Loading...
43-070 (11) BP-2022-1082 96DUNPHY DR COMMONWEALTH OF MASSACHUSETTS Map:Block:Lot: 43-070-001 CTCY OF NORTHAMPTON Permit: Exterior Res PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL c.142A) BUILDING PERMIT Permit# BP-2022-1082 PERMISSIONIS HEREBY GRANTED TO: Project# SIDING Contractor: License: NEXTGEN CONSTRUCTION Est. Cost: 22719 SERVICES INC 098654 Const.Class: Exp.Date:08/19/2023 Use Group: Owner: E BICKFORD DAVID L&JANE Lot Size (sq.ft.) Zoning: WSP Applicant: NEXTGEN CONSTRUCTION SERVICES INC Applicant Address Phone: Insurance: 1 ARCH RD (413)579-5798 VWC-1 00-6023 1 1 8 WESTI+IELD, MA 01085 ISSUED ON:09/01/2022 TO PERFORM THE FOLLOWING WORK: SIDING POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector Underground: Service: Meter: Footings: Rough: Rough: House# Foundation: Final: Final: Final: Rough Frame: Gas: Fire Department Driveway Final: Fireplace/Chimney: Rough: Oil: Insulation: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF ANY OF ITS RULES AND REGULATIONS. Signature: ( (� 97-)..ALa, • Fees Paid: $40.00 212 Main Street,Phone(413)587-1240,Fax:(413)587-1272 Office of the Building Commissioner i i I i `.' The Commonwealth of Massachusetts Ic "' I Board of Building Regulations and Standards FOR J Massachusetts State Building Code, 780 CMR MUNICIPALITY f a` USE Building Permit Application To Construct,Repair,Renovate Or Demolish a Revised Mar 2011 ID One-or Two-Family Dwelling This ection For Official Use Only Building Permit Number: �a /024)^ Date Applied: et.)16- ,`o l 20Z2 Building Official(Print Name) Signature Date SECTION 1:SITE INFORMATION 1.1 Property Address: 1.2 Assessors Map&Parcel Numbers 96 Dunphy Drive q3-n O- bo( 1.1 a Is this an accepted street?yes no Map Number Parcel Number 1.3 �Zioninng Information: 1.4 Property Dimensions: 3b8R. Zoning District Proposed Use Lot Area(sq ft) Frontage(ft) 1.5 Building Setbacks(ft) Front Yard Side Yards Rear Yard Required Provided Required Provided Required Provided 1.6 Water Supply:(M.G.L c.40,§54) 1.7 Flood Zone Information: 1.8 Sewage Disposal System: Public 0 Private CIZone• _ Outside Flood Zone? Municipal 0 On site disposal system 0 Check if yes❑ SECTION 2: PROPERTY OWNERSHIP' 2.1 Owner'of Record: David Bickford Florence,MAoio62 Name(Print) City,State,ZIP 96 Dunphy Drive 413-586-3662 . No.and Street Telephone Email Address SECTION 3: DESCRIPTION OF PROPOSED WORK2(check all that apply) New Construction 0 Existing Building m Owner-Occupied 0 Repairs(s) 0 Alteration(s) 0 Addition 0 Demolition 0 Accessory Bldg.0 Number of Units Other 0 Specify: Brief Description of Proposed Work2: Remove and replace Siding to code and manufacturers specifications. Please see estimate for details SECTION 4:ESTIMATED CONSTRUCTION COSTS Item Estimated Costs: Official Use Only (Labor and Materials) 1.Building $22,719.20 1. Building Permit Fee: $ Indicate how fee is determined: 2.Electrical $ ❑ Standard City/Town Application Fee ❑Total Project Cost (Item 6)x multiplier x 3.Plumbing $ 2. Other Fees: $ 4.Mechanical (HVAC) $ List: 5.Mechanical (Fire $ Suppression) Total All Fees:$ Check No2,0/1 Check Amount:PI-Of=Cash Amount: _ 6.Total Project Cost: $22,71 9.20 0 Paid in Full 0 Outstanding Balance Due: SECTION 5: CONSTRUCTION SERVICES 5.1 Construction Supervisor License(CSL) CS-o98654 08/19/2023 Rene Gauthier License Number Expiration Date Name of CSL Holder List CSL Type(see below) U 1 Arch Road Suite 11 No.and Street Type Description Westfield,MA 01o85 U Unrestricted(Buildings up to 35,000 cu.ft.) R Restricted 1&2 Family Dwelling City/Town,State,ZIP M Masonry RC Roofing Covering WS Window and Siding SF Solid Fuel Burning Appliances 413-579-5798 info@nextgen413.net I Insulation Telephone Email address D Demolition 5.2 Registered Home Improvement Contractor(HIC) NextGen Construction Service Inc. 196063 06/27/202 HIC Registration Number Expiration ate HIC Company Name or HIC Registrant Name 1 Arch Road Suite 11 info@nextgen413.net No.and Street Email address Westfield,MA o1085 413-579-5798 City/Town,State,ZIP Telephone SECTION 6:WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c. 152.