Plan's terms&conditions is available in the following link: hops://wwwsolaredge.com/sites/default/files/se-communication-plan-terms-and-con ditions-eng.pdf (10)Full power up to at least 50°C/122*F;for power de-rating information refer to:httpsj/www.solaredge.conVsites/default/files/se-temperature-deratirg-rate-na.pdf S`SolarEdge Technologies,Inc.All rights reserved.505AREDGE,the SolarEdge logo,OPTIMIZED BY SOLAREDGE are trademarks or registered trademarks of SolarEdge Technologies,Inc. RO H S All othertrademarks mentioned herein are trademarks of their respective owners.Date:06/2021 Ds-000031-1.5-NAM.Subject to change without notice. Be Prepared with P S U PPIM .= The ultimate value LG RESU is offering to custoamers is the maximum security for electricity consumption regardless of external uncertainties by realizing energy independence with eco-friendly solar energy. RESU16H PRIME RESU1OH PRIME "The world's largest capacity "The smartest choice of home battery for first home battery whole home backup" for daily use" World's Largest Capacity(16kWh,7kW)to back up Enough capacity(9 6kWh,5kW)to bac up essential loads in peak time and blackouts critical loads during peak time and emerge des World's ire Largest Capacity Optimal Capacity je RESU16H PRIME RESU1OH PRIME — — Maximum energy and high power output A - enable whole home backup both in peak Jo time and blackouts. Fully cover an average daily p RESU16H x 2ea RESU1OH x 2ea electricity use Capacity 32LWh 92kWh 2of RESU16H PRIME �\®• 2•7. Power 14 kW 10 kW / 'May vary depending on the size of household and energy consumption tt Contr Baol Uerynit Unique Modular Design Battery 4111talptio, With its unique modular design, I Modules RESU Prime can be divided into a battery control unit and two battery modules. It enables easier transportation, handling, and installation. *May vary depending on specific condition Connect Plate 0 Conventional RESU PRIME Carry& Handle �� Lift needed No lift On-the-Spot Maintenance `C ` 10 The detachable Control Unit Workload �C ` 2-3 Insrallers 1-2 Insrallers can be replaced on site, saving maintenance time and cost After sales 10 Service(*) collect& Early diagnosis& Replace On-the-Spot Maintenance RESU Monitoring Real time battery status monitoring and early diagnosis with RESU Monitor App/Web-based UI RESU Monitor remotely monitors battery :�,. For Installers&End Customers conditions in real time and proactively diagnoses in case of anomalies, enabling installers to take quick i and accurate remedial actions. Specification I. 1t A 1 $ RESU16H PRIME R=SU1OH PRIME Usable Energy(DoD 100%)[kWh] 16 Usable Energy(DoD 100%)[kWh] 9 6 Power(Rated/Peak)[kW] 7/11 Power(Rated/Peak)[kW] t 5/7 Voltage[V] ! 350-450 Voltage[V] 350-450 Round-trip Efficiency[%] >90 Round-trip Efficiency[%] >90 Storage Power Consumption[W] <0.1 Storage Power Consumption[W] J Dimension[W x H x D,inch] 19.8 x 42 8 x 116 Dimension[W x H x D,inch] 19.8 x 32.1 x 1 1.6 Total 352 Total 246 Module 286(143 x 2EA) Module 180(90 x 2EA) Weight[lb] -- Weight[lb] 1_ Control Unit a 55 Control Unit 55 Connect Plate ! 11 Connect Plate 11 Installation Type Floor-stand, r Installation Type Floor-standing&Wall-mounted Scalability Up to 2 unit;(32kWh/14kW) Scalability Up to 2 units(19 kWh/10 kW) Operational Temperature[°F] -50-122 Operational Temperature[°F] -50-122 Ingress Rating IP55 Ingress Rating j IP55 Warranty 70% a@10 years(Global) Warranty 70c - .-(Global) Communication CAN&RS485 Communication CA Cell ' UL 1642 Cell UL 1642 Certification CE/FCC/RCM/IEC62619/ Certification CE/FCC/RCM/IE6- 19! Product — Product Compatible Inverter SMA,Solareoge,SUNGROW,GOODWE,Solis `Values provided for 7 7°F i Elvao Fs-,# �; LG Home Battery R=SU Q' .e www.lghomebatterycom