Loading...
43-169 243 PARK HILL RD BP-2020-0269 GIS#: COMMONWEALTH OF MASSACHUSETTS MaR-Block:43 - 169 CITY OF NORTHAMPTON Lot:-001 PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS Permit: Building DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL e.142A) Category: SOLAR ELECTRIC SYSTEM BUILDING PERMIT Permit# BP-2020-0269 Project# JS-2020-000456 Est.Cost:$62000.00 Fee:$75.00 PERMISSION IS HEREBY GRANTED TO: Const.Class: Contractor. License: Use Group: SUNBUG SOLAR 109144 Lot Size(sg.ft.): 58893.12 Owner: COURTHRIGHT PETER tonin . Applicant: SUNBUG SOLAR AT. 243 PARK HILL RD Applicant Address: Phone: Insurance: 41 lA HIGHLAND AVE (413) 884-1000 O WC SOMERVILLEMA02144 ISSUED ON.813012019 0:00:00 TO PERFORM THE FOLLOWING WORK.-INSTALL 13.51 KW SOLAR ON ROOF - 37 PANELS POST THIS CARD SO IT IS VISIBLE FROM THE STREET Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector Underground: Service: Meter: Footings: Rough: Rough: House# Foundation: Driveway Final: Final: Final: Rough Frame: Gas: Fire Department Fireplace/Chimney: Rough: Oil: Insulation: Final: Smoke: Final: THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF ANY OF ITS RULES AND REGULATIONS. Certificate of Occupancy Signature: FeeType• Date Paid: Amount: Building 8/30/2019 0:00:00 $75.00 212 Main Street, Phone(413)587-1240,Fax:(413)587-1272 Louis Hasbrouck—Building Commissioner sign Envelope ID:3D118B2B-EC67-4419-8572-AD 6C27 Department use only City of No ham, ton S atus Permit: y - Building D partf ner,1f G 2 9 rb C t/Driveway Permit 212 Mai Str et wer/ eptic Availability Roo 1001- _ ater ell Availability Northampto MH��N�iLDiw;r two S is of Structural Plans AMPT , phone 413-587-1240 Fax 4'C3 5872 .1ot/Si a Plans Other Specify APPLICATION TO CONSTRUCT,ALTER, REPAIR, RENOVATE OR DEMOLISH A ONE OR TWO FAMILY DWELLING SECTION 1 -SITE INFORMATION 6 V 1.1 Property Address: This section to be completed by office 243 Park Hill Road Map Lot l o q Unit Northampton, MA 01062 Zone Overlay District Elm St.District CB District SECTION 2-PROPERTY OWNERSHIP/AUTHORIZED AGENT 2.1 Owner of Record: Peter Courthright 243 Park Hill Road - Northampton, MA 01062 Nages,,&by: Current Mailing Address: 617-851-4710 Pt f ('t�4A.t Telephone S 2.2 Authorized Agent: SunBug Solar 66 Westfield Ind Park Rd - Westfield, MA 01085 Namei(Print) Current Mailing Address: 413-884-1000 Signature Telephone SECTION 3-ESTIMATED CONSTRUCTION COSTS Item Estimated Cost(Dollars)to be Official Use Only completed by permit applicant 1. Building $19,000 (a)Building Permit Fee 2. Electrical (b) Estimated Total Cost of $43,000 Construction from 6 3. Plumbing Building Permit Fee 4. MechanicalHVAC ( ) 5. Fire Protection 6. Total =(1 +2+3+4+5) $ 62,000 Check Number This Section For Official Use Only Date Building Permit Numbe Issued: Signature: ✓� "2y�� Building Commissioner/inspector of Buildings Date EMAIL ADDRESS (REQUIRED; EITHER HOMEOWNER OR CONTRACTOR) .sign Envelope ID:3D1 18B2B-EC67-4419-B572-AD53DC2791 B7 Section 4. ZONING All Information Must Be Completed.Permit Can Be Denied Due To Incomplete Information Existing Proposed Required by Zoning This column to be filled in by Building Department Lot Size Frontage Setbacks Front Side L: R: L: R: Rear Building Height Bldg. Square Footage % Open Space Footage % (Lot area minus bldg&paved parking) #of Parking Spaces Fill: volume&Location A. Has a Special Permit/Variance/Finding ever been issued for/on the site? NO O DONT KNOW O YES O IF YES, date issued: IF YES: Was the permit recorded at the Registry of Deeds? NO O DONT KNOW O YES O IF YES: enter Book Page and/or Document# B. Does the site contain a brook, body of water or wetlands? NO O DONT KNOW © YES O IF YES, has a permit been or need to be obtained from the Conservation Commission? Needs to be obtained O Obtained O , Date Issued: C. Do any signs exist on the property? YES O NO O IF YES, describe size, type and location: D. Are there any proposed changes to or additions of signs intended for the property? YES O NO O IF YES, describe size, type and location: E. Will the construction activity disturb(clearing,grading,excavation,or filling)over 1 acre or is it part of a common plan that will disturb over 1 acre? YES O NO O IF YES,then a Northampton Storm Water Management Permit from the DPW is required. rignvelope ID:3D118B2B-EC67-4419-6572-AD53DC2791 B7 SECTION 5-DESCRIPTION OF PROPOSED WORK(check all applicable) New House ❑ Addition ❑ Replacement Windows Alteration(s) Roofing ❑ Or Doors F-I Accessory Bldg. ❑ Demolition ❑ New Signs [[3] Decks Siding[o] Other[[o Solar Brief Decriptio f r Work: Insta" .MW solar on roof, as per attached documents (37 panels) Alteration of existing bedroom Yes X No Adding new bedroom Yes X No Attached Narrative Renovating unfinished basement Yes X No Plans Attached Roll -Sheet 6a. If New house and or addition to existing housing, complete the following: a. Use of building : One Family Two Family Other b. Number of rooms in each family unit: Number of Bathrooms c. Is there a garage attached? d. Proposed Square footage of new construction. Dimensions e. Number of stories? f. Method of heating? Fireplaces or Woodstoves Number of each g. Energy Conservation Compliance. Masscheck Energy Compliance form attached? h. Type of construction i. Is construction within 100 ft. of wetlands? Yes No. Is construction within 100 yr. floodplain Yes No j. Depth of basement or cellar floor below finished grade k. Will building conform to the Building and Zoning regulations? Yes No. I. Septic Tank City Sewer Private well City water Supply SECTION 7a-OWNER AUTHORIZATION-TO BE COMPLETED WHEN OWNERS AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT Peter Courtright I, , as Owner of the subject property hereby authorize SunBug Solar LLC to act oia mXb eppl.f, in all matters relative to work authorized by this building permit application. N0C (h. .1__1 k 7/11/2019 Sig4AW_r9C4QMffE421 Date SunBug Solar LLC as Owner/Authorized Agent hereby declare that the statements and information on the foregoing application are true and accurate, to the best of my knowledge and belief. Signed under the pains and penalties of perjury. A on Simms Print Na e Signature of Owner/Agent Date ign Envelope ID:3D1 18B2B-EC674419-8572-AD53DC2791B7 SECTION 8 -CONSTRUCTION SERVICES 8.1 Licensed Construction Supervisor: Not Applicable ❑ Name of License Holder: Aaron Simms CS-109144 License Number 66 Westfield Ind Park Road - Westfield, MA 01085 07/21/19 AddressJ:::� Expiration Date 413-884-1000 Sig ure Telephone 9. Registered Home Improvement Contractor: Not Applicable ❑ SunBug Solar LLC 163091 Company Name Registration Number 411A Highland Avenue - Suite 312 05/10/21 Address Expiration Date Somerville MA 02144 Telephone 617-500-3938 SECTION 10-WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c. 152,§25C(6)) Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affidavit will result in the denial of the issuance of the building permit. Signed Affidavit Attached Yes....... X No...... ❑ ,Agn Envelope ID:3D118B2B-EC67-4419-B572-AD53DC2791B7 City of Northampton Massachusetts " DEPAR2I4:NT OF BUILDING INSPECTIONS �`• \ 212 Main Street • Municipal Building yJp•.,. O Northampton, MA 01060 AFFIDAVIT Home Improvement Contractor Law Supplement to Permit Application The Office of Consumer Affairs and Business Regulation("OCABR")regulates the registration of contractors and subcontractors performing improvements or renovations on detached one to four family homes.Prior to performing work on such homes,a contractor must be registered as a Home Improvement Contractor("HIC"). M.G.L.Chapter 142A requires that the"reconstruction, alteration, renovation, repair, modernization, conversion, improvement, removal, demolition, or construction of an addition to any pre-existing owner-occupied building containing at least one but not more than four dwelling units....or to structures which are adjacent to such residence or building"be done by registered contractors. Note:If the homeowner has contracted with a corporation or LLC,that entity must be registered Type of Work: Solar Installation Est.Cost: $43,000 Address of work: 243 Park Hill Road - Northampton, MA 01062 Date of Permit Application: 07/11/19 I hereby certify that: Registration is not required for the following reason(s): _Work excluded by law(explain): _Job under$1,000.00 Owner obtaining own permit(explain): Building not owner-occupied _Other(specify): OWNERS OBTAINING THEIR OWN PERMIT OR ENTERING INTO CONTRACTS WITH UNREGISTERED CONTRACTORS OR SUBCONTRACTORS FOR APPLICABLE HOME IMPROVEMENT WORK ARE NOT ELIGIBLE FOR AND DO NOT HAVE ACCESS TO THE ARBITRATION PROGRAM OR GUARANTY FUND UNDER M.G.L.Chapter 142A.SUCH OWNERS ALSO ASSUME THE RESPONSIBILITES FOR ALL WORK PERFORMED UNDER THE BUILDING PERMIT.SEE NEXT PAGE FOR MORE INFORMATION. Signed under the penalties of perjury: I hereby apply for a building permit as the agent of the owner: 07/11/19 SunBua Solar LLC 163091 Date Contractor Name HIC Registration No. OR: Notwithstanding the above notice,I hereby apply for a building permit as the owner of the above property: Date Owner Name and Signature ,ign Envelope ID:3D118B2B-EC674419-B572-AD53DC2791B7 City of Northampton Massachusetts ^ti , �A !G DEPARTMENT OF BUILDING INSPECTIONS ` 212 Main Street •Municipal BuildingUV Northampton, MA 01060 Debris Disposal Affidavit In accordance of the provisions