§ 25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the Issuance of the building permit. Signed Affidavit Attached? Yes ® No ❑ SECTION 7a:OWNER AUTHORIZATION TO BE COMPLETED WHEN OWNER'S AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT I,as Owner of the subject property,hereby authorize Rene Gauthier to act on my behalf,in all matters relative to work authorized by this building permit application. Rene Gauthier g,,,e 08/26/2022 Print Owner's Name(Electronic Signature) Date SECTION 7b:OWNER'OR AUTHORIZED AGENT DECLARATION By entering my name below,I hereby attest under the pains and penalties of perjury that all of the information contained in this application is true and accurate to the best of my knowledge and understanding. Rene Gauthier g,c '���-- 08/26/2022 Print Owner's or Authorized ( Signature)Agen t's Ele onic Si ature) Date NOTES: 1. An Owner who obtains a building permit to do his/her own work,or an owner who hires an unregistered contractor (not registered in the Home Improvement Contractor(HIC)Program),will not have access to the arbitration program or guaranty fund under M.G.L.c. 142A.Other important information on the HIC Program can be found at www.mass.gov/oca Information on the Construction Supervisor License can be found at www.mass.gov/dps 2. When substantial work is planned,provide the information below: Total floor area(sq.ft.) (including garage,finished basement/attics,decks or porch) Gross living area(sq.ft.) Habitable room count Number of fireplaces Number of bedrooms Number of bathrooms Number of half/baths Type of heating system Number of decks/porches Type of cooling system Enclosed Open 3. "Total Project Square Footage"may be substituted for"Total Project Cost" City of Northampton ?oat N M s .=..,..s •' Massachusetts t * ca . A 4totDEPARTMENT OF BUILDING INSPECTIONS y; Am +r Y�`r'` 212 Main Street • Municipal Building J,t., ‘,10060 r, Northampton, MA 01060 ,r4W T")‘.1 CONSTRUCTION DEBRIS AFFIDAVIT (FOR ALL DEMOLITION AND RENOVATION PROJECTS) In accordance of the provisions of MGL c 40, S54, a condition of Building Permit Number is that all debris resulting from this work shall be disposed of in a properly licensed waste disposal facility, as defined by MGL c 111, S 150A. The debris will be disposed of in: Location of Facility: Casella Waste 686 Main Street Holyoke,MA oio4o The debris will be transported by: Name of Hauler: NextGen Construction Service Inc. Signature of Applicant: �� Date: 08/26/2022 .5.`�'.-- . The Commonwealth of Massachusetts - ; ;; Department of industrial Accidents tr_ 1 Congress Street.Suite 100 ' , t_ Boston.MA 02114-2017 www mass gov/diu uekers'('ompensation IasurauceAtlida%it:Buildersrl('ontractorsiEketririansfPlumler's. 10 BE FILED WITH THE PER5MI fl ING All ftt WRITS". :1DDlieatt Information Please Print L.elglbiv Name lfa+incssAkfaniznts,n ndi.'u4uai):NextGen Construction Service Inc. Address: 1 Arch Road Suite n - city/State/zip: Westfield,MA o1085 Phone#: 413-579-5798 Are eon an rinpairiteCiticei.the appropriate boa: Type of project(required): 1.0 i am a employer with 12 coi+lonct1s null aantirrpart-iinat).' 7. ®New construction 21:1 1 am a Mule proprid r of prrrncnhtp and have no employeaa w-urkitj for me in li. W Remodeling any capacity-(No weaker;comp.unaurancc amend.) 9. 3 t am a homeowner doing all work myxeii_(No wnrkrra'comp.iinurincr a'aptaad.l" ❑Demolition #.®I am a horrwwrwT and will be hiring outtiradors to Modulo all work on my property_ 1*ill 10 0 Building addition rw miaow that all cunttacto%c-ithtt hove-winter;co.-,---- --na immainte or are sole 1 I I a Electrical repairs or additions prelusion with iru cnptloyc'a's_ I 2.0 Numbing repairs or additions 50 I am a sjncral contractor and I have Nig die faba'tsrtraa:ion Emil asnadir a iathcd abrti. I 1.11 RoofRf is Meese nib-contractors have cmployimamdhawnanntn ima c 'ctatrp. l :ei: repairs 6.0 we are a eurtxnarhon and its officer,.lane exerriand their right of eacmptiun per Wit.c l 4. O her 1(�1 tl 152.*1(4).and we Nampo cuipkt)res.(N o water;'comp.inauramta aagairw).1 *Arty applicant that check,hint XI omit atm till out die aectiun hrlow showia11 then*oilier,:.oiupeu aatu.n policy intone aia'n. t Hotrtsowrwnsa who Muhena din alradmit inificating they are doing all work and then hue mitotic contractors inns Muluvit a new atti:ia4 it smda.atntr midi. lCoatraeiur that cheek Ilia hos otaiat marked art adiktattnal sheet alarming the nutnc i.t the+ul*-ctamatuns and awe whether ur nail hone cataatici leak c iyees. It the sub-contracton have tatployeei,they mu,i pmoidr their workers"cvnyt.policy iiiutalvt., I am an employer that is providing wurAers'compensation insurance Or my employees. Below is the policy and job site information. htsmancc Company Name: Webber and Grinnell Policy#or Self-ins Lic.#:WC9°98917 Expiration Date:°7/14/2023 Job Site Address: 984 Park Hill Rd Citystate=zip:Florence,MAoto62 Attach a copy of the workers'compensation policy declaration page(showing the policy uusuber and expirados date). Failure to secure coverage as required under MGL c. 152,*25A is a criminal violation punishable by a fine up to$1,500.00 and/or one-year imprisonment.as well as civil penalties in the form of a STOP WORK ORDER and a fine of up to$250.00 a day against the violator.A copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certiii•under the pains and penalties of perjur1'that the information provided shove is true and correct_ Si8iiature: c Roc: 08/26/2022 ulcer/,IT: 413-579-5798 I01fcierl use unlr Do not write in this area.to be completed by city or town official I. (its or'Town: Permit/License# Issuing Authority (circle one): 1.Board of Health 2.Building Department 3.('itsfl"own("perk 4.Electrical Inspector 5.Plumbing Inspector 6.Other ("outset Person: Phone#: _ q DATE(MM/DD/YYYY) A` 'ORO CERTIFICATE OF LIABILITY INSURANCE 07/15/2022 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Stephanie Herring NAME: Webber&Grinnell PHONE Ext): (413)586-0111 FAX(A/C,No): (413)586-6481 (A/8 North King Street ADDRESS: sherring@webberandgrinnelLcom I INSURER(S)AFFORDING COVERAGE NAIC# Northampton MA 01060 INSURER A: Selective INSURED I INSURER B: Selective Ins Co of S Carolina 19259 NextGen Construction Service,Inc INSURER C: 82 Pequot Rd INSURER D: INSURER E: Southampton MA 01073 INSURER F: COVERAGES CERTIFICATE NUMBER: Exp 07/2023 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDLSUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER (MMIDD/YYYY) (MMIDDIYYYY) LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 DAMAGE RENTED CLAIMS-MADE X OCCUR PREMISESO(Ea occurrence) $ 500,000 MED EXP(Any one person) $ 1 5,000 A S2516200 07/14/2022 07/14/2023 PERSONAL 8 ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER. GENERAL AGGREGATE $ 2,000,000 X POLICY JECT PRO LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER Employee Benefits $ 1,000,000 AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) ANY AUTO BODILY INJURY(Per person) $ B OWNED X SCHEDULED A9109391 07/14/2022 07/14/2023 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X HIRED X NON-OWNED PROPERTY YDAMAGE $ AUTOS ONLY AUTOS ONLY (Peraccident) PIP-Basic $ 8,000 X UMBRELLA LIAB _ OCCUR EACH OCCURRENCE $ 1,000,000 A EXCESS LIAB CLAIMS-MADE S2516200 07/14/2022 07/14/2023 AGGREGATE $ 1,000,000 DED X RETENTION $ 0 $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER YIN 1,000,000 A ANY PROPRIETOR/PARTNER/EXECUTIVE Y N/A WC909891 7 07/14/2022 07/14/2023 E_L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED 1 000,000 (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ , If yes.describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Rene Gauthier is Excluded from Workers'Compensation coverage. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN "Proof of Coverage" ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE I " ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD Canwnonweatth or Massachusetts 111 Division of Protessiona1 Ltcensurs Board of Building Regulations and Sindards Cotvt:sor icr, 't CS-098654 c • fires:08119/2023 RENE E GAMz' , • 62 PEQUOT RD SOUTHAMPT41 MA ..i " :i Commissioner di i. Mar Mambo,— Construction Supervisor Unrestricted -Buildings of any use group which contain less than 36,000 cubic feet(991 cubic meters)of enclosed space. Failure to possess a current edition of the Massachusetts State Building Code is cause for revocation of this license. For intomtation about this license Call(617)727-3200 or visit www.mass.govidpl THE COMMONWEALTH OF MASSACHUSETTS Office of Consumer Affairs and Business Regulation 1000 Washington Street - Suite 710 Boston, Massachusetts 02118 Home Improvement Contractor Registration Mf f e,r., .- - Type. Corporation NEXTGEN CONSTRUCTION SERVICE INC - Registration 66063 - -W�= 0 Expiration 6/27/2023 1 ARCH ROAD SUITE 11 `.+t - = .. __.., WESTFIELD, MA 01085 � ,,. . Update Address and Return Card. THE COMMONWEALTH OF MASSACHUSETTS Office of Consumer Affairs&Business Regulation Registration valid for individual use only before the HOME IMPROVEMENT CONTRACTOR expiration date. If found return to: TYPE:Corporation Office of Consumer Affairs and Business Regulation Registration Pucflretion 1000 Washington Street -Suite 710 196063 06/27/2023 Boston,MA 02118 NEXTGEN CONSTRUCTION SERVICE INC. RENE E.GAUTHIER 82 PEQUOT ROAD.( ' SOUTHAMPTON,MA 01073 Undersecretary Not valid without signature it NEXTGEN ;, RATING: ROOFING �" �' ' `''� .., 110 . 1 . . . idik..' 1,46.— _ .______ .,:.-r- . . 1.. ...., ,,,„ .,. . _,_�--�- , , ,. .. ..._ . „. _ . . ., __ , . . r. ;.. , .....s. , ,,.. .. , ,......., . k , _ . , ... , .., _ s .:v r , ... ...„ ...... 44'- 4.14,'..-S 44. ir r •' r ,.. phi• ,�v� 4 { a ''i. ,,.r.• ,I .