of MGL c 40, S54, I acknowledge that as a condition of the building permit all debris resulting from the construction activity governed by this Building Permit shall be disposed of in a properly licensed solid waste disposal facility, as defined by MGL c 111, S 150A. The debris from construction work being performed at: 243 Park Hill Road (Please print house number and street name) Is to be disposed of at: SunBug Solar - 66 Westfield Ind Park Rd - Westfield, MA 01085 (Please print name and location of facility) Or will be disposed of in a dumpster onsite rented or leased from: (Company Name and Address) Signature of Permit Applicant or Owner Date If, for any reason, the debris will not be disposed of as indicated, the Applicant or Owner shall notify the Building Department as to the location where the debris will be disposed. Pr,g7,Evelope ID:3D1 18B2B-EC67-4419-B572-AD53DC2791 B7 4 SunBug Solar" TURNKEY INSTALLATION AGREEMENT THIS AGREEMENT,dated 7/11/2019 (the"Effective Date')is entered into between Peter Courtright("Owner") and SunBug Solar,LLC ("Installer')whose physical address is 1165R Mass Ave.Arlington,MA 02476 and HIC license number is 163091,for the installation and/or improvement of a solar system at the Owner's premises located at 243 Park Hill Rd.Northampton, MA 01062(the"Premises�,all as more specifically described below(the"Project'. A. THE WORK Installer has previously submitted and Owner has approved the Proposal for the Project(the"Proposal"). By way of summary only,Installer's Scope of Work consists of the following elements as indicated: Materials Procurement Permitting Completion of Incentive Paperwork Turnkey Installation Electrical Interconnection Support Owner Operation Training Cwtomer is responsible for providing Inte met roxxectlox for online monitoring servicer. B. CONTRACT DOCUMENTS. This Turnkey Installation Agreement together with the Terms & Conditions set forth below(the"Terms and Conditions',any change orders executed by the parties("Change Orders')and the Proposal(each of which are incorporated herein by reference and may be referred to as the"Contract Documents'l comprise the entire agreement of the parties and mai be referred to as"this Agreement." C. CONTRACT SUM.PAYMENTS.REBATES. C 1. The cost of the Project, including all materials, labor and Installer's fees (described as the gross price in the Proposal) is$42,691 dollars("Guaranteed Maximum Price'). The Guaranteed Maximum Price is a fixed price,not an estimate,and can only be changed by the parties executing and delivering a Change Order(see Section 10 of the Terms& Conditions for more information on Change Orders). However,the cost of the Project may be affected by unanticipated regulatory requirements (rg.,such as wetlands studies) and unforeseen conditions occasionally discovered after Installer's engineering analysis (cg., structural reinforcement or roof repair). If this is the case, a Change Order reflecting a new Guaranteed Maximum Price will be required in order for the Project to continue. C 2. Owner will make payments to Installer in accordance with the following schedule. Payment Terms Breakdown Amounts Down payment $1,000 $ 1,000.00 /o due on order of materials 50% $ 30,419.50 /o due on construction completion 40% $ 24,335.60 Balance due on Utility Interconnection Balance $ 6,083.90 Total $ 61,839.00 C 3. Installer is ordering materials on behalf of Customer and will warehouse materials until time of installation. C 4. Installer may bill Owner partial progress payments for construction work(Lg.,when some work is scheduled to be done before or after our primary construction mobilization we may bill a portion of the construction payment for that work;rough-in electrical work,critter guard,etc.) C 5. Installer shall apply,on behalf of Owner,for applicable rebates including any rebates as offered by Owner's utility service.Unless otherwise noted below,any rebates shall be payable directly to Owner subject to utility or other third-party approval. Owner acknowledges that rebates payable to Installer have reduced the contract sum payable to Installer by Owner. o Rebates will be paid directly to Installer(Cbeck only if rebates to installer). C 6. If requested by Owner, Installer shall submit a Massachusetts Department of Energy Resources (DOER) and Massachusetts Clean Energy Center(MassCEC)Mass Solar Loan Technical Application.In that case,this Agreement and subsequent work is contingent on Program Loan approval(the"CEC Loan A$+provals'�. C 7. Installer shall secure all necessary construction related permits, other permits and/or governmental licenses and inspections necessary for the completion of the Project. Unless otherwise noted, fees associated with acquiring such permits,licenses and inspections will be home by Installer; owners who secure their own construction-related permits or deal with unregistered contractors shall be excluded from access to the Guarantee Fund. C 8. Contractor's obligations are specifically conditioned on the receipt of payment in full of the above amounts at the times specified. Without limiting the foregoing,delayed payments shall accrue interest at the rate of 1.0%per month. D. NOTICE OF RIGHT TO CANCEL. Owner may cancel this Agreement and the transactions contemplated hereby with no liability at any time prior to midnight on the third business day following the Effective Date. Page 1 of 6— SUNBUG SOLAR,LLC 0 2019 INSTALLATION AGREEMENT gn Envelope ID:3D118B2B-EC67-4419-8572-AD53DC2791B7 E. CONFLICTS. In the event of a conflict between this Turnkey Installation Agreement and any Contract Document or between the Terms and Conditions and any other Contract Document,this Tumkey Installation Agreement and the Terms and Conditions,respectively,shall govern. DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES Entered into as of the Effective Date: O\\NL•• Doo�cu�signee by: SUNBUG SOLAR,LLC f✓1tA' u Isignaturel OC9068EQFEE421... Peter Courtright By: Peter Ben Mayer,Sales Manager 7/11/2019 Date: Solar Consultant Dan Britton Page 2 of 6— SUNBUG SOLAR,LLC©2019 INSTALLATION AGREEMENT Pr!,gF�:nvelope ID:3D118B2B-EC67-4419-8572-AD53DC2791B7 SunBug Solar' TERMS & CONDITIONS These Terms&Conditions are incorporated by reference into that certain Turnkey Installation Agreement between Installer and Owner(together with these Terms&Conditions and the other documents incorporated by reference therein,this"AWeement")and applies to all products and services furnished by Installer thereunder. Capitalized terms used but not otherwise defined in these Terms&Conditions shall have the meanings assigned to them in the documents comprising this Agreement. 1. TIME OF COMMENCEMENT&SUBSTANTIAL COMPLETION. 1.1. Work on the Project(including all labor,materials,equipment and services,whether completed or partially completed under this Agreement, the "Work") will, unless otherwise scheduled in the Proposal, commence no later than sixty days (60) following the receipt of all applicable approvals including but not limited to the CEC Loan Approvals(the"Start Date'). 1.2. Installer estimates that the Work will be substantially completed within one hundred twenty(120) days following the Start Date (the "Completion Date'). Substantially complete shall be defined as the date the Owners receive a utility interconnection,or similar such certification from the applicable authority. 1.3. If the Work is delayed at any time by causes beyond Installer's reasonable control,which causes may include,but not be limited to, weather, acts of war or terrorism, material shortages, delays in the delivery of materials, Change Orders, inspection/permitting delays, labor disputes, design changes, hazardous site conditions, design flaws or impairments, subcontractor disputes,or Owner's use or directives,then the Completion Date will be extended for such equal number of days as occasioned the delay. In addition,the Completion Date may be extended for such reasonable time as Owner and Installer may determine in writing pursuant to a Change Order. 1.4. Installer shall have all materials required to commence the Work at the Premises no later than the Start Date. 1.5. Installer shall supervise and direct the Work in accordance with industry and regulatory standards,and it shall be solely responsible for all construction means,methods,techniques,sequences and procedures and for coordinating all portions of the Work hereunder. 2. WARRANTIES OF INSTALLER. 2.1. Installer warrants to Owner that all materials,equipment,and accessories incorporated into the Work by Installer will be new unless otherwise agreed in the Proposal.Except for the warranty specified in this Section 2.1,Installer disclaims any and all warranties with respect to any materials,equipment,or accessories incorporated into the Work,it being the understanding of Owner that such warranties,if any,shall be provided by the manufacturer thereof. 2.2. Installer wan-ants to Owner that all labor and services provided by Installer and included in the Work shall be of good quality,free from material defects,and in material conformance with the Contract Documents. 