✓ ':+`wYrfi w ,w •r ^ � �'o"4y K.4 K` x r` • know` ''' "*.;. '6 - 74orn , .'4 • SIDING REPLACEMENT PROPOSAL DAVID BICKFORD AUG 26,2022 I Project#1200 96 Dunphy Drive Florence, MA We can help you with 01062 Roofing, Siding, Windows, Gutters, & Decks 1 Arch Rd Suite 11 Westfield, MA 01085 info@nextgen413.net (413) 579-5798 MASTIC QUEST D4 Description Siding Materials MASTIC Quest is an ideal choice for remodelers because of its optimal thickness and wide selection of designer-inspired colors. Proprietary technology adds extra UV protection to our deepest, most vivid colors, protects colors against hard elements,and maximizes long-term weather-ability. SIDING BACKER: covers the cost to supply and install a 3/8"fan-fold siding backer to create a vapor and secondary water barrier while improving the R-value of your home. LIGHT BLOCK: create a smooth,stable surface for installing accessories on your home. From lights and doorbells to electrical outlets,water faucets,and more. MASTIC 4" OUTSIDE CORNER: protects corners and has a receiving channel that hides the ends of siding panels for a finished, professional vinyl siding installation. Soffit and Fascia VINYL SOFFIT: covers the cost to supply and install vinyl soffit.Vented soffit on the eaves and solid on the rakes of the home. FASCIA TRIM: covers the material and labor to fabricate and install custom aluminum fascia coverings. Aluminum Wraps ALUMINUM WINDOW WRAPS: covers the cost of material and labor to fabricate and install custom aluminum window wraps. Existing Items D&R STORMDOOR: covers the cost of time and labor to detach and reset an existing stormdoor. D&R LIGHT FIXTURE: covers the cost of time and labor to detach and reset an existing light fixture. D&R ELECTRICAL METER: cover the time and labor to detach and reset an electrical service box.This must be performed by an electrician. PORTABLE TOILET: Is provided in cases where there is not a sufficient place for the installer to use the washroom. Quote subtotal $22,719.50 Total $22,719.50 Sunlight Financial est. $263.68Imo Fixed APR of 6.99%for 120 months AUTHORIZATION PAGE Mastic Quest D4 $22,719.50 Project: 1200 Name: David Bickford Address: 96 Dunphy Drive, Florence, MA Estimates valid for 30 days from date of estimate/A 50%deposit is required before any project begins. Upgrades We Suggest for your Fixed APR of 6.99%for Sunlight Financial' 120 months New Siding Description Qty Unit price Line total Est. Payment 0 $0.00/mth Final Price $22,719.50 Customer Comments / Notes My Product Selections Siding Color Autumn Harvest Siding Profile 4D Trim Color White PVC Grain David Bickford: �,}.•�� 9191:44 Date:8/26/2022 Exclusions: By signing this form I agree to and confirm the following:I certify that I am the registered owner of the above project property,or have the legal permission to authorize the work as stated.I agree to pay the total project price and understand that this work will be completed in accordance with industry best practices. TERMS AND CONDITIONS NEXTGEN CONSTRUCTION SERVICE INC/NEXTGEN ROOFING -CUSTOMER AGREEMENT infol©nextgen413.net 1413.579.5798 MA License No.CS-098654 HIC 196063 CT HIC 0663014 1 Arch Rd Suite 11 Westfield,MA 01085 CUSTOMER (also referred to as"YOU"or"CUSTOMER") and NEXTGEN,a fully licensed and insured General Contractor (referred to as"CONTRACTOR","US"or"WE")AGREE AS FOLLOWS: 1.CONTRACTOR SCOPE OF WORK: Please see Estimate for the detailed scope of work 2.CUSTOMER WORK:All work will be performed by Contractor or Contractor's subcontractors.Customer and Contractor agree that Customer must obtain written permission from Contractor prior to performing any work on the Property,Customer agrees to remove any items off walls which may interfere with the Work or be damaged during the course of the Work.Customer acknowledges and agrees that Contractor shall not be liable for any and all damages to such items.Customer acknowledges that during the roofing process some debris may be forced through nail holes or openings in the wood,Contractor is not responsible for clean-up or damages due to this and recommends covering items directly under roofing surface to facilitate easy clean-up. 3.PAYMENT TERMS: Non-Insurance Claim: The total amount due for the"Work"shall be payable in the amount equal to 1/3 of the total,at the time this agreement is entered into,and payment of the remainder is due upon'successful completion of the work. 4.Insurance Claim:The amount due for the Work shalt be equal to the total insurance claim amount as authorized by your insurance company (the"price").This Agreement does not obligate NextGen in any way to complete the work unless your claim is approved by your insurance company and then accepted by the Contractor. By signing this Agreement,you authorize NextGen to pursue your insured interest for the work at a price agreeable to the insurance company and NextGen with no additional cost to your regards to the work except for the insurance deductible in the FULL amount,which shall be due to NextGen by the customer as a deposit upon execution of this agreeiment. By signing this agreement,you authorize and agree that NextGen may correspond with your insurance provider regarding the scope of work and shall complete the work upon approval by your insurance company and acceptance by NextGen. Under no circumstance shall this agreement be construed to require NextGen to negotiate customer's insurance coverage or otherwise fulfill the duties of a public adjuster.Customer authorizes its insurance company