2.3. Upon written notice from Owner delivered to Installer no later than the 10th anniversary date of the Completion Date, Installer shall promptly correct any labor and services in breach of Section 2.2 above. Installer's obligation to promptly correct any labor and services in breach of Section 2.2 shall be Owner's sole and exclusive remedy for Installer's breach of 2.2 above.The provisions of this Article apply to Work performed by third parties engaged by Installer as well as to work done by direct employees of Installer. 2.4. To the extent assignable,Installer shall pass through to Owner all original manufacturers'warranties and shall provide Owner with its reasonable assistance in connection with any warranty claim against a manufacturer for defective materials, equipment,or accessories incorporated into the Work by Installer.Installer makes no representation or warranty regarding the warranties of manufacturers whose materials, equipment, or accessories are incorporated into the Work. Owner acknowledges that manufacturers' warranties may provide coverage to Owner for replacement of defective materials, equipment,or accessories,but that an individual manufacturer's warranty may not cover 100%of the costs and expenses home by Installer to troubleshoot and/or replace defective materials,equipment,or accessories. Payment to Installer for such uncovered corrective maintenance costs and expenses may be Owner's responsibility. 2.5. Enhanced Product Warranty. In instances where Installer is required to troubleshoot and/or replace defective materials, equipment,or accessories incorporated into the Work by Installer prior to the first anniversary date of the Completion Date, Installer shall waive all of its costs and expenses associated therewith in excess of the amount covered by the manufacturer's warranty, and Owner shall not be required to pay Installer such excess amount. Within the first year following the Completion Date,Owner may optionally select to purchase an extension to Installer's Enhanced Product Warranty through the tenth anniversary date of the Completion Date. 2.6. Notwithstanding anything contained herein to the contrary,Installer's warranties and obligations under this Article 2 do not extend to (i)any materials,equipment,or accessories not selected by Installer or its agents,or to work performed by third Page 3 of 6— SUNBUG SOLAR,LLC©2019 INSTALLATION AGREEMENT Prign7Enjolope ID:3D1 1862B-EC67-4419-B572-AD53DC2791 B7 parties not engaged by Installer, (it) any damage to the Work due to weather,animal infestation,or other external factors unrelated to Installer's installation workmanship, or (tri) the effectiveness of any accessories incorporated into the Work including,by way of example,pest abatement barriers(so-called critter guards)and snow abatement systems(so-called snow guards).Damage or defect caused by abuse,modifications not executed by Installer,improper or insufficient maintenance, improper operation,or normal wear and tear shall void Installer's warranties and obligations hereunder. 2.7. Installer disclaims any and all warranties or guarantees with respect to the level of electrical production of the Project. Information with respect to electrical production of the Project is based on manufacturer's estimates of installed materials, and of peak sun hours,sun direction,and other factors.Factors such as dust,shading,snow,ice,weather,and other natural and man-made elements,including usage,may adversely affect electrical production. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND IN LIEU OF ALL OTHER WARRANTIES OF QUALITY AND PERFORMANCE,WHETHER WRITTEN,ORAL OR IMPLIED,AND ALL OTHER WARRANTIES INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, NONINFRINGEMENT OR USAGE OF TRADE ARE HEREBY DISCLAIMED. THE REMEDIES STATED HEREIN CONSTITUTE OWNER'S EXCLUSIVE REMEDIES AND INSTALLER'S ENTIRE LIABILITY FOR ANY BREACH OF WARRANTY. 3. COMPLIANCE WITH LAWS. 3.1. Unless otherwise specified in this Agreement,Installer shall secure all necessary permits,any applicable rebate applications, other governmental licenses and inspections necessary for the completion of the Project. Unless otherwise specified in this Agreement,fees associated with acquiring such permits,licenses and inspections will be bome by Installer. 3.2. Owner shall furnish at Owner's expense,all of the following as deemed necessary by the Installer. 3.2.1. Legal descriptions (including legal limitations such as easements, rights of way, codes, covenants, conditions,restrictions,design guidelines),surveys and utility locations for the Premises;and 3.2.2. Any required engineering plans,drawings,calculations,or specifications (the"Additional Plans') ()in order to obtain any required non-ministerial permits or inspections,or(n)in order to adequately secure the Premises and provide reasonable safety precautions.Owner acknowledges that some municipalities, utilities or other necessary permitting parties may require specific engineering studies or inspections in addition to those customary required or already obtained by Owner 3.3. Installer shall give all notices and comply with all laws, ordinances, rules, regulations, and lawful orders of any public authority applicable to the performance of the Work,and shall promptly notify Owner if it has a reasonable basis to conclude that the designs,plans or Additional Plans are at variance therewith. 3.4. Installer shall be responsible for all safety precautions in connection with the Work. Installer shall take all legally required and commercially reasonable safety precautions at the Premises. 3.5. Installer and all subcontractors shall be registered as home improvement contractors and any inquiries relating to a registration should be directed to:Office of Consumer Affairs and Business Regulation Ten Park Plaza,Suite 5170 Boston, MA 02116 Phone:(617)973-8700 4. INSURANCE. Installer's liability insurance shall be purchased and maintained by the Installer to cover claims under workers' compensation acts and other employee benefit acts,claims for damage because of bodily injury,including death,and from claims for property damage to the Premises which may arise out of or result from Installer's operations under this Agreement,whether such operations be by itself or by any subcontractor or anyone directly or indirectly employed by any of them.This insurance shall be written for not less than the minimums required by the state where the Project is located under applicable law and state rebate programs.Certificates of such insurance shall be filed with Owner prior to the commencement of the Work at Owner(s)'request. Owner shall maintain liability insurance(either as separate policy or included in a homeowners or excess liability policy)sufficient to meet to Owner indemnity obligations under Section 8 below. 5. SUBCONTRACTORS. Owner acknowledges that portions of the Work may be allocated to Subcontractors. Installer shall not employ any subcontractor to whom the Owner may have a reasonable objection. Installer shall not be required to contract with anyone to whom it has a reasonable objection. The Guaranteed Maximum Price includes the cost of a qualified electrician for electrical interconnection to the utility. Unless specifically noted in the Proposal, additional costs for any required electrical upgrades or improvements to the site's electrical service and components shall be the responsibility of Owner and are not included in the Guaranteed Maximum Price. 6. SITE CONDITIONS. Owner has no knowledge of any pre-existing toxic materials, hazardous substances, or defective or dangerous conditions,structural or otherwise which may pose a health or injury risk to Installer or Installer's employees or agents. In the event that Installer observes hazardous site conditions,Installer will notify Owner promptly and Owner and Installer will,if feasible,execute a Change Order for the remediation of such conditions.Such hazardous conditions will postpone the Completion Page 4 of 6— SUNBUG SOLAR,LLC 0 2019 INSTALLATION AGREEMENT rignEnvelope ID:3D118B2B-EC67-4419-B572-AD53DC2791B7 Date by the amount of days required to complete remediation.The Guaranteed Maximum Price includes the cost of basic site preparation, but does not include the cost of any remedial site preparation as contemplated in this Section. The cost of such remedial site preparation shall be the responsibility of Owner. Z INCENTIVE APPLICATIONS. Unless otherwise set forth in this Agreement,Installer shall apply for available incentives on behalf of Owner.Owner will assist Installer in such application process and warrants that all Owner information provided therein (including financial information,home value information and other personal information)shall be true,correct and complete as of the date of the application.Owner agrees that Installer will be listed as the primary installer/contractor on any application and be credited as the installer of record on all public documents and correspondence concerning the Project. Owner hereby acknowledges that Installer makes no warranty or guarantee of the availability of all,or any part of,any federal,state,local or utility incentives,tax credits or deductions. Owner is encouraged to consult vith a tax advisor as to the availability of tax credits with respect to the Project. 8. INDEMNITY. 