to issue all insurance proceeds checks jointly in the name of Nextgen Construction Service Inc. EXECUTION OF AGREEMENT: (The signatures below acknowledge that the parties have read and agreed to each provision provided) "*There are some important things to know about our Terms&Conditions.These conditions are born from suggestions from risk-averse paranoid Legal Departments.We are bound by our core values.Our core values supersede a long jargon-filled block of text as we know any time the terms and conditions are used it is a risk of an unhappy customer and damage to our brand and the loss of future referrals. Feel free to call your sales rep directly for clarification on any of these industry-standard terms and conditions. We have a very logical and reasonable explanation for every line in this agreement and we are happy to share it.** 5.DOWN PAYMENTS/DEPOSITS:Customer understands that any money paid to Contractor as a deposit is to be applied to Contractor's cost to complete the Work("Contractor Deposit"). In the event Customer terminates this Agreement pursuant to Notice of Cancellation,such funds shall be returned to Customer pursuant to the Notice of Cancellation. If Contractor has purchased any permits or special order materials for the job there may be a cancelation fee to cover costs. I acknowledge that I have read and understand this page.Initials: DB 6.CHANGES TO THE WORK(CHANGE ORDERS):Contractor's obligations under this Agreement cannot be changed unless they are changed in writing on a separate Change Order form signed by Customer and Contractor and the insurance company as necessary and applicable ("Change Order"). If there is a discrepancy between documents,the written Change Orders shall take precedence over this Agreement. Payment for the Change Order work is due upon execution of the Change Order.Contractor may,at Contractor's sole discretion, require the customer to provide an additional deposit towards increased costs associated with Change Orders.Customer acknowledges that it shall be personally responsible for any changes which are not included in any applicable insurance settlement.Contractor shall have the right to stop all Work at such time as a change is requested or required until such time as the Change Order is executed by Customer.Contractor has an absolute right to reject any requested Change Order for any reason. 7.REMEDIES: In the event of Customer's default of this Agreement, interest will accrue on unpaid amounts at the rate of 1.5%per month,or if lower,the highest amount allowed by law. In the event that Contractor incurs costs or attorney's fees to enforce this Agreement's terms,such amounts will be in addition to any amounts owed by Customer to Contractor. If Contractor does not receive any payments due under this Agreement's terms,Contractor may stop Work without further notice and seek all available remedies.Contractor shall be entitled to all payments due up until the point at which Work is stopped,and for all losses sustained by the Contractor, including but not limited to,materials, machinery,equipment or tools,overhead, lost profits,soft costs,and damages.Contractor will retain title to all machinery and materials if this Agreement is canceled,this includes a situation in which Customer attempts to improperly terminate this Agreement after any insurance proceeds have been determined but construction has not commenced.Contractor is hereby granted a license to enter the Property to remove such items upon termination of this Agreement. If Work has stopped for any reason,including delays by Customer's insurance company,for more than 30 days,Contractor may terminate this Agreement and recover pursuant to this Agreement. If Customer defaults in any manner under this Agreement,Contractor will have the right to (1)terminate this Agreement, (2) retain all deposits, fees,and progress payments Customer has made,and (3)take legal action to recover from Customer payment for all Work completed,and for all losses sustained by Contractor on all materials,machinery,equipment or tools,overhead, soft costs,profit and damages,and (4) place liens upon the Property for payment of any amounts owed,and (5) foreclose any liens placed on the Property if the amounts due including costs and interest are not paid in full. Contractor's exercise of any remedy shall not preclude the exercise of the remedies available to Contractor.The remedies contained in this Agreement may be used concurrently and are in addition to any other remedy which may be available to Contractor at law or equity.This one is a Doozy,and we have never had to use it.Typically this is for commercial jobs.When it comes to"Bob and Betty"homeowners this is pretty simple.We do the job,be prepared to pay us.If we have to chase you,we charge you to chase you.Simple.We want you happy and don't want you to pay us until you are happy. ARBITRATION OF DISPUTES THIS CONTRACT SHALL BE INTERPRETED UNDER THE LAWS OF THE COMMONWEALTH OF MASSACHUSETTS. IN THE EVENT OF ANY DISPUTE ARISING HEREUNDER AS TO WHETHER CONTRACTOR'S WORK COMPLIES WITH THE PLANS AND SPECIFICATIONS OR WHETHER PAYMENT IS PROPERLY DUE AND THE SAME IS NOT SETTLED WITHIN FOURTEEN DAYS,THEN SAID DISPUTE SHALL BE RESOLVED BY ARBITRATION WITH A PRIVATE ARBITRATION SERVICE THAT HAS BEEN APPROVED BY THE SECRETARY OF THE EXECUTIVE OFFICE OF CONSUMER AFFAIRS AND BUSINESS REGULATIONS AS PROVIDED IN MASSACHUSETTS GENERAL LAWS CHAPTER 142A PRIOR TO EITHER PARTY PROCEEDING TO LEGAL ACTION IN THE COURTS.THE PARTIES SIGN BELOW ACCEPTING SUCH ARBITRATION WITH THE CONSTRUCTION INDUSTRY ARBITRATION RULES OF THE AMERICAN ARBITRATION ASSOCIATION THEN OBTAINING.THERE SHALL BE A SINGLE ARBITRATOR.THE JUDGMENT ON ANY AWARD RENDERED BY THE ARBITRATOR MAY BE ENTERED IN ANY COURT HAVING JURISDICTION.THE PARTIES HEREBY AGREE TO USE REASONABLE EFFORTS TO RESOLVE ANY DISPUTES SO AS TO AVOID THE COST AND DELAY ASSOCIATED WITH THE ARBITRATION. 8.TIME DELAYS:Customer agrees that Contractor is not responsible for delays in completion of the Work due to weather,strikes,war,terrorist attacks,shortage or delay in getting materials,shortage or delay in labor or subcontracting,government regulations,court actions or any other cause beyond Contractor's control. If the cost of materials or labor increases during any such delays,Contractor may require that Customer or Customer's insurance company pay such increased costs or terminate this Agreement after paying Contractor for all work completed to the date of termination and for all materials which cannot be returned.Customer will not be entitled to any remedy for Contractor's failure to start or complete the Work at any particular time.Customer understands that delays caused by Customer,Customer's Lender,or Customer's insurance company may cause additional delays on the part of Contractor due to unavailability of labor or subcontractors. 9.CONCEALED CONDITIONS:There are occasionally unseen site conditions,we make every effort to discover this I acknowledge that I have read and understand this page.Initials: DB during the estimate.We make a stronger effort here than most, BUT some things just cannot be seen before opening the roof.This Agreement and the price are based solely on the observations of Contractor at the time of entering into this Agreement. If additional concealed conditions are discovered once the Work has commenced,which conditions were not visible at the time of entering into this Agreement,Contractor will identify the unforeseen conditions,and Customer and Contractor will execute a change order for any additional work (which must be approved by the insurance company).Customer agrees that if the insurance company does not agree to pay for unexpected or unanticipated extra costs,then Contractor may terminate this Agreement and Contractor shall be entitled to payment for all Work completed through the date of termination.Customer will be responsible for all additional costs and time for work due to concealed conditions.Such conditions may also extend the time for completion of Contractor's Work under this Agreement. 10.CUSTOMER SITE VISITS: Because of hazards that may be on the construction site during construction and the potential to interfere with the Work,Customer is encouraged to enter into the construction area only after first consulting with Contractor. During the time of construction on the Property,conditions will exist that will be hazardous to Customer and Customer's family,friends,and guests.Customer waives all claims against Contractor and agrees to indemnify,defend and hold Contractor harmless for injuries or damages that customer or any member of Customer's family,friends,or guests may suffer while on or around the property during construction. 11. USE OF DUMPSTER:Customer acknowledges and agrees that Contractor may place a dumpster on the Property for collection of construction waste materials (the"Dumpster").Customer agrees that Customer and Customer's family, friends,or guests will not place any materials in the Dumpster whatsoever or otherwise interfere with,enter into,or move the Dumpster.Customer waives all claims against contractor (and agrees to indemnify,defend and hold Contractor harmless)for property damage or injuries or other damages that Customer or any member of the Customer's family,friends,or guests,may suffer as a result of the Dumpster.Should Customer or any member of Customer's family,friends,or guests place any materials in the Dumpster,Customer agrees that it shall be responsible for any increased costs associated with such actions. 