8.1. To the fullest extent permitted by law, Owner shall indemnity, hold harmless and reimburse Installer, its agents and employees from and against all claims,damages,losses and expenses(including,but not limited to reasonable attorney's fees) arising out of or resulting from any death,bodily injury or illness or destruction to property,including any resulting loss of use thereof(i)due to a breach of Owner's warranty contained in the first sentence of Section 6 above or(ii) to the extent resulting from the negligence or misconduct of Owner or its invitees or agents(other than Installer and its subcontractors). Owner's indemnification obligations herein are conditioned upon the following. (a) it is promptly notified in writing; provided,that the indemnified party's failure to promptly notify shall not relieve the indemnifying party of its obligations hereunder to the extent the indemnifying parry is not actually prejudiced, (b)Owner is allowed to exercise sole control over the defense of any claim and all related settlement negotiations(with counsel reasonably acceptable to the indemnified party); and (c) the indemnified party provides Owner, at Owner's expense, all reasonably necessary assistance, information, and authority to perform the above. The indemnified party shall have the right to participate in its defense with counsel of its own choosing at the indemnified party's sole cost and expense. 8.2. The foregoing notwithstanding, Owner will not make any offers of settlement nor enter into any settlement agreements without the written consent of the indemnified party,which consent will not be unreasonably withheld or delayed. 9. LIMITATIONS ON DAMAGES AND LIABILITY. Except in connection with Owner's obligations under Section 8,each party's liability to the other parry for any loss,cost,claim,injury,liability,or expense,including reasonable attorney's fees,relating to or arising from any act or omission in its performance of this Agreement, shall be limited to the amount of direct damage actually incurred. Except in connection with Owner's obligations under Section 8,in no event shall either party be liable to the other party for any indirect, incidental, special, consequential, or punitive damages of any kind whatsoever. This waiver shall survive any termination of this Agreement. 10. CHANGE IN THE WORK. Owner, without invalidating this Agreement, may seek changes in the Project consisting of additions, deletions, or modifications. In addition, changes in the Project may be necessitated by permitting or regulatory requirements. All such changes in the Project shall be authorized by a written Change Order signed by Owner and Installer. Installer will advise Owner of the cost of a proposed Change Order,and,if executed,the Guaranteed Maximum Price or price per watt will be adjusted accordingly.All Change Orders will include revision of the Completion Date. 11. TERMINATION. 11.1. If a Change Order is necessary to complete the work,either party has the option to terminate the agreement. 11.2. Either party may terminate this Agreement by a written notice(a"Default Notice")if the other party commits any material breach of this Agreement;provided,that if such breach is capable of cure,such party shall have seven(7)days following its receipt of a Default Notice(the"Cure Period')to cure such breach to the non-breaching party's reasonable satisfaction.If such breach is not cured prior to the expiration of the Cure Period,the non-breaching party may terminate this Agreement immediately by written notice. By way of example only,material breaches include the following: (a)Owner fails to make a payment when due(in which event Installer may,in its discretion,also suspend work until payment is made);(b)Owner fails to promptly execute a Change Order necessitated by a revision in the Minimum Technical Requirements of a permitting body or regulator;(c)Installer persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; (d) Installer fails to make payment to subcontractors for materials or labor in accordance with the respective agreements between the Installer and subcontractors; and (e) Installer persistently disregards laws, ordinances, or rules, regulations or orders of a public authority having jurisdiction. 11.3. If the CEC Loan Approvals are not obtained,this Agreement shall automatically terminate unless Owner provides Installer with prompt written notice that it wishes to proceed with the Project. 11.4. Either Owner or Installer may terminate this Agreement upon fifteen(15)days prior written notice,if the parties are unable to promptly agree on the terms of a Change Order reasonably necessary for the completion of the Project(fg.,changes due to regulatory requirements or hazardous conditions). Page 5 of 6— SUNBUG SOLAR,LLC©2019 INSTALLATION AGREEMENT rignEnvelope ID:3D118B2B-EC67-4419-8572-AD53DC2791B7 11.5. If this Agreement is terminated for any reason,Owner shall pay Installer for all work completed and materials used through the date of termination. 11.6. Notwithstanding anything to the contrary set forth herein,Sections 2,the first sentence of Section 6,8,9,11(d),11(e),12,13 and 14 of this Agreement and any remedies for the breach thereof,shall survive the termination of this Agreement under the terms hereof. Termination of this Agreement shall not relieve or release either party from any rights,liabilities or obligations which it or she has accrued prior the effective date of such termination. 12. CHOICE OF LAW. This Agreement shall be governed by the internal laws of the Commonwealth of Massachusetts without regard to principles of conflicts of laws. Disputes arising hereunder shall be adjudicated solely and exclusively in Boston,Massachusetts. 13. PROMOTIONAL USE OF PROJECT. Installer may use the description and images of the Project along with any supplied recommendations or testimony of Owner for promotional purposes. @'promotional consent notgranted,or if owner requires individual prior written consent,check herr:u) 14. GENERAL PROVISIONS. This Agreement set forth the entire agreement and understanding between Owner and Installer relating to the subject matter hereof,and merges all prior discussions between them. If any one or more of the provisions in this Agreement are deemed void by law,then the remaining provisions will continue in full force and effect. No waiver by either party of any term or condition of this Agreement,whether by conduct or otherwise,in any one or more instance, shall be deemed a continuing waiver of any such term or condition,or a waiver of any other term or condition of this Agreement. Headings set forth in this Agreement are solely for the convenience of the parties and have no legal effect. The singular shall include the plural,and the masculine gender shall include the feminine and neuter,and vice versa,unless the context otherwise requires.This Agreement may be executed and delivered either originally or by facsimile transmission,and in one or more counterparts,each of which shall be deemed an original and all of which taken together shall constitute one and the same instrument. This Agreement shall be(i) binding upon,and will inure to the benefit of,the parties and their permitted respective successors and assigns and(6)construed without presumption of any rule requiring construction to be made against the party causing it to be drafted. Page 6 of 6— SUNBUG SOLAR,LLC©2019 INSTALLATION AGREEMENT WESTSHORE DESIGN ENGINEERS, P.C. - 100 GREAT OAKS BLVD. I SUITE 115 ALBANY I NEW YORK 1 12203 To: SunBug Solar 66 Westfield Industrial Park Rd. Westfield,MA 01085 Date: July 15,2019 Ref.: 19070424 Subject: Courtright Residence 342 Park Hill Rd. Northampton, MA To Whom It May Concern, The following references the Courtright Residence in Northampton, MA: 1. Existing roof framin& Roofs 1&2: Conventional framing is 2x 10 at 16"o.c. with a 16'-6" max. span (horizontal rafter projection). This existing structure is capable to support all the loads that are indicated below for this photovoltaic project. 2. Roof Loading: - 4.33psf dead load(modules plus mounting hardware) - 40psf ground snow load - 6.9psf roof materials(2.9psf 2x10, 1.5psf sheathing,2.5psf asphalt shingles) - Exposure Category B, 140mph wind(3 sec.) This installation design will be in general conformance to the manufacturer's specifications,and complies with all applicable laws, codes, and ordinances, specifically the International Building Code/IBC 2015 and International Residential Code/IRC 2015 including all MA regulations and amendments. The spacing and fastening of the mounting brackets is to have a maximum of 48"o.c.span between mounting brackets, staggered, and secured using 5/16" diameter corrosive resistant steel lag bolts. A minimum of 2.5" of penetration per lag bolt is required,which is adequate to resist all 125mph wind live loads including wind shear. Per NDS Section 11.1.4 clearance holes equal to the diameter of the shank need to be bored into primary a primary framing member for the full length to the threaded portion of the screw to avoid splitting of the framing member. Thank you. agog° SGS Westshore Design Engineers NICOLAS A. Ems, <n NITTI CIVIL NO. 50222 ,o gfGISTE4E� 0� 9p July 15,2019 John Eibert Nicolas Nitti,PE Project Coordinator President Westshore Design Engineers 1100 Great Oaks Blvd.I Suite 115 1 Albany,NY 12203 1518.313.7153 SITE PLAN:SCALE:-1°=64' SITE PLAN DETAIL:SCALE:-1"=10.6666T SOLAR SOLAR PITCH AZIMUTH AREA WEIGHT #MODULES (SOFT) (LBS) N N AR-01 40° 122° 483.34 1060.54 26 AR-02 0° 122° 204.49 448.69 11 (N)TESLA ENERGY GATEWAY (E)SUBPANEL CONDUIT RUN (THROUGH ATTIC) (2)TESLA POWERWALL 2 (E)RESIDENCE (N)1 SOLAREDGE SET APP INVERTER SE1000OH-US (N)MA SMART METER (N)W A PV SYSTEM AC DISCONNECT 1 (E)MAIN SERVICE PANEL n ✓ (E)UTILITY METER (E)RESIDENCE (�✓� PP / (N)ARRAY AR-01 / r aSunBug Solar' \ \\ CONTRACTOR INSTALLED SUNBUG SOLAR ABBE \ DANIEL(N)ARRAY AR-02 411A HIGHLAND AVE \ \ SUITE 312,SOMERVILLE, MA 01854 \ Pnar:(6t](ypp�B7B mm TESLA POWERWALLS TO BE PLACED INSIDE E�e. e�e.p.unwy�w \ THE BASEMENT PETER COURTRIGHT \ EXISTING SUB PANEL IS INSIDE THE BASEMENT 243 PARK HILL RD i NORTHAMPTON,MA 01062 3 PARK HILL RD RD LEGEND Ra (E)DRIVEWAY 24 0 METER DATE 14 Wpu1 ZO+e ©MAIN SERVICE PANEL JOB NUMBER2=WESW rA-C-p AC DISCONNECT VM PV PRODUCTION METER SITE PLAN ©JUNCTION BOX n`/ n L°O 0 INVERTER r V #MODULES PER ROOF TYPE ATTACHMENT ROOF HEIGHT FRAME MATERIAL FRAME TYPE FRAME SIZE OC SPACING ARRAY AR-01 26 ASPHALT SHINGLE SNAPNRACK ULTRA RAIL COMP KIT TWO STORY WOOD RAFTER Z"x 10" 16'O.C. AR-02 11 ASPHALT SHINGLE SNAPNRACK ULTRA RAIL TWO STORY WOOD RAFTER 2"X 10" 16'O.C. STANDOFF TILT KITS LEGEND RAIL PITCH:40° V-3" RAFTERS AZIMUTH:122° 1-� ►_ -*I 'i • ATTACHMENT POINTS f - - ►- - ♦ 2"x 10'RAFTER @ 16"OC * SNAPNRACK ULTRA RAIL I -- t- - = ♦ - COMP KIT ATTACHMENT PLAN ATTACHMENTS MAX.RAIL OVERHANG IR (26)OPTIMIZER lMx SNAPNRACK ULTRA RAIL SPIN K(STAGGER ATTACHENTS) mF w ■ sosGN RAILS 19r(MIN r,aTayww)ERow EDGE OF ♦ SOLAREDGE P370 ♦ f ♦ ♦ -RAIL ROOF FRAMING _ RAIL W,WTERS2UP IV OC _75:2.10-If OC WA I ' i 4'-0' •.�.� �.•. d 6'-1` A9Y wA wA - -- -— ♦-+ ARRAY POSITION POSITION MP1 ROOF ARRAY CENTERED ON ROOF AND TIGHT TO RIDGE POSITION MP2 ROOF ARRAY CENTERED ON R",ADMT ACCORDNCAY FOR 19'-5" 13'-8" 13'-7r" 0'-6" OBSTRUCTIONS ADDITIONAL WORK CRn7ER GUARDS �naKE END DEAN" AR-02-SCALE 8' 1'= PITCH:0° SNOW GUARDS AZIMUTH:122° 8(RNCE� 0,$, 37'-6' aTN1CTIFK AEaA'aRCE aE[arRucnwu ENGnfEREA: aTAGGER PATTERN SEE a T,1UCTUAft ENOry SW _-_--_-__ /1/ * ■ ■. ' �. .. .t.. -. 9 _ - 5'-7" WA a....- --t-- --�- ---- -..�--�- - -- ♦--... --♦ - 2"x 10"RAFTER @ 16"OC 51— SNAPNRACK ULTRA-RAIL CONTRACTOR INSTALLED EQUIPMENT LOCATION RAIL SUNBUG SOLAR awERTER ,EEE GETnExPIEFw EaurEcrrrLxwTE,N..cuF.Mn.Icw9uTcueTwER ',, SNAPNRACK ULTRA RAIL DANIEL LABBE H„E,E'No,.NTPRoo.NETEAEocaETo,neloEHURAcoBco.lAwvEME,ERax«ET 411A HIGHLAND AVE AC DISCONNECT 6AE T—YRTMN 19 FT 6 UTL- TER.VM K MOM( IE 9Wr E 13'-7" I I ''. ''. '', ''� '. STANDOFF TILT KITS DISCONNECTN1SUITE 312,SOMERVILLE, PROJECT NOTES PI 01854 ' RVr(617)5W3934 E�I'.BAniN Ie0E.9Nmd9wlrovn SNR MID CLAMPS.END CLAMPS.RAL SPIICEE TORQUE TO 1aFTy// '' ' (11)OPTIMIZER SOLAREDGE P370 PETER COURTRIGHT 243 PARK HILL RD 6,9' NORTHAMPTON,MA 01062 1 3�" 0,-4. t Rw A DATE-14Ag" 2019 •... _ -.-._.._ .qB NUTABER�.2212-WESW ,�� 4'-0" 5'-7' DETAIL LAYOUT —ak NOTE:-MAX.ATTACHMENT SPACING IS V-0" PV 3.0 NOTE:-MAX.ATTACHMENT SPACING IS 4'-0' DESIGN CRITERIA MODULES: PV MODULE 37 MAX DISTRIBUTED LOAD:3 PSF SNOW LOAD:40 PSF WIND SPEED: 117 MPH 3-SEC GUST. LAG SCREWS: 5116"x 2.5"MIN EMBEDMENT SEE(2117V 3.1) ` NOTE: FOR ENLARGED INSTALLERS TO VERIFY RAFTER VIEW SIZE,SPACING AND SLOPED O C. SPANS,AND NOTIFY E.O.R.OF 1p^RPFjER@ 15 PROCEED E ANY ANCIES BEFORE (E)SINGLE LAYER OF ASPHALT SHINGLE POINT LOAD CALCULATION PER ARRAY ITEM #OR WEIGHT TOTAL WEIGHT LIN FT PER(Ibs) (lbs) MODULES 37 40.79 1509.23 RAILS 214.95 0.4 93.7 1 ATTACHMENT DETAIL ATTACHMENTS 84 0.65 5460 TILT LEGS 20 3.5 70 PV-31 SCARF NTS POWER OPTIMIZER 37 1.4 51.8 TOTAL WEIGHT 1779.3 MODULE DIMENSION(LxW) 66.4"x 40.0"= 18.59 sq.ft PV MODULES WEIGHT PER MOUNT 1779.31 84- 21.2 lbs/Mount WEIGHT PER SO FT 1779.3 f 687.83 sq.tt.=2.6 Ibs/sq.ft. $SunSug Jalar' SNAPNRACK ULTRA RAIL COMP KIT SNAPNRACK ULTRA RAIL CONTRACTOR INSTALLED UNIVERSAL END CLAMP(OR COMP KIT ATTACHMENT GROUNDING MID CLAMP) SUNBUG SOLAR SNAPNRACK ULTRA-RAIL DANIEL LABBE 411A HIGHLAND AVE SNAPNRACK ULTRA RAIL COMP SUITE 312,SOMERVILLE, KIT FLASHING MA 01854 2'x 10"RAFTER@ 16 O.C. B>>xv 39M Emw a.�+e isoeetnv.�o��w,:� (E)SINGLE LAYER OF ASPHALT SHINGLES 1 5116'X 3-1/2"SS LAG SCREW PETER COURTRIGHT THREADED TOP 1 LAG PER ATTACHMENT 2.5"MIN EMBEDMENT 243 PARK HILL RD NORTHAMPTON,MA 01062 Rev A DATE'4 August 20'9 :OB NUMBFR 2282-5- 2 ATTACHMENT DETAIL (section view)- PV-31 MOUNTING LAYOUT PV 3.1 SNAPNRACK END CLAMP(OR GROUNDING MID CLAMP) P SNAPNRACK V MODULE STANDOFFBASE `o 'o NOTE: SNAPNRACK SNAPNRACK ULTRA-RAIL PANELS IN PORTRAIT TO BE / FRONT LEG TILTED UP TO WON NORTH FACING DORMER 7O SNAPNRACK ULTRA RAIL STANDOFF TILT KITS F R� 76'0 SNAPNRACK c REAR LEG,23" (E)SINGLE LAYER OF 5116"X 3-112"SS LAG SCREW ASPHALT SHINGLE THREADED TOP 1 LAG PER ATTACHMENT 2.5"MIN EMBEDMENT SunBug Solar' CONTRACTOR INSTALLED SUNBUG SOLAR DANIEL LABBE 411A HIGHLAND AVE SUITE 312,SOMERVILLE, MA 01854 Pb 4611)5W3936 E~d—W.b40�Aw+pgwlr.oan PETER COURTRIGHT 243 PARK HILL RD NORTHAMPTON,MA 01062 1 ATTACHMENT DETAIL PV-3.2 SCALE:NTS DATE 1a iW M 2019 JOBNASER1262-WEB. MOUNTING LAYOUT PV 3.2 CONDUIT SCHEDULE GROUND CONNECT SYSTEM VIA INSULATION EXISTING METER METER i 05059398 CONDUCTOR CONDUCTOR SYSTEM SIZE:13505W OC,10008W AC PIERCING ON SUPPLY SIDE OF THE R CONDUIT (REaBLACK) NEUTRAL(WI,ITE) (CONTROL CABLE) (GREEN) (eARECOPPER) MAIN BREAKER FOR 200A SUBPANEL UNDERGROUND UTILITY SERVICE 1 NONE (2)10 AWG PV WIRE NONE NONE NONE (1)06 NOTE: INSIDE BASEMENT. NATIONAL GRID 2A 3N'EMT (2)16 Awa NONE NONE (i)IOAWG NONE SOLAREDGE INVERTER IS EQUIPPED WITH RAPID SHUTDOWN �O CONO THHNfThWN-2 THHN/THWN-2 2 3/4'EMT (6)16 AWG NONE NONE jtj 10 Awc NONE FUINCTION PER NEC 690.12. 5 Sl9PANEl A THHWTHWW2 THHNnHWN-2 100A-2P IV' 3 3/4'EMT (2)6 AWG (1)B AWG NONE (1)10 AWG NONE THHN/THWN-2 THHWTHWN-2I THHNITHWN-2 5 4 3N'EMT (2)10 AWG (1)10 AWG (4)22 AWG (1)10 AWG NONE THHN/THWN-2 THHN/fMMN-2 THHWTHWFL2 THNNRHWN-2 (2)2AWG (1)2 AWG NONE NONE (1)10 AWG NONE 2P 5 1-19-EMT THHWTHWN-2 THHWTMMN-2 THH 0A-M-2 200A (N)BACK UP LOADS NEW 100AAC EXISTING PANEL K UP L, DISCONNECT(2-POLE 3 3 1201240V FUSED) WI 100A FUSES EXISTING 1 JUNCTION BOX (N) LOACKABLE METER/MAIN PANEL _ OR EQUIVALENT BLADE TYPE 2P TOO 200A MAIN BREAKER LG LG36501C-A5 UTILITY AC 125A 100A MAIN BREAKER (13)SolarEdge P370 DISCONNECT �CT LEADS (1)STRING OF(13)MODULES —� STRING A,ARRAY 1 ti 1 M 2P CTRL 200A LG LG365Q1C-A5 2A EXISTING (13)SolarEdge P370 `o (1)STRING OF(13)MODULES SUPPLY SIDE STRING B,ARRAY 1 CONNECTION 30A-2P (N)TESLA ENERGY 1 _ GATEWAY 200 A. EXISTING BOA-2P 30A_2p NEMA 3R,UL LISTED SUB PANEL (DUAL LUGGED) 2SU00A PANEL LG LG365Q1C-A5 IOOA MAIN BREAKER NEW SOLAR INVERTER NEW 80A 200A BREAKER BUSBAR (11)SolarEdge P370 AC DISCONNECT (1)STRING OF(11)MODULES �— 2 SOLAREDGE SET APP 3R 2P TO Q 5 END FED STRING C,ARRAY 2 INVERTER SE10000H-US 120f240C (IN BASEMENT) JUNCTION BOX 400V 42A MAX CURENT NON-FUSED OR EQUIVALENT 3 0%SUnBUg Solar NOTE: (N)MA SMART METER 4 CONTRACTOR INSTALLED • IN THE EVENT OF A GRID OUTAGE WHEN THE PV SYSTEM OUTPUT EXCEEDS THE LOADS,THE 4 SUNBUG SOLAR POWERWALL 2 SYSTEM WILL CHANGE THE DANIEL LABBE FREQUENCY OF THE POWERWALL 2INVERTER OUTPUT CIRCUIT PER THE UL 1741 LISTING TO 411A HIGHLAND AVE SHUT DOWN THE SOLAR INVERTER AVOIDING ANY (N)13.SKWH TESLA POWER IN)13.5KWH TESLA POWER SUITE 312,SOMERVILLE, WALL.UL LISTED.NEMA 3R DAMAGE TO THE SYSTEM. WALL.UL LISTED,NEMA 3R MA 01854 • WHEN A GRID OUTAGE IS DETECTED,THE 5eW CONTMUOus. sew eoNTlNuous. Tkw PEAK PNre:re,T)sOP�JB GATEWAY INSTANTLY ISOLATES POWERWALL Tew PEAK Em•JO•niN aee•Aw,a,B,ow.r.•0. CTRL CTRL FROM THE GRID USING A MICROPROCESSOR-CONTROLLED POWER PETER COURTRIGHT CONTACTOR. 243 PARK HILL RD PV PRODUCTION METER — NORTHAMPTON,MA 01062 GROUNDING NOTES: + t 1. THE BACKUP GATEWAY SHIPS WITH A SN OF — R°"A A. SIZE EGC PER NEC 250.122 NEUTRAL TO GROUND JUMPER INSTALLED. DATE z2 AugW 20,8 DNm J. B. SIZE GEC FROM PANEL GROUND BAR TO ENSURE THE NEUTRAL TO GROUND BOND IS 00LOM90 _ _ 308 NUMBER-2282-wEaw GROUNDD ROD/UFER PER NEC 250.166 8 NOT DUPLICATED AND IS LOCATED 250.66 APPROPRIATELY IN ACCORDANCE WITH ALL EXCEPTION:WHEN ESTABLISHING NEW GROUND APPLICABLE CODES AND STANDARDS. Qi ELECTRICAL AT THE MAIN PANEL,GEC WILL BE SIZED AS#6 AWG 2. WHEN USING THE TESLA PROVIDED NOTE:IF TAP INSIDE,AN EXTERIOR AC FUSED CU PER NEC 250.66(A) NEUTRAL-GROUND JUMPER ENSURE THE -, L DISCONNECT REQUIRED WITHING 10 FT OF TAP. ALL CONDUCTORS AND TERMINATIONS SHALL BE GROUNDING ELECTRODE CONDUCTOR IF TAP IS EXTERIOR,THE EXTERIOR PV 4.0 LISTED FOR 75 DEGREES. COMPLIES WITH NEC 250.7008-23-2019 DISCONNECT MUST BE FUSED. INVERTER RATING MODULE AND ARRAY RATINGS:(37)MODULES) TESLA POWERWALL 2.0 SPECIFICATIONS SOLAR MODULE RATINGS(STC) STRING A STRINGS STRING C MANUFACTURER/MODEL M TESLA POWERWALL 2.0 SOLAREDGE MAXCONTINOUSPOWER 5KW MAKE SET APP MAKE LG SERIES 13 13 11 OVER CURRRENT PROTECTION DEVICE 30A INVERTER MODEL SEt0000H-US MODEL LG36501C-A5 PARALLEL 1 1 1 Imp 9.95A Imp 11.9A 11.9A 10.OA MAX INPUT CURRENT 27A Vmp 36.7V Vmp 400V 400V 400V MAX POWER Isc 10.80A Isc 15A 15A 15A (AC) 10000W Voc 42.BV Voc 480V 480V 480V NOM.AC Pmax 365W Pmax 4745W 4745W 4015W VOLTAGE 240V %VodC •0.24% MAX AC 42A CURRENT CONDUCTOR SIZING CALULATIONS CEC CURRENT EFFICIENCY WA CIRCUIT CURRENT Imax(890.8(A)) Icont(890.8(Bx2)(a) SPECIFIED AMPACITY AMBIENT CARRYING CO(69 OF USE APPLIED DESCRIPTION ealc CONDUCTOR 90C TEMP c COND. (690.8(Bx2)(D)talc PV SOURCE 15A 15A 15A Imax x #10 THWN-2 40A 31-35 4-6 40A x 0.96(am b.temp)x 0.8 CIRCUIT STRING A 1.25=18.75A (raceway fill)=30.72A PV SOURCE 15A 15A 15A Imax x #10 THWN-2 40A 31-35 4-6 40A x 0.96(am b.temp)x 0.8 CIRCUIT STRING B 1.25=18.75A (raceway fill)=30.72A