12.SUBCONTRACTORS:Contractor may use subcontractors and suppliers to complete the Work.Subcontractors will be chosen by the Contractor only.Customer agrees not to hire any of Contractor's subcontractors or suppliers to do any work or supply any materials,except upon written agreement signed by the Contractor.Customer agrees not to interfere with,discuss with, interrupt or provide instruction to any contractor or subcontractor working on the Property. 13.PRE-LIEN NOTICE TO OWNER:GENERAL CONTRACTOR PRE-LIEN NOTICE TO OWNER(A)ANY PERSON OR COMPANY SUPPLYING LABOR OR MATERIALS FOR THIS IMPROVEMENT TO YOUR PROPERTY MAY FILE A LIEN AGAINST YOUR PROPERTY IF THAT PERSON OR COMPANY IS NOT PAID FOR THE CONTRIBUTIONS. (B) UNDER MASSACHUSETTS LAW,YOU HAVE THE RIGHT TO PAY PERSONS WHO SUPPLIED LABOR OR MATERIALS FOR THIS IMPROVEMENT DIRECTLY AND DEDUCT THIS AMOUNT FROM OUR CONTRACT PRICE,OR WITHHOLD THE AMOUNTS DUE THEM FROM US UNTIL 120 DAYS AFTER COMPLETION OF THE IMPROVEMENT UNLESS WE GIVE YOU A LIEN WAIVER SIGNED BY PERSONS WHO SUPPLIED ANY LABOR OR MATERIAL FOR THE IMPROVEMENT AND WHO CAVE YOU TIMELY NOTICE. UNDER CHAPTER 254 OF MASSACHUSETTS GENERAL LAWS,THE CONTRACTOR AND ANY SUBCONTRACTORS THAT THE CONTRACTOR HAS A WRITTEN CONTRACT WITH, MAY OBTAIN A LIEN COMMONLY KNOWN AS A"MECHANICS LIEN"AGAINST THE PROPERTY WHERE THE WORK IS BEING PERFORMED 14.LEGAL NOTICES:Customer acknowledges reviewing the following attached or incorporated legal notices:General Contractor Pre-Lien Notice to Owner, Building Performance Guideline, Urea Formaldehyde Notice,327A Warranty Addendum, Notice of Right of Rescission (if applicable),a Lead Paint Pamphlet and Addendum (if applicable),Water Intrusion and Mold Growth Notice,Authorization to Correspond and the Notice Regarding Cancellation Rights and the Notice of Cancellation which shall be incorporated herein by reference. 15.CUSTOMER'S THREE-DAY RIGHT TO TERMINATE:CUSTOMER IS ADVISED THAT FEDERAL AND STATE LAW ALLOWS CUSTOMER TO TERMINATE THIS AGREEMENT FOR ANY REASON WITHIN THREE (3) DAYS AFTER SIGNING IT. CUSTOMER ACKNOWLEDGES THAT THEY HAVE RECEIVED SUCH NOTICE PURSUANT TO THIS SECTION AND PURSUANT TO THE RIGHT OF RESCISSION ATTACHED HERETO. LIQUIDATED DAMAGES:Customer ack owledges that this agreement constitutes an enforceable contract and that in reliance upon the representations and t rms herein, Contractor shall incur substantial time and resources toward the completion of the work authorized herein,which may or may not involve physical work at Customer's property.Customer acknowledges that such expense can not be reasonably ascertained at any specific time,and as such,Customer agrees that if customer terminates this agreement prior to Contractor's commencement of any improvement to your property,in addition to any other damages Contractor shall be entitled to,Customer shall pay contractor,as liquidated damages and NOT as a penalty,the sum of I acknowledge that I have read and understand this page.Initials: DB $1,500.00 immediately upon demand. 16.DISPUTE RESOLUTION: Except as otherwise provided herein,any claim by Customer or Contractor in any way arising out of this Agreement,any and all other agreements between Customer and Contractor and/or in any way arising out of or relating to the physical condition of the property shall be settled by binding arbitration in Hampden County Massachusetts, under the Construction Industry Rules of the American Arbitration Association.Contractor retains the right to file,perfect and start a lawsuit to Enforce Mechanic's Lien Rights.The parties agree that the court may refer the matter to arbitration,but retain jurisdiction for enforcement of the Mechanic's Lien. 17.PAYMENT UPON COMPLETION AND RETAINAGE RIGHTS:Customer shall pay any outstanding amounts withheld from the Price in accordance with this Contraction notice by the Contractor that the work is complete.Should the Customer believe that the work is not complete,Customer shall communicate and document the belief via text or email within 24 hours of receiving notice from Contractor that the work is complete.Customer shall retain no more than 5%of the Price and must provide Contractor with availability for inspection and walkthrough within three days of Customer's notice of non-completion. 18. PUNCH LIST ITEMS:Contractor shall communicate to customer if work is complete but for certain minor items that Contractor is addressing with due diligence ("punch list items").Contractor shall provide a list and expected completion date for any punch list items if such work shall require more than 7 days to complete. Upon contractor's communication to Customer that work is complete except for identified punch list items,Customer shall pay Contractor all but 5%of the price,the remainder due within 24hrs of notification of completion of punch list items. If customer believes that punch list items are not all completed,such communication must be made to Contractor within 24hrs and the Contractor must be provided access to inspect the claimed non-complete punch list items within 3 days of Customer's notice to Contractor of said belief. 