PV SOURCE 5A 15A ISA Imax x #10 THWN-2 40A 31-35 q.8 40A x 0.96(am b.temp)x 0.8 1 CIRCUIT STRING C 1.25=18.75A (raceway fill)-30.72A INVERTER AC 42A 42A 42A Imax x 1.25= #6 THWN-2 76A 31-35 1-3 75A x 0.96(am b.temp.)xl OUTPUT 52.50A (raceway BM)=72A TESLA 13AT'TERY 30A 30A 30A #10 THWN-2 30A 31-35 1-3 `55A x 1.00(am b.temp.)xl OUTPUT (raceway fill)=52.8A TERMINAL TEMPERATURE RATING CONSIDERATIONS SunBN9 Sobf• TERMINAL TEMP SPECIFIED AMPACITY CIRCUIT DESCRIPTION CURRENT loom RATING CONDUCTOR TERMNAL TEMP. CONTRACTOR INSTALLED RATING PV SOURCE CIRCUIT STRING 15A 15A Imax x 1.25=18.75A 75C #10 35A SUNBUG SOLAR A DANIEL LABBE PV SOURCE CIRCUIT STRING 16A 15A Imax x 1.25=18.75A 75C #10 35A 411A HIGHLAND AVE B 15A 15A Imax x 1.25=18.75A 75C #10 35A SUITE 312,SOMERVILLE, PV SOURCE CIRCUIT STRING C MA 01854 Ph-611)5W3930 INVERTER AC OUTPUT 42A 42A Imax x 1.25=52.50A 75C #6 65A En ld..N - TESLA BATTERY OUTPUT 30A 30A 75C #10 35A PETER COURTRIGHT 243 PARK HILL RD NORTHAMPTON,MA 01062 VOLTAGE DROP CALCULATIONS Rev A LENGTH I Ohms/kFt V CALC Vdrop DATE 12 AugW 20% JOB NLOMER'2M-WFS-W 5OFt 15A 0.9989 400V 50'x 15A x 2 x 0.9989/1 OW/400V= 0.37% 5OFt 15A 0.9989 400V 50'x 15A x 2 x 0.9989/1000'1400V= 0.37% ELECTRICAL 5OFt 15A 0.9989 400V 50'x 15A x 2 x 0.99119/1000'1400V= 0.37% 30F1 42A 0.6282 240V 30'x 42A x 2 x 0.628211000'/240V= 0.66% PV 4.1 INSTALL ON THE UTILITY METER INSTALL ON THE AC DISCONNECT INSTALL ON THE INVERTER PHOTOVOLTAIC SYSTEM PHOTOVOLTAICCAUTION: DISCONNECTAC DISCONNECT DC POWER TO THIS BUILDING IS ALSO SUPPLIED OPERATING VOLTAGE11 VDC FROM THE FOLLOWING SOURCES WITH OPERATING DISCONNECTS LOCATED AS SHOWN: CURRENT 33 76 AMPS OPERATING VOLTAGE1 VOLTS OPERATINGMAX SYSTEM VOLTAGE :1 VDC SHORT INSTALL ON THE MAIN BREAKER PANEL CHARGE CONTROLLER DISCONNECTPV SYSTEM •' SHUTDOWNRAPID OPERATION PV ARRAY SWITCH FOR SOLAR (2)TESLA POWERWALL 2 SUB PANEL TO BE INSTALLED IN ACCORDANCE ENERGY GATEWAY WITH SECTION 690.5NC): METER ECTRIC MAIN SEPAVNIEL NVERCE TERION PANEL AC SYSTEM CONNECTED PV METER DISCONNECTS PHOTOVOLTAIC SYSTEM 243 PARK HILL RD.NORTHAMPTON.MA 01082 AC DISCONNECT SOLAR PV SYSTEM OPERATING VOLTAGE 241 VOLTS EQUIPPED WITH • - 42 AMPS RAPID SHUTDOWN I$SunBug Solar' CONTRACTOR INSTALLED ,.wn4tae. wwK. SUNBUG SOLAR DANIEL LABBE _ 411A HIGHLAND AVE SUITE 312,SOMERVILLE, INSTALL EVERY 10 FEET ON CONDUIT. MA 01854 TURN RAPID SHUTDOWN SWFtCH TO Pros- (61115M3936 THE"OFF'POSITION TO SHUT DOWN WARNING: E�Ydan 1 0°°•"n°�O�m" CAUTION PV SYSTEM AND REDUCE POWER SOURCE SHOCK HAZARD IN THE ARRAY. PETER COURTRIGHT TRI POWER SOURCE SECOND SOURCE S PHOTOVOLTAIC SYSTEM 243 PARK HILL RD THIRD SOURCE IS ENERGY STORAGE SYSTEM NORTHAMPTON,MA 01062 INSTALL ON THE BACK UP PANEL INSTALL ON THE MAIN SERVICE PANEL R.A INSTALL INSIDE THE BACK UP PANL,NEXT DATE 22 Augu 2019 TO THE SOLAR BREAKER JOB NUMBER2261-NES-W : LOAD CAPACITY FOR ALL BRANCH -V SOLAR DO BREAKERENERGY STORAGE SYSTEM CIRCUITS WITHIN THIS PANEL WARNING LABELS NOT RELOCATE ON SITE LOCATED INSIDE SHALL NOT • AMPS THIS OVERCURRENT DEVICE PV 5.0 Commonwealth of Massachusetts Division of Professional Licensure Board of Building Regulations and Standards Construction Supervisor CS-109144 Expires: 07/21/2021 AARON SIMMS 42 LEAD MINE RD - SOUTHAMPTON MA 01073 r f Commissioner . ///l� ��f�2/l2�/ZCI��'CZ��/� �� � �/�/(iCl^il/�/1lCcsEl��✓ Office of Consumer Affairs and Business Regulation 1000 Washington Street - Suite 710 Boston, Massachusetts 02118 Home Improvement Contractor Registration -=—�� Type: LLC / Registration: 163091 SUN BUG SOLAR LLC. Expiration: 05/10/2021 411 A HIGHLAND AVE. ST 312 SOMERVILLE, MA 02144 Update Address and Return Card. SCA 1 l3 20M-W17 Office of Consumer Affairs& Business Regulation HOME IMPROVEMENT CONTRACTOR Registration valid for individual use only TYPE: LLC before the expiration date. If found return to: Registration Expiration Office of Consumer Affairs and Business Regulation 163091 05/10/2021 1000 Washington Street - Suite 710 SUN BUG SOLAR LLC. Boston, MA 02118 CHENEY BRAND 411A HIGHLAND AVE. ST 312 SOMERVILLE, MA 02144 Not valid without signature Undersecretary -� SUNBSOL-01 RUSSHI ACORD �- CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/VYYY)4/29/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: ---._--- Risk Consulting Partners PHONE, _ 8112 Maryland Ave. A// o,Ext):(314)678-1200 - -- _ FAX C 4)3W1 751 No):(31 ... ---------- Suite 400 E-MAIL info@rcpholdings.com Clayton,MO 63105 INSURER(S)AFFORDING COVERAGE NAIL• INSURER A:Gotham-Insurance-Company 25569 INSURED INSURER B:New York Marine&General Insurance Company 16608 SunBug Solar,LLC;SunBug,LLC;SunBug WM,LLC INSURER C 411 A Highland Ave#312 INSURER D Somerville,MA 02144 INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF POLICY EXPITIR LIMITS A X COMMERCIAL GENERAL LIAMLITY1,000,000 ( EACH OCCURRENCE 5 CLAIMS-MADE X OCCUR PK201900010568 4/30/2019 4/30/2020 DAMAGE TO RENTED _ 1,000,000 PREMISES(Ea occurrence) $ ------------ MED EXP(Any one person) S 5,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER. GENERAL AGGREGATE 2,000,000 POLICY X PRO- OLOC PRODUCTS-COMPIOPAGGS 2,000,000 JECT OTHER. COMBINED SINGLE LIMIT 1,000,000 B AUTOMOBILE LIABILITY (Ea accident) $ ANY AUTO AU201900016856 4/30/2019 4/30/2020 BODILY INJURY(Per person) $ 20,000 OWNED AUTOS ONLY X S�OEDULED BODILY INJURY(Per 40'000 REE _ _ JCH DU Ep X AUTOS ONLY _X J';Al7TOS ONNLY (Peri PROPERTY $ 5,000 $ A X UMBRELLA LAB X OCCUR EACH OCCURRENCE $ 5,000,000 EXCESS LIAB CLAIMS-MADE UM201900005479 4/30/2019 4/30/2020 AGGREGATE $ 5,000,000 DED X RETENTION$ 10,000 $ B WORKERS COMPENSATION X STATUTE ORH AND ROPRIEERS'LIABILITY v Y/N WC201900015422 4/30/2019 4/30/2020 1,000,000 ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ FFFICER/MEMBER EXCLUDED) N/A 1 000()f)f) MandatoryInNH) E.L.DISEASE-EA EMPLOYEE $ If es,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ A Error&Ommissions PK201900010568 4/30/2019 4/30/2020 Extension 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached it more space is required) CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Information Purposes Only THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN p y ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE V � _ ACORD 25(2016/03) 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD The Commonwealth of Massachusetts Department of Industrial Accidents Office of Investigations 600 Washington Street Boston, MA 02111 UV www mass.gov/dia Workers' Compensation Insurance Affidavit: Builders/Contractors/Electricians/Plumbers Applicant Information Please Print Legibly Name (Business/Organization/Individual): S u n B u g Solar Address: 411A Highland Ave., Suite 312 City/State/Zip: Somerville, MA, 02144 Phone #: 617 500 3938 Are on an employer?Check the appropriate box: Type of project(required): 1 am a employer with 70 4.11 I am a general contractor and I 6. New construction employees (full and/or part-time).* have hired the sub-contractors 2D am a sole proprietor or partner- listed on the attached sheet. t Remodeling ship and have no employees These sub-contractors have 8. Demolition working for me in any capacity. workers' comp. insurance. 9• Building addition [No workers' comp. insurance 5.F-]We are a corporation and its required.] officers have exercised their 1 Electrical repairs or additions 3�am a homeowner doing all work right of exemption per MGL 11 Plumbing repairs or additions yself. [No workers'comp. c. 152, §1(4),and we have no 1 Roof repairs insurance required.] t employees.[No workers' 1_ �/ Other Solar Installation comp. insurance required.] *Any applicant that checks box#1 must also fill out the section below showing their workers'compensation policy information. t Homeowners who submit this affidavit indicating they are doing all work and then hire outside contractors must submit a new affidavit indicating such. $Contractors that check this box must attached an additional sheet showing the name of the sub-contractors and their workers'comp.policy information. I am an employer that is providing workers'compensation insurance for my employees. Below is the policy and job site information. Insurance Company Name: New York Marine and General Insurance Policy#or Self-ins. Lic. #: WC201900015422 Expiration Date: 4/30/20 Job Site Address: City/State/Zip: Attach a copy of the workers' compensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under Section 25A of MGL c. 152 can lead to the imposition of criminal penalties of a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of a STOP WORK ORDER and a fine of up to$250.00 a day against the violator. Be advised that a copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. Ido hereby certi�and the and penalties of perjury that the information provided above is true and correct. Signa e: Date: Phone=: 617 506'3938 Official use only. Do not write in this area,to be completed by city or town official City or Town: Permit/License# Issuing Authority(circle one): 1.Board of Health 2. Building Department 3.City/Town Clerk 4.Electrical Inspector 5.Plumbing Inspector 6.Other Contact Person: Phone#: (9 LG Life's Good ■ LG NeON®R M2616M MMM ME ME m M 31 Mem The LG NeON®R is a powerful solar module that provides world-class performance.A new cell structure that eliminates electrodes on the front o�E COus maximizes the utilization of light and enhances 60 cell reliability.The LG NeON®R is a result of LG's efforts to increase customer value beyond basic efficiency. C C The NeON®R features enhanced durability and performance under real-world conditions,an enhanced warranty and an aesthetic design suitable for roofs. Enhanced Warranties LG offers a 25-year product warranty for LG NeON®R, High Power Output including labor,in addition to an enhanced performance The LG NeON®R has been designed to significantly warranty.After 25 years,LG NeON19 R is guaranteed to enhance its output,making it efficient even in produce at least 88.4%of its initial power output. limited spaces. Roof Aesthetics Outstanding Durability LG NeON®R has been designed with aesthetics in With its newly reinforced frame design,LG NeON®R mind:the lack of any electrodes on the front creates an can endure a front load up to 6000 Pa,and a rear load improved,modem aesthetic. up to 5400 Pa. • ' Improved Performance on Sunny P Y Days Near Zero LID(Light Induced Degradation) ❖ LG NeON R now performs better on sunny days,thanks The n-type cells used in LG NeON°R have almost no to its improved temperature coefficient. boron.This leads to less LID right after installation. About LG Electronics LG Electronics is a global leader,n ek tl c products n the clean energy mwke s by off­g g:ow PV peels and energy stwage syau The company fim e.*.Iked an a solar LG Solar energy source research program in 1986.supported by LG Groups vast•apim—m the—corductw,LCO,dw.,ri—y and m iwnail:ndustrrcz.n 2010.LG Solar­Noy released ns first M—Xa sear m the market,which a now ere 1"in 32 cow—TM NeOW(pr—M—Xe N.M).N~2,WON-2 Biracial—the`Int—N. AWARD'in 2013,2015 and 2016.Much demonstrates LG's Ieadwsup a d wino hun in the soler industry DS_LG3W3%Q1C.A6.IrM 1 4/2/19 6:01 PM LG NeON3R •• Mechanical Properties Electrical Properties(STC*) Cells 6x10 Mndu1M 350 3S5 360 385 Cell Vendor _..........__....... ._.LG-..... Maximum Power(Prnex) 350 355 360 365 Cell Type M-rystaWne I Wtype MPP Voltage(Vmpp) 361 363 36.5 367 Cell Dimensions 1617.161.7 mm/6 inches MPP Current(impp) 9.70 9.79 9.87 995 Dimensions(L x W x H) 1700 x 1016 x 40 mm Open Circe t Voltage(Vx) 42.7 42742.7 428 66.93 x 40.0 x 1.57 xxh Short Cxcu4 Current(Isc) 10.77 10.78 10.79 108 Ferrt Load 6,000Pa 1 125 psf Module Efficier" 20.3 20.6 208 21 1 Rear Load 5,40OPa/113 psf Operating Temperature -40--90 Weight 18.5 kg 140 79 Ib Maximum System Voltage 1000 Connector Type MC4 Maximum Seines Fme Rating 20 Junction Box IP68 with 3 Bypass Dwdes Pma-Ti.-(%) O-.3 Length of Cahles 1000 mm x 2 ea Glass Tempered Glass with AR Coatrg Frame Arwdized Akxrrenen STC(Standard Test Corxf,uon}Irradfianc•1000 Wlm=,AmbTentperature 1 The nameplate power output rs measured and datermmed by LG Electronxs at ns sole and absolute d:crenon 'The typical change,r mo0ula efficiency at 200 W/m'in relation to 1000 W/m'is-2 0% Certifications and Warranty Ekancal Properties(NOCT*) --- IEC 61215.1EC 61730.1/•2 Module 350 35s 360 365 UL 1703Maxinwm Fie-(Pmex) 263 267 271 275 - �-...__-------------------- Certifications IEC 61701(Salt mist corrosion t est) MPP Voltage(Vmpp) 36.0 36.2 364 36.6 IEC62716(Ammor"corrosiontest) MPP Current(Irri _732 7.39 745 7.51 ISG 9001 Open Circuit Vottage(Vnc) 40.1 402 40.2 402 Module Fire performance(USA) Type Shut Crcuit Cun t(Isc) 8.67 8.68 869 8.70 Fire Resistance Class(CANADA) Class C(ULC/OROC1703) 'NOR(Nominal Operating Cet:lempeniati Irradiance 800 W/m2,ambient tomperat-20'C,wind Product Warranty 25 years speed l mrs Output Warranty of Pmax Umar wNT*rW -1)First 5 years 9514k 2)After 5th year,O 4%annual degradation,3)2S yeer 884% Dimensions(mm!inch) Temperature Characteristics + t NOCT 44 t 3'C Voc -0.24Yd'C Ise 0.04%-K Characteristic Curves ------ -- __ Qr2W am.ts,ea.es -.-_--___--_ 1aoD u 800 ------- - - 6110 f .I. . 1 400 I it I 2.00 � I OW S00 10W 1500 2000 2500 3a" 35D0 400D 4500 j kt v �Pries. --1- i 20 4 t- -- 1 0----.__._.,...___._-----..___.. Te-at..e r•q •The distance between the center of the mounting/grounding holes 40 -2S o 25 50 T5 0. LG Ele:trimcs Inc Product specificaticrrs are subject to change without notice. OLG Solar M,Ilmss Dnnsion DS_LG350-365410-AS_US_VerOl jx# 2000 Business Drrve { Lincolnshire.IL 60D69 r•V- . x Life'sGood wwwlg-solarcom 012019 LG Elect-cs.All rights reser-d r a-•� DS_LG350-36501C-A5.Indd 2 4019 6:01 PM I Single Phase Inverter z C with HD-Wave Technology rn for North America T! SE3000H-US / SE380OH-US / SE5000H-US / SE6000H-US / SE760OH-US / SE10000H-US / SE1140OH-US I..'.' r12-215 YEAR • WARRANTY Ln 0 0 e • o e solar:' ,,HD solar IX 0 O 'O • O O e , • o a o O W Optimized installation with HD-Wave technology / Specifically designed to work with / UL1741 SA certified,for CPUC Rule 21 grid compliance power optimizers / Record-breaking efficiency / Extremely small / Quick and easy inverter commissioning directly / guilt-in module-level monitoring from a smartphone using the SolarEdge SetApp / Fixed voltage inverter for longer strings / Outdoor and indoor installation / Integrated arc fault protection and rapid shutdown for NEC 2014 and 2017, per article / Optional: Revenue grade data, ANSI C12.20 690.11 and 690.12 Class 0.5 (0.5%accuracy) solaredge.com solare e z / Single Phase Inverter with HD-Wave Tec no ogy for North America SE3000H-US / SE380OH-US / SE5000H-US / SE6000H-US/ SE760OH-US / SE1000OH-US / SE1140OH-US SE300OH-US811 111 .111 .11 till 11 APPLICABLE TO INVERTERS WITH PART NUMBER SEXXXXH-XXXXXBXX4 OUTPUT Rated AC Power Output 3000 3800 @240V 5000 6000 @ 240V 7600 10000 11400 @ 240V VA 3300 @ 208V 5000 @ 208V 10000 @ 208V Maximum AC Power Output 3000 3800 @ 240V 5000 6000 @ 240V 7600 10000 11400 @ 240V VA 3300 @ 208V 5000 @ 208V 10000 @ 208V AC Output Voltage Min.-Nom.-Max. ✓ ✓ ✓ ✓ ✓ ✓ ✓ Vac (211-240-264) AC Output Voltage Min.-Nom.-Max. ✓ ✓ I ✓ Vac (183-208-229) AC Frequency(Nominap 59.3-60-605' Hz Maximum Continuous Output 12.5 16 21 25 32 42 47.5 A Current @240V Maximum Continuous Output 16 - 24 - - 48.5 A Current @208V Power Factor 1,adjustable-0.85 to 0.85 GFDI Threshold 1 A Utility Monitoring,Islanding Protection,Country Configurable Yes Thresholds INPUT Maximum DC Power @240V 4650 5900 7750 1 9300 11800 15500 17650 W Maximum DC Power @208V - 5100 7750 15500 W Transformer-less,Ungrounded les Maximum Input Voltage 480 Vdc Nominal DC Input Voltage 380 400 Vdc Maximum Input Current @240W'' 8.5 10-S5 16.5 20 27 30.5 Adc Maximum Input Current @208V' - 9 13.5 - 27 Adc Max.Input Short Circuit Current 45 Adc Reverse-Polarity Protection les Ground-Fault Isolation Detection 600ku Sensitivity Maximum Inverter Efficiency 99 i 99.2 % CEC Weighted Efficiency 99 99 @ 240V % 98.5 @ 208V Nighttime Power Consumption <2.5 W For other regional settings please contact SolarEdge support "'A higher current source may be used;the inverter will limit its input current to the values stated / Single Phase Inverter with HD-Wave Technology for North America SE3000H-US / SE380OH-US / SE5000H-US / SE6000H-US/ SE760OH-US / SE1000OH-US / SE1140OH-US 00„ .,O ADDITIONAL FEATURES Supported Communicator RS485,Ethernet,ZigBee(optional) Cellular(optional) Revenue Grade Data,ANSI C12.20 Optiolali37 Inverter Commissioning with the SetApp mobile application using built-in W114i station for local connection Raapid6SShh 1tdown-NEC 2014 and Automatic Rapid Shutdown upon AC Grid Disconnect STANDARD COMPLIANCE Satety 1.11.1741,UL1741 SA,U1.16998,CSA C22.2,Canadian AFCI according to T.I.L.M-07 Grid Connection Standards IEEE1547,Rule 21,Rule 14(HI) Emissions FCC Part 15 Class B INSTALLATION SPECIFICATIONS AC Output Conduit Size/AWG 3/4'minimum/14-6 AWG 3/4'minimum/14-4 AWG Range DC Input Conduit Size/#of Strings/ 3/4'minimum/1-2 strings/14-6 AWG 3/4'minimum/1-3 strings/14-6 AWG AWG Range Dimensions with Safety Switch 17.7 x 14.6 x 6.8 /450 x 370 x 174 21.3 x 14.6 x 7.3/540 x 370 x 185 in/ (HxWxD) mm Weight with Safety Switch 22110 1 25.1/11.4 1 26.2/11.9 38,8/17.6 Ib/kg Noise <25 <50 dBA Cooling Natural Convection Operating Temperature Range -40 to+140/-40 to+60111 F/°C Protection Rating NEMA 4X(Inverter with Safety Switch) ;"Revenue grade inverter P/N:SExxxxH-US0008NC4 Full power up to at least WC/122-F;for power de-rating infornution refer to:https://wwwsolaredge,corn/sstesidefauttlfiles/se-temperature-derating-note-na pdf 6 SolarEdge Technologies,Inc.All rights reserved.SOLAREDGE,the Solarlidge logo.OPTIMQED 8Y SOLAREDGE are trademarks or registered trademarks of SolarEdge Technologies,Inc,All Ro H S other trademarks mentioned herein are trademarks of their respective owr—Date:1/2019N07/fNG,NAM Subjert to change without notice. Power Optirnizer O For North America P320 / P340 / P370 / P400 / P405 / P505 M r2 51 YEAR 70 WARRANTY O IN M 70 PV power optimization at the module-level / Specifically designed to work with SolarEdge / Fast installation with a single bolt inverters / Next generation maintenance with module- / Up to 25% more energy level monitoring / Superior efficiency(99.5%) / Meets NEC requirements for arc fault protection (AFC[) and Photovoltaic Rapid / Mitigates all types of module mismatch losses, Shutdown System (PVRSS) from manufacturing tolerance to partial shading / Module-level voltage shutdown for installer / Flexible system design for maximum space and firefighter safety utilization solaredge.com solars � / Power Optimizer For North America P320 / P340 / P370 / P400 / P405 / P505 P340 P37' P400 P505 O. 1 / module ./ power 