19.MISCELLANEOUS:The invalidity,illegality,or unenforceability of any provision, restriction,condition, reservation,or any other part of this Agreement, in its entirety or as applied to particular circumstances shall not impair or affect in any manner the validity, legality,enforceability or effect of the remainder of this Agreement.This Agreement shall not be assigned by Customer,except with Contractor's prior written consent.This Agreement may be amended only by a written instrument signed by both parties.The captions contained in this Agreement are for convenience only.Any number of counterparts of this Agreement may be executed and each such executed counterpart shall be deemed an original,but all such counterparts together shall constitute one Agreement.The electronic signature of any party to this Agreement shall be sufficient for all purposes.CUSTOMER AGREES THAT THIS AGREEMENT IS SUBJECT TO APPROVAL OF A CORPORATE OFFICER OF CONSTRUCTION COMPANY,AND UPON REVIEW OF THE DETAILS OF TITLE AGREEMENT, INCLUDING THE PRICE, MEASUREMENTS OR ANY OTHER FACTORS,CONSTRUCTION COMPANY MAY DECLINE TO APPROVE THIS AGREEMENT,AND DECLARE THE AGREEMENT NULL AND VOID AT ITS OPTION,AT WHICH TIME ANY DEPOSIT MADE BY CUSTOMER WILL BE PAID IN FULL TO CUSTOMER. 20. Interior prep: During construction,the home will vibrate and even shake at times.We recommend removing any valuable items from the walls or shelves. Nextgen will not be responsible for any broken items.We also recommend moving and protecting items in the attic. It is common for debris to fall through the roof decking and make a mess in the attic. Nextgen is not responsible for cleaning the interior of the home or attic or protecting any of the contents. 21.Skylights:The Company is not responsible for any damages related to leaks from skylights unless the Company completed the skylight replacement as part of the Work.See,skylights are a common issue,and there are 9 ways to install them incorrectly yet can be indistinguishable from the average person's inspection.So if we don't get to replace it we can not guarantee the work we have to do around it as disturbing it could cause problems. It's always best to replace your skylights when replacing your roof. Look at how many improvements and updates your phone has had in 5-years, now think about your 18-year-old skylight. 22.Solar panels: If there are solar panels on the roof,Customer agrees to take all necessary steps to remove,protect, and reinstall the same. Under no circumstances will the Company be responsible for damage to such solar panels during the course of the Work unless the removal of the Panels is provided by NextGen Roofing in this agreement. If you hire someone to remove and replace the panels,then the panels including how and where they are stored are not our responsibility.So make sure they put them somewhere for safekeeping and store them properly to prevent damage. 23.Media:Customer agrees that Contractor has the right to use any reproductions of the Work for publication or distribution,including the publishing or use of photographs or descriptions of the Work,for promotional or advertising uses.You might have found us on Facebook, Instagram,or Youtube,that is because we are proud of the work we do and choose to share it with the world. If you are a billionaire who has hired us to roof your mansion on the beach,we I acknowledge that I have read and understand this page.Initials: DB can talk about confidentiality.Otherwise,we might record a video showing us doing awesome work on your roof and share it with the world! 24.Price: Having experienced the COVID-19 Pandemic it seems necessary to mention that our price Guarantee is void barring any drastic swing in prices from our suppliers.This could be caused by any reason out of our control to have been reasonably foreseen.We do not know if America will suffer excessive waves of viral infections, hyperinflation, government shutdowns,or other events that can have a serious impact on pricing volatility.We can can,'cel the job at any time due to delays,shortages,or volatile pricing.We will refund any money paid prior to starting the job in accordance with our policy above.There are no guarantees in this world.That is one lesson we have learhed,and things like Pandemics are tough. I acknowledge that I have read and understand this page.Initials: DB FINAL AUTHORIZATION SUMMARY Status: Signed Agreement Completed: Fri, 26 Aug 202217:49:16 GMT • Document emailed for signature: Fri, 26 Aug 2022 17:46:17 GMT Document e-signed by: David Bickford (davidbickford945@gmaii.com) Signature date: Fri, 26 Aug 2022 17:49:16 GMT I P address: 64.124.151 .208