60-cell cell .. .1 . modules) modules) .. modules) INPUT Rated Input DC Power/' 320 340 370 400 1 405 505 W Absolute Maximum Input Voltage 48 60 80 1250 830 Vdc (Voc at lowest temperature) MPPT Operating Range 8-48 8-60 8-80 12.5-105 12.5-83 Vdc Maximum Short Circuit Current 11 10.1 14 Adc (Isc) Maximum DC Input Current 13.75 12.63 17.5 Adc Maximum Efficiency 99.5 % Weighted Efficiency 98.8 98.6 % Overvoltage Category II OUTPUT DURING OPERATION(POWER OPTIMIZER CONNECTED TO OPERATING SOLAREDGE INVERTER) Maximum Output Current 15 Adc Maximum Output Voltage 60 85 I Vdc OUTPUT DURING STANDBY(POWER OPTIMIZER DISCONNECTED FROM SOLAREDGE INVERTER OR SOLAREDGE INVERTER OFF) Safety Output Voltage per Power Optimizer t Qt Vdc STANDARD COMPLIANCE EMC FCC Part15 Class 8,IEC61000-6-2,IEC61000-6-3 Safety IEC62109-1(class 11 safety),UL1741 RoHS Nes INSTALLATION SPECIFICATIONS Maximum Allowed SySlein 1000 Vdc Voltage Compatible inverters All SolarEdge Single Phase and Three Phase inverters Dimensions(W x L x H) 129x153x27.5/5.1x6x1.1 129x153x33.5/ 129x159x49.51 129x162x59/ mm/in 5.1x6x1.3 5.1 x6.3 x1.9 5.1x6.4x2.3 Weight(including cables) 630/1.4 1 750/1.7 84S/1.9 1064/2.3 gr/Ib Input Connector _ MC4V1 Output Wire Type/Connector Double Insulated:MC4 Output Wire Length 0.9513.0 1.2/3.9 m/ft Input Wire Length 0.16/0.52 m/ft Operating Temperature Range -40-+85/-40-+185 -C/-F Protection Rating IP68/NEMA6P Relative Humidity 0-100 % Rated STC power of the module.Module of up to+5%power tolerance alkwred NEC 2017 requires max input voltage be not more than 80v 'For other connector types please contact SolwIdge PV System Design Using Single Phase Single phase Three Phase 208V F hi ee Phase 480V SolarEdge HD-Wave P320.P34(,.=;;0, P�lir�i:run,Stl ir.�Ler,�!n ' P40Q 8 10 18 (Power Optimizers) P405/P505 6 8 14 Maximum String Length 25 25 50161 (Power Citimizers) 5700(6000 with Maximum Power per String SE7600-US-SE11400- 5250 600(YA 12750-1, W US) Parallel Strings of Different Lengths Yes or Orientations For detailed string sizing information refer to:http.,/Aw .scbrpdge,cofn/sites/defau tAiiks/3ring-sizing-na.pdf "It is not allowed to mix P40S/PS05 with P320/P340/P370/P400 in one string A string with more than 30 optimizers does not meet NEC rapid shutdown requirements:safety voltage will be above the 30V requirement '^For SE14.4KUS/SE43.2KUS,It is allcmed to install up to 6,500W per string when 3 strings are connected to the inverter(3 strings per unit for SE43.2KUS)and when the maximum power difference between the strings is up to 1,ODDW For SE30KUS/SE33.3KUS/SE66.6KU5/SHOOKUS:Itis allowed to install up to 15.000W per string when 3 strings are connected to the imrertei(3 strings per unit for SE66.6KU5/SE100KUS) and when the maximum power difference between the strings is up to 2,000W C Solar Edge Technologies Ltd.All rights reser d SOLAREDGE,the SolarEdge toga.OP71MVED 8Y SOLAREDGE are trademarks or registered trademarks of Solarldge Technologies,Inc. E Ro H S All other trademarks mentioned herein are trademarks of their respective owners.Date:121M18NO1/ENG NAM.Subject to change snthou,notice SnapNrack- UR-40 Solar Mounting Solutions UR-60 Ultra Rail The Ultimate Value in Rooftop Solar Industry leading Wire Al Mounts available for all Management Solutions roof types Single Tool Installation r All SnapNrack Module. r . • • Accessories Vb are compatible with both raiii profiles Start Installing Ultra • il • • • RESOURCES snapnrack.com/resources DESIGN snapnrack.com/configurator WHERE TO BUY snapnrack.com/where-to-buy SnapNrack A sleek, straightforward rail solution for mounting solar modules on all roof types. Ultra Rail features two rail profiles; UR-40 is a lightweight rail profile that is suitable for most geographic regions and maintains all the great features of SnapNrack rail, while UR-60 is a heavier duty rail profile that provides a larger rail channel and increased span capabilities. Both are compatible with all existing mounts, module clamps, and accessories for ease of install. The Entire System is a Snap to Install • New Ultra Rail Mounts include snap-in brackets for attaching rail • Compatible with all the SnapNrack Mid Clamps and End Clamps customers love • Universal End Clamps and snap-in End Caps provide a clean look to the array edge i!l Unparalleled Wire Management • Open rail channel provides room for running wires resulting in a long-lasting quality install • Industry best wire management offering includes Junction Boxes, Universal Wire Clamps, MLPE Attachment Kits, and Conduit Clamps • System is fully bonded and listed to UL 2703 Standard Heavy Duty UR-60 Rail • UR-60 rail profile provides increased span capabilities for high wind speeds and snow loads • Taller, stronger rail profile includes profile- specific rail splice and end cap • All existing mounts, module clamps, and accessories are retained for the same great install experience Quality. Innovative . Superior. SnapNrack Solar Mounting Solutions are engineered to optimize material use and labor resources and improve overall installation quality and safety. . • www.snapnrack.com • • • •► N SUNM INSTALLATION MADE EZ & EZR61 EZ + . EZR t. SUnModO' S best-selling EZ Roof Mount is the industry standard for PV system • mounting on any composite . . . . - . . - shingle roof. - • • • • Now, SunModo introduces a smaller footprint, EZR Roof Mount flashing, where truss _ • anchoring can be assured, embossed design minimizes bending, and only one tool is needed. Key Features SUNM*&m0,F'h0' 1 1 1 MODELEZ Mount EZR Mount ; I I - - - - - - - - - - - - - - - - � - - -I Raised teardrop design diverts water from the roof penetration. - - - - - - - - - - - - - - - - 360-clegree .. positioning, serrated .. . ' 1 1 both sides for rail mounting. J J 1 1 I - - - - - - - - - - - - - - - - - - A wide variety of L-feet and standoffs available. 1 1 1 1 1 t 1 1 1 - - - - - - - - - - - - - - - - - -- Versatile - • - • • option includes direct-to- decking _ • 1 1 1 1 1 1 1 I _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ y _ _ _ _ - - _ _. _ _ _ _ _ - _ _ - _Stamped emboss features stiffen the flashing toI 1 I minimize bending. 1 1 _ _ _ _ _ _ _ _- _ _ _ _ - - - - - - - - - - - - - - - - - - Only one •• is needed. I t 1 -- _ _ _ _ _ - _ _ - _. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _1 Application Composite shingle Material High grade aluminum, 304 stainless steel hardware Finish Clear- anodized, silver or black powder coated Flashing Size EZ Roof Mount: 10.00 x 12.48 x 0.04 inches EZR Roof Mount: 8.00 x 11 .38 x 0.03 inches Roof Attachment EZ Roof Mount: Rafter and decking EZR Roof Mount: Rafter only Structural Integrity IBC and IRC compliant Warranty 20 years SunModo, Corp. Vancouver, WA., USA - www.sunmodo.com - 360.844.0048 - info@sunmodo.com POWERWALL Tesla Powerwall is a fully-integrated AC battery system for � L n residential or light commercial use. Its rechargeable lithium-ion .T. battery pack provides energy storage for solar self-consumption, time-based control,and backup. Powerwall's electrical interface provides a simple connection to any home or building. Its revolutionary compact design achieves market-leading energy density and is easy to install,enabling owners to quickly realize the benefits of reliable,clean power. PERFORMANCE SPECIFICATIONS MECHANICAL SPECIFICATIONS AC Voltage(Nominal) 120/240 V Dimensions 1150 mm x 755 mm x 155 mm Feed-In Type Split Phase (45.3 in x 29.7 in x 6.1 in) Weight 125 kg(276 lbs) Grid Frequency 60 Hz Mounting options Floor or wall mount Total Energy' 14 kWh Usable Energy' 13.5 kWh 755 mm 155 mm (29.7 in) (8.1 in) Real Power,max continuous 5 kW(charge and discharge) Real Power,peak(10s,off-grid/backup) 7 kW(charge and discharge) Apparent Power,max continuous 5.8 kVA(charge and discharge) T9SLFi Apparent Power,peak(10s,off-grid/backup) 7.2 kVA(charge and discharge) Maximum Supply Fault Current 10 kA Maximum Output Fault Current 32 A 1150 mm (45.3 in) Overcurrent Protection Device 30 A Imbalance for Split-Phase Loads 100% I Power Factor Output Range +/-1.0 adjustable i Power Factor Range(full-rated power) +/-0.85 Internal Battery DC Voltage 50 V Round Trip Efficiency',' 90% Warranty 10 years ENVIRONMENTAL SPECIFICATIONS 'Values provided for 25`C(771F),3.3 kW cnarge`diu,hanle power. Operating Temperature -201C to 50°C(-4°F to 122'F) 'AC to battery to AC,at beginning of life. Optimum Temperature 0'C to 30'C(32'F to 86'F) COMPLIANCE INFORMATION Operating Humidity(RH) Up to 100%,condensing Certifications UL 1642,UL 1741,UL 1973, Storage Conditions -201C to 301C(-4'F to 86'F) UL 9540,IEEE 1547,UN 38.3 Up to 95%RH,non-condensing State of Energy(SoE):25%initial Grid Connection Worldwide Compatibility Maximum Elevation 3000 m(9843 ft) Emissions FCC Part 15 Class 8,ICES 003 Environment Indoor and outdoor rated Environmental RoHS Directive 2011/65/EU Enclosure Type NEMA 3R Seismic AC 156.IEEE 693-2005(high) Ingress Rating IP67(battery 8 Power Electronics) IP56(Wiring Compartment) Wet Location Rating Yes Noise Level @ 1m <40 d8A at 30'C(86'F) T=S L n TYPICAL SYSTEM LAYOUTS WHOLE HOME BACKUP Solar Fol 0 Solar inverter Main panel Backup Gateway Utility meter Grid including service disconnect Tas�R 0 Powerwall Whole home backup PARTIAL HOME BACKUP Z Solar I Solar inverter - Sub panel Backup Gateway Main panel Utility meter Grid I n 0 Powerwall Backup loads Home loads T=5Ln